Hvac Tenders

Details: A Market Survey Is Being Conducted To Determine If There Are A Reasonable Number Of Interested Small Business Concerns To Set This Future Project Aside For Them. If Your Firm Is A Small Business, Certified Hubzone, 8a, Woman-owned Small Business Or Service-disabled Veteran Owned Small Business And You Are Interested In This Project Please Respond Appropriately. project Location: Dublin, Alameda County, California project Description: The Proposed Project Is A Design/bid/build (dbb) Construction Project Of A Standard Design 45,000 Sf Two-story Advanced Skills Training Barracks. Buildings Will Be Of Permanent Construction With Reinforced Concrete Foundations; Concrete Floor Slabs; Masonry Veneer And Efis Over Load Bearing Cmu; Low-slope Or Sloped Roof; Heating, Ventilation And Air Conditioning (hvac); And Plumbing, Mechanical, Security And Electrical Systems. Supporting Facilities Include Land Clearing, Paving, Fencing, General Site Improvements And Utility Connections. Accessibility For The Disabled Will Be Provided. Antiterrorism/force Protection (at/fp) And Physical Security Measures Will Be Incorporated Into The Design Including Maximum Standoff Distances From Roads, Parking Areas And Vehicle Unloading Areas. Sustainability/energy Measures Will Be Provided. Facilities Will Be Designed To A Minimum Life Of 40 Years In Accordance With Dod’s Unified Facilities Criteria (ufc 1-200-02) Including Energy Efficiencies, Building Envelope And Integrated Building Systems Performance. contract Duration Is Estimated At 700 Calendar Days. The Estimated Cost Range Is Between $25,000,000 And $100,000,000. Naics Code Is 236220. All Interested Small Businesses, Certified Hubzone, 8a, Woman-owned Small Business Or Service-disabled Veteran Owned Small Business Contractors Should Respond To This Survey Via Email By Tuesday, August 27, 2024, By 3:00 Pm Eastern Standard Time. responses Should Include: identification And Verification Of The Company’s Small Business Status. contractor’s Unique Entity Identifier (uei) And Cage Code(s). documentation From The Firm’s Bonding Company Showing Current Single And Aggregate Performance And Payment Bond Limits. provide Descriptions Your Firm’s Past Experience On Projects On No More Than Three (3) Projects With Greater Than 90% Construction Complete Or Those Projects Completed Within The Last Five Years Which Are Similar To This Project In Size And Scope. Provide Documentation Demonstrating And Managing Multiple Sub-contractors small Businesses Are Reminded Under Far 52.219-14, Limitations On Subcontracting; They Must Perform At Least 15% Of The Cost Of The Contract, Not Including The Cost Of Materials, With The Firm’s Own Employees For General Construction-type Procurement. Include The Percentage Of Work That Will Be Self-performed On This Project, And How It Will Be Accomplished. projects Similar In Scope To This Project Include: Projects Considered Similar In Scope To This Project Include Multi-story (two Or More Floors) New Construction, Of Barracks, Hotels, Dormitories, Apartment Buildings And Classroom Facilities. Construction Of Pre-engineered Buildings Does Not Count Toward A Project Of Similar Scope Or Size. projects Similar In Size To This Project Include: Projects Similar In Size Will Include Projects With New Construction Of Approximately 27,000 Sf Or Greater. based On Definitions Above, For Each Project Submitted Include: current Percentage Of Construction Complete And The Date When It Was Or Will Be Completed. scope Of The Project. size Of The Project. dollar Value Of The Project. the Portion And Percentage Of Work That Was Self Performed. whether The Project Was Design/build Or Not. note: Total Submittal Package Shall Be No Longer Than 8 Pages. Please Only Include A Narrative Of The Requested Information; Additional Information Will Not Be Reviewed. email Responses And Any Questions To Seth Dukes At Seth.j.dukes@usace.army.mil. This Is Not A Request For Proposal And Does Not Constitute Any Commitment By The Government. Responses To This Sources Sought Notice Will Be Used By The Government To Make Appropriate Acquisition Decisions. All Interested Sources Must Respond To Future Solicitation Announcements Separately For Responses To This Market Survey. notice: The Following Information Is Provided For Situational Awareness And Is Not Required To Respond To This Sources Sought. all Contractors Must Be Registered In The System For Award Management (www.sam.gov) Prior To Award Of A Contract. All Proposed Contractors Are Highly Encouraged To Review Far Clause 52.232-33 Payments By Electronic Funds Transfer – System For Award Management, Which Indicates “all Payments By The Government Under This Contract Shall Be Made By Electronic Funds Transfer (eft).” Those Not Currently Registered Can Obtain Registration By Going To The Website Http://www.sam.gov. The Process Can Usually Be Completed From 24 To 48 Hours After Submission. Contractors Will Need To Obtain A Unique Entity Identifier (formerly Duns Number) For Processing Their Registration. If You Do Not Already Have A Unique Entity Identifier, One Can Be Obtained From Http://www.sam.gov. Refer To Www.sam.gov For Information Formerly Found In Ccr, Epls, Orca And Fedreg. please Begin The Registration Process Immediately In Order To Avoid Delay Of The Contract Award Should Your Firm Be Selected. alert: You Must Submit A Notarized Letter Appointing The Authorized Entity Administrator Before Your Registration Will Be Activated. This Requirement Now Applies To Both New And Existing Entities. Effective 29 April 2018, The Notarized Letter Process Is Now Mandatory On All Current Registrants At Sam Who Have A Requirement To Update Data On Their Sam Record. The Notarized Letter Is Mandatory And Is Required Before The Gsa Federal Service Desk (fsd) Will Activate The Entity's Registration. effective 29 June 2018, Vendors Creating Or Updating Their Registration Can Have Their Registration Activated Prior To The Approval Of The Required Notarized Letter. However, The Signed Copy Of The Notarized Letter Must Be Sent To The Gsa Federal Service Desk (fsd) Within 30 Days Of Activation Or The Vendor Risks No Longer Being Active In Sam. vendors Can Check Whether An Account Is Active By Performing A Query By Their Cage Or Unique Entity Identifier (known As Duns). The New Registration Process May Now Take Several Weeks, So Vendors Are Highly Encouraged To Begin Registering As Soon As Possible To Avoid Any Possible Delays In Future Contract Awards. Remember, There Is No Cost To Use Sam. to Find Out Additional Information About The Changes Of The Sam Registration Process, Contractors Should Visit The Frequently Asked Questions (faq) Link Located At The Top Of The Sam Homepage (www.sam.gov).

Details: The Us Department Of Labor, Office Of Job Corps Acquisition Services, Has A Requirement For A Qualified Firm To Provide Design/build (design And Construction) Services For The Renovation Of The Male Dormitory Building 54 At The Potomac Job Corps Center In Washington, Dc. This Is A Sources Sought Notice. In Accordance With Federal Acquisition Regulation (far) 10.002 (b) (2) (i), This Notice Is Issued For The Purpose Of Conducting Market Research. Market Research Is Being Conducted To Determine If There Are Potential Businesses With The Capacity And Experience To Perform The Required Work. This Notice Is Not An Invitation For Bid Or Request For Proposal. there Is No Solicitation At This Time. This Request For Capability Information Does Not Constitute A Request For Proposal; Submission Of Any Information In Response To This Market Survey Is Purely Voluntary; The Government Assumes No Financial Responsibility For Any Costs Incurred. the Full Extent Of The Work Will Be Described In The Solicitation, Which May Follow At A Later Date. However, A Summary Of The Services To Be Performed Is Provided As Follows: the Work Involves Design-build (design And Construction) Services For The Renovation Of Male Dormitory Building 54 At The Potomac Job Corps Center. Male Dormitory Building 54 Is A Two-story Structure Totaling Approximately 25,580 Gsf, Built In 1997. The Building Has Concrete Foundation With Loadbearing Masonry Walls. The Roof Structure Is Wood With Asphalt Shingles Roofing System And Exterior Gutters/downspouts Which Was Replaced In 2019. The Building Interiors Were Severely Damaged By Continuous Roof Leaks, Which Caused Mold/mildew Issues In The Building. As A Result Of The Mold/mildews Growth, Remediation Was Performed. this Work Includes, But Is Not Limited To, Interior Renovations Of The 1st And 2nd Floors Including Wall, Ceiling And Flooring Replacements And Repairs; Painting; Door Repairs; Elevator Repair, Certification And Permitting; Plumbing And Electrical System Repairs And Replacements Inclusive Of New Fire Alarm And Sprinkler Systems, Mechanical System Replacements; And Attic Insulation Replacements. The Work Also Involves, Hvac System Replacement And Duct Cleaning, Plumbing Upgrades, Domestic Hot Water Systems Replacement, Fire Alarms Replacement, Electrical Systems And Security Systems Upgrades And Repairs To The Existing Elevator Cab And Equipment And Renovation To The Exterior Stairwells As Well As Roof Soffit Vents/panels Repair. estimated Construction Value • Base: Phase I (2nd Floor): $1,000,000 And $5,000,000 • Optional Clin - Phase Ii (1st Floor): $1,000,000 And $5,000,000 firms Interested In This Requirement Are Requested To Submit A Statement Of Qualifications. Your Statement Of Qualifications Shall Demonstrate The Capacity Of Your Firm To Perform The Services Described Above, And Should Include The Following: 1. Previous Projects Of Similar Scope And Value your Submittal Shall Demonstrate That Your Firm Has Performed Design-build Services On Two Or More Institutional Dormitories Building Or Residential Living Facilities Multi-phase Renovation Projects That Include Architectural, Mechanical, Plumbing, Electrical, Fire Alarm, Fire Suppression, And Minor Exterior Repairs With A $1,000,000 To $5,000,000 Construction Value Within The Last Five Years. the Previous Project Examples Shall Include The Location Of The Project, The Project Owner, Brief And Concise Description Of The Project Scope, Specialty Design Consultants Employed, A Comparison Of The Construction Budget Versus Construction Award Value, And The Final Contract Amount. 2. Project Location your Project Examples Shall Include Three Or More Projects Completed Within The Last Five Years In The Region Of The Country Where This Project Is Located, Indicating A Familiarity With State And Local Codes, Environmental Conditions, Economic Conditions, And Experience With Local Design Consultants. 3. Cost Control, Project Schedule, Safety, And Quality Of Work your Previous Project Examples Shall Demonstrate A Proven Record Of Excellent Performance By Completing Projects On Or Ahead Of Time. Using The Previous Project Examples Include The Contract Award/ntp Date, The Original Contract Completion Date, And The Actual Contract Completion Date For Each Project. include With Your Submission Those Projects That Demonstrate A Proven Record Of Excellent Performance By Reducing Cost And Completing Projects On Or Below Budget. Using The Previous Project Examples Indicate The Contract Award Amount, The Final Contract Value, And A Percentage Of Change Order Value Relative To The Total Construction Value For Each Project. please Include With Your Submission Your Established Safety And Quality Control Procedures And Protocols Which Are Consistently Applied To All Projects. 4. Financial Capabilities contractor Must Be In Sound Financial Standing With No Claims Or Liens. Contractor Has Sufficient Financial Capacity To Bond A Project In The $1m To $5m Range. Bonding Capacity Must Be Included With Your Submission. Please Provide Your Aggregate And Per Project Bonding Capacity Limits. your Previous Project Examples Shall Include The Location Of The Project, The Project Owner, A Brief Description Of The Services Performed. Your Synopsis Should Include The Date Of Contract Award, The Original And Final Date Of Contract Completion, Original Contract Price, And Final Contract Value. the Government Will Evaluate Market Information To Ascertain Potential Market Capacity To 1) Provide Services Consistent In Scope And Scale With Those Described In This Notice And Otherwise Anticipated; And 2) Secure And Apply The Full Range Of Corporate Financial, Human Capital, And Technical Resources Required To Successfully Perform Similar Requirements. your Submission Should Not Exceed 10 Pages. Your Response To This Notice, Is Due No Later Than February 20, 2024, By 2:00 Pm Est. Please Submit Response Via Email To Bernadette L Hughes, Contract Specialist, Us Department Of Labor/oasam/ospe/jcas, A&e Construction, Hughes.bernadette.l@dol.gov. hub Zone, Small Disabled Veterans, Small Disadvantaged, 8(a) Certified, Wosb, And Large Businesses Are Encouraged To Submit A Response To This Notice. The Naics Code For This Requirement Is 236220. acknowledgement Of The Responses Will Not Be Made, Nor Will Respondents Be Notified Regarding The Results Of The Government’s Evaluation Of The Information Received. The Determination To Proceed With The Acquisition Is Within The Discretion Of The Government. Telephone Inquiries Will Not Be Accepted. a Prospective Offeror Interested In Obtaining A Contract Award With The Government Must Be Registered In The Federal Government’s System For Award Management (sam) Database. Additional Information Regarding Contractor Registration Can Be Obtained Through The Following Website, Www.sam.gov.

Details: This Is A Sources Sought Synopsis Announcement, A Market Survey For Information To Be Used For Preliminary Planning Purposes. The Information Received Will Be Used Within The Navy To Facilitate The Decision-making Process And Will Not Be Disclosed Outside Of The Agency. The Intent Of This Sources Sought Synopsis Is To Identify Potential Qualified Small Businesses, U.s. Small Business Administration (sba) Certified 8(a) Businesses, Sba Certified Hubzone Small Businesses, Economically Disadvantaged Women Owned Small Businesses, And/or Service Disabled Veteran Owned Small Businesses. This Sources Sought Synopsis Is One Facet In The Governments Overall Market Research In Regards To Whether The Proposed Solicitation Will Be Issued As A Competitive Set-aside Or As Full And Open (unrestricted). No Procurement Strategy Will Be Determined Based Solely On The Information Received In Response To This Sources Sought Synopsis. No Reimbursement Will Be Made For Any Costs Associated With Providing Information In Response To This Announcement Or Any Follow-up Information Requests. This Notice Does Not Constitute A Request For Proposal And Is Not To Be Construed As A Commitment By The Government For Any Purpose Other Than Market Research. Respondents Will Not Be Notified Of The Results Of This Market Research. Naval Facilities Engineering Systems Command Southwest (navfac Sw) Is Seeking Small Business, Sba Certified 8(a) Business, Sba Certified Hubzone Small Business, Economically Disadvantaged Women Owned Small Business, And/or Service Disabled Veteran Owned Small Business Sources With Current And Relevant Experience, Personnel, And Capability To Perform A Multiple Award Construction Contract For Roofing System Projects. The Term Self-performance Refers To Performing Relevant Major Trade Work In-house Without Subcontractors. Relevant Major Trade Work Is That Which Is The Same Or Similar To The Work That May Be Ordered Under The Proposed Contract. The North American Industry Classification System (naics) Code Is 238160: Roofing Contractors With A Small Business Size Standard Of $19 Million. Task Orders Issued Under The Proposed Multiple Award Contract(s) Will Be Performed At Various Federal Sites Within The Area Of Responsibility (aor) Of Navfac Sw Including, But Not Limited To, California, Arizona, Nevada, Utah, Colorado, And New Mexico. However, It Is Anticipated That Most Projects Will Be Performed In The State Of California. The Proposed Contract(s) Will Be For One (1) Base Period Of Two (2) Years With Three (3) One-year Option Periods, Resulting In The Contract Performance Period Of Maximum Five (5) Years. The Estimated Total Contract Price For The Base Year And All Option Years Is $150,000,000. Task Order Range Is Estimated Between $100,000 And $7,500,000. Projects Will Be Primarily Design-bid-build Or Secondarily Design-build. Projects Will Predominantly Involve Roofing System Construction Including, But Not Limited To New Installation, Addition, Alterations, Maintenance, Repair, Roof Condition Assessment, Emergency Leak Response And Testing For Hazardous Material On Various Roofing Systems. It Also Covers All Roofing Related Work Such As, But Not Limited To, Demolition And Disposal Of Roofing Materials That May Contain Asbestos And Lead Paint, Removal And Reinstallation Of Equipment, Piping And Hvac Ductwork, Painting And Installation Of Gutters, Downspouts, Fascia, Sheet Metal Flashing, Sealants, Caulking, Insulation, Vents, And Drainage Assemblies. The Types Of Roofing Systems May Include, But Are Not Limited To: Single Ply, Pvc, Modified Bitumen, Shingle, Tile, Preformed Metal, Foam And Built-up Roofing Systems. Interested Sources Are Invited To Respond To This Sources Sought Announcement By Using The Forms Provided Under Separate File Titled Sources Sought Information Form. The Following Information Shall Be Provided:1) Contractor Information: Provide Your Firms Contact Information, Including Uei Number And Cage Code. 2) Type Of Business: Identify Whether Your Firm Is A Small Business, Sba Certified 8(a), Sba Certified Hubzone, Service Disabled Veteran Owned, And/or Economically Disadvantaged Women Owned Small Business Concern. For More Information On The Definitions Or Requirements For These Small Business\ Programs, Refer To Http://www.sba.gov/. 3) Bonding Capacity: Provide Your Surety?s Name, Your Maximum Bonding Capacity Per Project, And Your Aggregate Maximum Bonding Capacity. 4) Locations: Identify The Locations In Which You Are Willing And Capable To Work. 5) Submit A Maximum Of Five (5) Recent Specific Government Or Commercial Contracts/projects To Demonstrate Your Firms Experience In Self-performing Construction And Repair Of Roofing Systems As Indicated In This Announcement. A Specific Project Is A Single Project Or A Single Task Order Under An Indefinite Quantity Contract Or On-call Type Contract. Recent Is Defined As Having Been 100% Completed Within The Seven Years Prior To The Sources Sought Synopsis Issuance Date. All Projects Shall Have A Minimum Construction Cost Of $100,000. If Your Firm Performed The Work As A Subcontractor, Your Subcontract Shall Have A Minimum Construction Cost Of $100,000. Projects Which Do Not Meet These Requirements May Not Be Considered Relevant. Additional Submission Requirements: -at Least One (1) Self-performed Relevant Construction Project Shall Have A Construction Cost (forroofing Scope Only) Of $1,000,000 Or Above. This Refers To The Total Contract Cost If The Work Wasperformed By The Contractor As Prime Contractor, And The Subcontract Cost If The Work Wasperformed By The Contractor As A Subcontractor.-- At Least One (1) Self-performed Relevant Construction Project Demonstrating The Contractor?s Experience With The Full Replacement Of An Existing Roof.- At Least One (1) Self-performed Relevant Construction Project Demonstrating The Contractor?s Experience With Construction Or Repair Of A Standing Seam Metal Roof.- One Project Can Satisfy Two (2) Of These Additional Submission Requirements. For Each Of The Projects Submitted For Experience Evaluation, Provide The Following:-title And Location-award And Completion Dates-contract Or Subcontract Value-type Of Work For Overall Project-current Customer Information Including Point Of Contact, Phone Number, And Email Address-whether The Work Was Performed As A Prime Or Subcontractor-type Of Contract (design-bid-build Or Design-build ? See Sources Sought Information Form)-narrative Project Description-description Of The Work That Was Self-performed By Your Firm, Including The Percentage Of Contract Value Your Firm Self-performedresponses To This Sources Sought Announcement Are Due No Later Than Time 2:00 P.m. (pacific Standard Time) On March, 13, 2024. Please Provide Electronic Submissions By Email To Elson Muzada At Elson.g.muzada.civ@us.navy.mil). All Navfac Southwest Solicitations Are Posted On The Website At Https://sam.gov/ And Begin With N62473.

Details: Synopsis: introduction: in Accordance With Federal Acquisition Regulation (far) 10.002(b)(2), This Sources Sought Notice Is For Market Research And Information Purposes Only At This Time And Shall Not Be Construed As A Solicitation Or As An Obligation On The Part Of The Department Of Veterans Affairs (va). the Department Of Veterans Affairs, Veterans Health Administration (vha), Program Contracting Activity Central (pcac) Is Conducting A Market Survey And Is Seeking Potential Sources For The Ehrm Infrastructure Upgrades Construction Project At The Fargo Va Medical Center (vamc). project Description: the Project Includes But Not Limited To The Following Infrastructure Improvements: Construct New Data Center Addition To Include Electrical (electrical Panel, Lighting, Fire Alarm, Power Distribution (normal, Emergency, Bonding, Ups,) Mechanical (new Hvac And Ductwork, Controls, Interface With Building Management), Construction Of New Space (site Work, Utilities, Physical Security, Demo, New Construction, Finishes), Relocate Fiber Infrastructure Mda, Install Diversified Path To Datacenter For Wan Project Building Locations Include: Buildings 1 And Site. the Contractor Shall Completely Prepare Buildings And Campus For Operations, Including Demolition And Removal Of Existing Portions Of Structures, And Furnish Labor And Materials And Perform Work For Fargo Va Health Care System Ehrm Infrastructure Upgrades, Tier 2 Construction Project. procurement Information: the Proposed Project Will Be A Competitive, Firm-fixed-price Contract Utilizing The Design-bid-build Approach (final Specifications And Drawings Will Be Provided). The Anticipated Solicitation Will Be Issued Either As A Request For Proposal (rfp) In Accordance With Far Part 15, Considering Technical And Price Factors Or As An Invitation For Bid (ifb) In Accordance With Far Part 14, Considering Price Only. The Results And Analysis Of The Market Research Will Finalize The Determination Of The Procurement Method. The Type Of Socio-economic Set-aside, If Any, Will Depend Upon The Responses To This Notice And Any Other Information Gathered During The Market Research Process. this Project Is Planned For Advertising In June Of 2024. In Accordance With Vaar 836.204, The Magnitude Of Construction Is Between $10,000,000.00 And $20,000,000.00. The North American Industry Classification System (naics) Code 236220 (size Standard $45.0 Million) Applies To This Procurement. The Duration Of The Project Is Currently Estimated At 546 Calendar Days From The Issuance Of A Notice To Proceed. The Services For This Project Will Include Providing All Construction Related Services Such As: Providing Labor, Materials And Equipment Required To Complete The Project As Per Contract Documents Prepared By An Independent Architect-engineer Firm. capability Statement: respondents Shall Provide A General Capabilities Statement To Include The Following Information: section 1: Provide Company Name, Duns Number And Unique Entity Identifier (uei), Company Address, Point-of-contact Name, Phone Number And Email. section 2: Provide Company Business Size Based On Naics Code 236220. Also, Provide Business Type (i.e., Large Business, Small Business, Service-disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-owned Small Business, Hub Zone Small Business, Etc.). section 3: Provide A Statement Of Interest In The Project. section 4: Provide The Prime Contractor S Available Bonding Capacity In The Form Of A Letter Of Intent From Your Bonding Company With This Submission. *please Ensure That The Individual Bonding Capacity Is In Line With The Vaar Magnitude Of Construction Listed Above. section 5: Provide The Type Of Work Your Company Has Performed In The Past In Support Of The Same Or Similar Requirement. This Section Is Important As It Will Help To Determine The Type Of Socio-economic Set-aside, If Any. Please Provide The Following In Your Response: no More Than Three (3) Contracts That Your Company Has Performed Within The Last Seven (7) Years That Are Of Comparable Size, Complexity, And Scope To This Requirement. Include The Project Name, Project Owner And Contact Information As This Person May Be Contacted For Further Information, Project Scope, Project Size (example: Square Footage), Building Use (example: Medical Facility, Office Building, Etc.), Project Dollar Value, Start And Completion Dates. provide Specific Examples That Relate Aspects Of Previous Projects To The Proposed Project. Describe Specific Technical Skills And Key Personnel Your Company Possess To Perform The Requirements Described Under Description Of Work. describe Your Self-performed** Effort (as Either A Prime Or Subcontractor). Describe Self-performed Work In Terms Of Dollar Value And Description. **self-performed Means Work Performed By The Offeror Themselves, Not Work Performed By Another Company For Them For Any Of The Project Examples Provided. it Is Requested That Interested Contractors Submit A Response (electronic Submission) Of No More Than Eight (8) Single Sided Pages, Single-spaced, 12-point Font Minimum That Addresses The Above Information. This Response Must Be Submitted As A Single Application-generated (not Scanned) Pdf Document That Is Less Than Or Equal To 4mb In Size. Please Note That Hard Copies Will Not Be Accepted. Please Also Include A Cover Page, Which Includes, At A Minimum: The Company S Name, Address, Dun & Bradstreet Number, Unique Entity Identifier (if Available), Socio-economic Status, Point-of-contact Name, Phone Number, And E-mail Address. Responses Must Include The Sources Sought Number And Project Title In The Subject Line Of Their E-mail Response. Submissions (responses) Shall Be Submitted Via Email To The Primary Point Of Contact Listed Below By March 21, 2024 At 1:00 Pm Et. No Phone Calls Will Be Accepted. the Capabilities Statement Submitted In Response To This Sources Sought Shall Not Be Considered To Be A Bid Or Proposal. This Notice Is For Information And Planning Purposes Only And Is Neither To Be Construed As A Commitment By The Government Nor Will The Government Pay For Information Solicited. No Evaluation Letters And/or Results Will Be Issued To The Respondents. After Completing Its Analyses, The Government Will Determine Whether To Limit Competition Among The Small Business Categories Listed Above Or Proceed With Full And Open Competition As Other Than Small Business. at This Time No Solicitation Exists; Therefore, Please Do Not Request A Copy Of The Solicitation. If A Solicitation Is Released It Will Be Synopsized In Contract Opportunities At Https://sam.gov/. It Is The Potential Offeror's Responsibility To Monitor This Site For The Release Of Any Solicitation Or Synopsis. contracting Office Address: vha Program Contracting Activity Central (vha-pcac) 6100 Oak Tree Blvd. Suite 490 independence, Oh 44131 primary Point Of Contact: bailey Donato contract Specialist bailey.donato@va.gov

Details: Description this Is A Request For Information (questionnaire Attached). This Is Not A Request For Proposal (rfp), Request For Quote (rfq), Or An Invitation For Bid (ifb) And It Shall Not Be Construed As An Obligation On The Part Of The Government. There Will Be No Solicitation, Specification, Or Drawings Available At This Time. naval Facilities Engineering Systems Command Southeast (navfac Se) Is Soliciting Comments From The Construction Community Addressing The Use Of Project Labor Agreements (pla) For Construction Projects (including New Work, Additions, Alterations, And Repairs). p103 Construct Engineering Test Facility (etf) At Naval Ordnance Test Unit (notu). This Project Will Provide The U.s. Navy With A New Mission Critical Facility Located At Cape Canaveral Space Force Station (ccsfs) In Florida. The Facility Will Consist Of Approximately 132,000 Square Foot (sf) Building, Which Will Sit On An Approximate 33.50-acre Green Field Site. The Proposed Construction Includes A High Bay, Single Story Building With A Mezzanine On A Reinforced Concrete Foundation With A Steel Frame Superstructure And Reinforced Concrete Exterior Wall Panels. The Roof Structure Will Include Metal Decking Over Steel Joists Covered By Rigid Insulation And Built-up Roofing. Interior Walls Will Be Reinforced Concrete Masonry Units (cmu) With Filled Cores And Light-gage Metal Framing With Gypsum Wallboard Partitions Which Extend To The Underside Of The Roof / Ceiling. the Building Will Consist Of Large Laboratory (lab) And Test Areas. The Individual Areas Will Be Connected By An Internal Circulation Spine And Have Exterior Access For Material Delivery. The Facility Will Be Supported By Other Administration, Mechanical, Electrical, Communications, And Building Services Spaces Throughout. A Mezzanine Will Be Provided For The Heating, Ventilation, And Cooling (hvac) Air-handling Units And For Mezzanine Access To One Of The Test Areas. Several Of The Areas Will Require High-bay Construction For Either Overhead Bridge Cranes, Storage Racks, Or To House Tall Vertical Elements. Several Of The Spaces Will Require Additional Special Requirements For Operational Needs. Some Of These Will Be Raised Access Flooring Systems For Heavy Electrical And Communication Infrastructure And Acoustical Treatments For Loud Operation Uses Or For Controlled Communication. this Site And Building Have Heightened Flood And Wind Control Due To Its Location. These Features Will Require A Raised Finish Floor Elevation To Lift The Building Above The Flood And Ocean Surge Plane Along With Increased Structural Design Requirements For High Wind Gusts During A Hurricane Event. Increased Environmental Care Will Be Required For This Sensitive Site. The Site Is Undeveloped And Has The Potential To Support Habitats For Endangered Animal And Bird Species. In Particular, The Beach Mouse, Gopher Tortoise, Scrub Jay, And Tri-colored Bat. This Project Anticipates Relocating Existing Scrub Jay Habitat To Another Location. There May Also Be Some Cultural Sensitivities. Additional Investigation Is Needed To Confirm Any Presence Of Historical Items And Their Possible Impact On The Development Of The Facility. The Design Will Be Developed To Meet A 50-year Building Life Cycle. This Will Impact The Performance Level Of Building Systems And Materials Selected. There Will Be Several Large Pieces Of Equipment Sensitive To Vibration That Will Require Isolated Floor Slabs To Meet The Weight And Seismic Requirements. The Use Of Air Pallets Will Also Require Several Of These Isolated Slabs To Have A Low Tolerance For Flatness (i.e., Be Super Flat). There Will Be Several Built-in Cranes In The Facility That Will Require An Increased Structural Design Load Or Separate Steel Structure And Concrete Footings. There Will Be Two Special Commissioning Requirements For The Etf: Cybersecurity And Security. This Project Will Follow The Ufc 4-010-01 Minimum Antiterrorism Standards For Buildings, Ufc 4-010-06 Cybersecurity Of Facility Related Control Systems, And Ufc 4-010-05 Sensitive Compartmented Information Facilities Planning, Design And Construction. the Project Will Be Design-bid-build, North American Industry Classification System (naics) Code Is 236220 – Commercial And Institutional Building Construction With The Annual Size Standard Of $45 Million. Project Magnitude Is Between $100,000,000 And $250,000,000. The General Period Of Performance Is Anticipated To Be Approximately 851 Calendar Days. a Pla Is Defined As A Pre-hire Collective Bargaining Agreement With One Or More Labor Organizations That Establishes The Terms And Conditions Of Employment For A Specific Construction Project And Is An Agreement As Described In 29 U.s.c. 158 (f). Effective January 22, 2024, Final Rule (far Case 2022-003), Implements Executive Order (e.o.) 14063, Use Of Plas For Federal Construction Projects, Which Requires The Use Of Plas In Large-scale (defined As $35 Million Or More) Federal Construction Projects Within The United States. Contractors And Subcontractors Working On Large-scale Construction Projects Must Negotiate Or Become Party To A Pla With One Or More Labor Organizations Unless An Exception Is Granted. This Requirement Applies To New Solicitations, Including Task Or Delivery Orders, Issued On Or After January 22, 2024. the Government Is Requesting Information To Determine If The Use Of Project Labor Agreements Will (1) Advance The Federal Government's Interest In Achieving Economy And Efficiency In Federal Procurement; (2) Promote Adequate Competition At A Fair And Reasonable Price; And (3) Be Consistent With Statutes, Regulations, Laws, Etc. The Government Is Seeking Information From Both Unionized And Non-unionized Contractors, As Well As Contractors Familiar With The Federal Marketplace As Well As New Entrants, That May Be Interested In Participating In Competition For This Procurement. Reference Is Made To: Far Subpart 22.5 Use Of Project Labor Agreements For Federal Construction Projects; Provision, Far 52.222-33 Notice Of Requirement For Project Labor Agreement; And To Clause, Far 52.222-34 Project Labor Agreement. in Consideration Of The Above Factors, And Any Others Which May Be Deemed Appropriate, The Construction Community Is Invited To Comment On The Use Of A Pla For This Proposed Project Using The Attached Questionnaire. this Is Not An Announcement Of The Availability Of A Solicitation Nor Is It A Means Of Generating A Plan Holder’s List. After Review Of The Responses To This Special Notice, The Government Intends To Make A Determination To Pursue An Exception To The Mandatory Use Of A Pla Or Not. The Government Will Not Contact The Responders For Clarification Of Information Provided. This Survey Is For Planning Purposes Only And Shall Not Be Construed As A Request For Proposal Or As An Obligation On The Part Of The Government. The Government Does Not Intend To Award A Contract On The Basis Of This Market Survey Or Otherwise Pay For The Requested Information. The Government Will Not Provide A Debriefing On The Results Of This Survey. All Information Will Be Held In A Confidential Manner And Will Only Be Used For The Purposes Intended. responses Shall Be Submitted On The Attached Questionnaire Via Email To Sheila Borges, Sheila.i.borges.civ@us.navy.mil And Lindsay Betteridge, Lindsay.e.betteridge.civ@us.navy.mil. No Later Than 2:00 Pm Et On April 1, 2024.

Details: Sources Sought Notice sources Sought Notice title: Tf - Fca - Remove And Replace End-of-life Heating, Ventilation And Air Conditioning Infrastructure Building 1 solicitation Number: 36c25525q0014 contracting Office: Network Contracting Office 15 contracting Office Location: 3450 S 4th Street Traffic Way, Leavenworth, Kansas description type Of Notice: Sources Sought posted Date: 10/07/2024 response Date: 10/25/2024 At 2:00 Pm Central Time set Aside: Service-disabled Veteran Owned Small Business classification Code: Z2da - Repair Or Alteration Of Hospitals And Infirmaries naics Code: 236220 Commercial And Institutional Building Construction synopsis: please Note That This Is Not A Request For Quotes Or Proposals, The Government Is Seeking Information For Market Research Purposes Only. The Government May Or May Not Issue Solicitation Documents. The Department Of Veterans Affairs Network Contracting Office (nco) 15, Is Conducting A Market Survey For Qualified: Service-disabled Veteran Owned Small Businesses (sdvosb), Capable Of Providing The Required Services Outlined Below For The John J. Pershing Va Medical Center, Poplar Bluff, Missouri. The Applicable Naics Code Is 236220 Commercial And Institutional Building Construction And The Size Standard Is $45.0 Million. Responses To This Notice Must Be Submitted Via E-mail And Received No Later Than October 25, 2024, At 2:00 Pm Central Time. No Telephone Inquiries Will Be Accepted Or Returned. Additional Information About This Project Will Be Issued On The Federal Contract Opportunities Website Https://www.sam.gov Once Available. period Of Performance For All Work Is 900 Calendar Days. in Accordance With Vaar 836.204, The Estimated Cost Magnitude Is Between $10,000,000 And $20,000,000. prospective Sdvosb Firms Are Reminded That In Accordance With Federal Acquisition Regulation (far) 52.219-14(e)(3), The Contractor Agrees It Will Not Pay More Than 85 Percent Of The Amount Paid By The Government For Contract Performance, Excluding The Cost Of Materials, To Subcontractors That Are Not Similarly Situated Entities. Any Work That A Similarly Situated Entity Further Subcontracts Will Count Towards The Prime Contractor's 85 Percent Subcontract Amount That Cannot Be Exceeded. General Scope Of Work: project 657a4-21-800, Tf - Fca - Remove And Replace End-of-life Heating, Ventilation And Air Conditioning Infrastructure Building 1, At The John J. Pershing Va Medical Center, 1500 North Westwood Blvd Poplar Bluff, Missouri 63901. contractor Shall Remove And Replace Laboratory Service Hvac System And Remove And Replace Ac 9 (ground Floor, Dental, Admin Suite, Laundry). contractor Shall Furnish All The Proper Skilled Labor, Equipment, Materials, Supplies, And Supervision For Performance Of All Work. Contractor Will Perform Site Investigations To Fully Inform Themselves Of The Conditions And Limitations Applied To The Work. end Of Scope Of Work interested Firms Must Be Registered In Https://sam.gov With Naics Code 236220 And Qualified As A Service-disabled Veteran Owned Small Business Under Naics Code 236220. Qualified Service-disabled Veteran Owned Small Businesses Are Encouraged To Respond And Required To Be Registered In With The Small Business Administration (sba) Registry Https://veterans.certify.sba.gov On Or Before The Response Date. if Interested In This Opportunity, Please Provide Capability Statement Via Email. The Capability Statement Is Designed To Inform The Department Of Veteran Affairs Of Any Prospective Construction Contractors' Project Execution Capabilities. The Submission Is Limited To 10 Pages Which Shall Include The Following Information: 1) Offeror's Name, Address, Point Of Contact, Phone Number, E-mail Address, And Unique Entity Id. 2) Offeror's Interest In Bidding On The Solicitation When It Is Issued. 3) Offeror's Capability To Perform A Contract Of This Magnitude And Complexity And Comparable Work Performed Within The Past 5 Years - Brief Description Of The Project, Customer Name, Timeliness Of Performance, Customer Satisfaction, And Dollar Value Of The Project - Provide At Least 1, But No More Than 3 Completed Construction Examples. 4) Offeror's Cve Certification As A Veteran Owned Business. 5) Please Provide Socio-economic Status For Naics Code 236220, Commercial And Institutional Building Construction And Provide Percentage Of Self-performed Labor Your Company Can Perform For This Type Of Project. 6) Offeror's Joint Venture Information If Applicable - Existing And Potential. 7) Offeror's Bonding Capability In The Form Of A Letter From Surety Providing Bonding Level Per Contract And Aggregate. 8) Letter From Insurance Company Identifying Contractors Insurance Experience Modification Rate (emr). no Basis For Claim Against The Government Shall Arise As A Result Of A Response To This Sources Sought Or Government Use Of Any Information Provided. The Government Will Not Pay For Information Or Comments Provided And Will Not Recognize Any Costs Associated With Submission Of Comments. There Is No Guarantee, Expressed Or Implicit, That Market Research For This Acquisition Will Result In A Particular Set-aside, Or Any Other Guarantee Of Award Or Acquisition Strategy. responses Must Be Received By 2:00 Pm Central On October 25, 2024, Via E-mail To The Contract Specialist At Lucia.cowsert@va.gov And The Contracting Officer At Arnold.payne@va.gov. Please Reference "sources Sought: Project 657a4-21-800, Tf - Fca - Remove And Replace End-of-life Heating, Ventilation And Air Conditioning Infrastructure Building 1 " In The Subject Line And Cover Sheet. Respondents Will Not Be Contacted Regarding Their Submission Or Information Gathered As A Result Of This Sources Sought Notice. Interested Firms Shall Be Required To Respond To Additional Announcements Separately From This Announcement Without Further Notice From The Government When Posted To The Contract Opportunities Website At Https://sam.gov. The Contract Opportunities Website Is The Only Official Site To Obtain These Documents. contracting Office Address: department Of Veterans Affairs; Network 15 Contracting Office; 3450 S. 4th Street, Leavenworth, Ks 66048 point Of Contact(s): arnold Payne, Contracting Officer, E-mail Address: Arnold.payne@va.gov lucia Cowsert, Contract Specialist, E-mail Address: Lucia.cowsert@va.gov

Details: Sources Sought for w912pp24r0024 small Arms Storage Facility, Kirtland Air Force Base, Bernalillo County, New Mexico this Is A Sources Sought Announcement; A Market Survey For Information Only, To Be Used For Preliminary Planning Purposes.  This Is Not A Solicitation For Proposals And No Contract Will Be Awarded From This Sources Sought.  No Reimbursement Will Be Made For Any Costs Associated With Providing Information In Response To This Notice Or Any Follow Up Information Requests.  the U.s. Army Corps Of Engineers (usace) – Albuquerque District Has Been Tasked To Solicit For And Award Small Arms Storage Facility At Kirtland Air Force Base (kafb).  The Proposed Project Will Be A Competitive, Firm-fixed-price, Design-bid-build Contract Procured In Accordance With Far 15, Negotiated Procurement Using A Lowest Priced Technically Acceptable (lpta) Best Value Process, However, The Results And Analysis Of The Market Research Will Finalize The Determination Of Procurement Method.  The Type Of Set-aside Decision To Be Issued Will Depend Upon The Responses To This Synopsis. purpose Of Sources Sought the Purpose Of This Synopsis Is To Gain Knowledge Of Interest, Capabilities And Qualifications Of Various Members Of Industry, To Include The Small Business Community: Small Business, Section 8(a), Historically Underutilized Business Zones (hub-zone), Woman-owned Small Business (wosb), Economically Disadvantaged Woman-owned Small Business (edwosb) And Service-disabled Veteran-owned Small Business (sdvosb). The Government Must Ensure There Is Adequate Competition Among The Potential Pool Of Responsible Contractors.  project Description & Experience Requirements the Government Is Seeking Qualified, Experienced Sources Capable Of Constructing A Pre-engineered Metal Building (approximately 5,000 Sf) Capable Of Storing Small Quantities Of Explosives Hazard Class 1.3 And 1.4 At The 377th Maintenance Squadron (377mxs) Munitions Storage Area (msa) At Kirtland Afb, Albuquerque, Nm.  Facility Will Include Power, Lighting, Lightning Protection, Hvac, Concrete Driveway And 1600 Ft Asphalt Access Road With Associated Grading And Drainage Features.  Project Will Have A Perimeter Security Fence And  Will Comply With Department Of Defense Antiterrorism/force Protection Requirements Per Unified Facilities Criteria 4-010-01. . in Accordance With Far 36/dfars 236, The Estimated Construction Price Range For This Project Is: Between $1,000,000 And $5,000,000. the Minimum/special Capabilities Required For This Project Are: --prime Contractor Experience With Procuring The Professional Design And Installation Of Pre-engineered Metal Buildings. --prime Contractor Experience With Construction Of Asphalt Roadways On Military Installations Or Other Secure Sites With Controlled Access. --prime Contractor Experience With Design-bid-build Projects Performed For The Government And Processes Such As Submitting Safety Plans, Environmental Protection Plans, Construction Schedules, And Quality Control Plans For Approval Prior To Construction. Contractor Is Reminded That Contractor’s Qc Manager Shall Be A Graduate Engineer Or A Graduate Of Construction Mgmt. With A Minimum 5yrs Experience In Heavy Civil Construction) --prime Contractor Experience With The Security Requirements Imposed On Construction Contractors And Associated Personnel Working On Military Installations the North American Industry Classification System Code For This Procurement Is 236220 Which Has A Small Business Size Standard Of $45 Million.  small Businesses Are Reminded Under Far 52.219-14 Dev, Limitations On Subcontracting That They Must Perform At Least 15% Of The Cost Of The Contract, Not Including The Cost Of Materials, With Their Own Employees, Or Similarly Situated Entities For General Construction-type Procurement. prior Government Contract Work Is Not Required For Submitting A Response Under This Sources Sought Synopsis. anticipated Solicitation Issuance Date For The Solicitation Is On Or About 1 August 2024. The Official Synopsis Citing The Solicitation Number Will Be Issued On Sam.gov Inviting Firms To Register Electronically To Receive A Copy Of The Solicitation When It Is Issued. instructions On Submission Of Responses To This Sources Sought firm’s Response To This Sources Sought Shall Be Limited To 10 Pages And Shall Include The Following Information: 1.  Firm’s Name, Address, Point Of Contact, Phone Number, E-mail Address, Cage, Duns, And Website (if Applicable). 2.  Firm’s Business Size – Lb, Sb, 8(a), Hubzone, Sdvosb, Ewosb, 3.  Provide A List Of At Least Three Examples Of Same Or Similar Work Performed By Your Firm In The Past 5 Years Of Same Or Similar Size, Scope, Magnitude And Complexity As This Project. a. Provide A Brief Description Of The Project, Contract Type, Contract Number, Technical Description, Dollar Value Of The Project, Period Of Performance, Customer Name Along With The Current Point Of Contact, Telephone Number And Email, Whether Your Firm Worked As A Prime Or Subcontractor, As Part Of A Teaming Partner, Jv Partner, Or Mentor/protégé Program. If Your Firm Was A Subcontractor Indicate Your Role In The Project And The Dollar Value Of The Portion Performed. 4. Firm’s Experience With The Minimum Capabilities Listed In This Sources Sought Notice. 5. Do You Intend To Have Partners Represented In The Response? This Includes, But Is Not Limited To, Existing Joint Venture Partners, Potential Teaming Partners, Prime Contractor (if Responder Is Potential Subcontractor), Or Subcontractors (if Responder Is Potential Prime Contractor). If Yes, Please Describe The Partner And The Expected Relationship With Respect To This Activity. 6. Firm’s Bonding Capability (construction Bonding Level Per Contract And Aggregate Construction Bonding Level, Both Expressed In Dollars). Indicate Whether The Firm Can Bond To The Estimated Construction Price Range Of This Project. all Prospective Offerors And Their Subcontractors Must Be Registered In The System For Award Management (sam - Www.sam.gov).  Copies Of The Solicitation And The Solicited Plans And Specifications Will Be Made Available For Inspection Without Charge After The Solicitation Is Released. interested Firm’s Shall Respond To This Sources Sought Synopsis No Later Than 8 Feb 2024, 2:00pm Mst.  All Interested Firms Must Be Registered In Sam To Be Eligible For Award Of Government Contracts.  email Your Response To Karen Irving At Karen.k.irving@usace.army.mil.  firms Responding To This Sources Sought Notice Who Fail To Provide All Of The Required Information Requested Will Not Be Used To Assist The Government In The Acquisition Decision, Which Is The Intent Of This Sources Sought Notice. if Inadequate Responses Are Received, This Solicitation May Be Issued For Full And Open Competition.

Details: A Market Survey Is Being Conducted To Determine If There Are A Reasonable Number Of Interested Small Business Concerns To Set This Future Project Aside For Them. If Your Firm Is A Small Business, Certified Hubzone, 8a, Woman-owned Small Business Or Service Disabled Veteran Owned Small Business And You Are Interested In This Project Please Respond Appropriately. project Location: Rock Island, Il project Description: Design-bid-build Five Separate Private Offices And One Vtc-capable Conference/team Room Space Within Room N315 In Building104, 3rd Floor, Northwest Corner. Assess Current Condition Of The Space To Be Renovated And The Supporting Building Systems. Interior Space Is Approximately 1,600 Sf. Renovation To Match As Closely As Possible, The Design And Finishes Of The Surrounding Oc/t Academy Space To Include, But Not Limited To, New Steel Stud & Drywall System, Insulation, 2x2 Suspended Ceiling System, Flooring, Carpet Squares, Lighting, Power, Outlets, Nipr Ports, Cabling, Phone And Av Ports Connections, Doors & Frames, Replacing Existing [18 Small] Windows, Fire Alarm/mns, Sprinkler Drops, Vtc System Infrastructure. Renovate, Revise, Reuse Where Possible Existing Hvac & Other Building Systems. Procure And Install Furniture. contract Duration Is Estimated At 545 Calendar Days. The Estimated Cost Range Is Between $1,000,000 And $5,000,000. Naics Code Is 236220. All Interested Small Businesses, Certified Hubzone, 8a, Woman-owned Small Businesses Or Service-disabled Veteran Owned Small Business Contractors Should Respond To This Survey By Email On 26 February 2024 By 4pm Eastern Time. responses Should Include: 1. Identification And Verification Of The Company’s Small Business Status. 2. Contractor’s Unique Identifier Number And Cage Code(s). 3. Documentation From The Firm’s Bonding Company Showing Current Single And Aggregate Performance And Payment Bond Limits. 4. Descriptions Of Experience – Interested Construction Firms Must Provide No More Than Three (3) Example Projects With Either Greater Than 95 Percent Completion Or Projects Completed In The Past Five (5) Years Where The Interested Firm Served As The Prime Contractor. Each Project Must Include The Name, Title, Project Role, E-mail Address, And Telephone Number Of At Least One Reference. References May Be Used To Verify Project Size, Scope, Dollar Value, Percentages, And Quality Of Performance. Example Projects Must Be Of Similar Size And Scope. a. Projects Similar In Scope To This Project Included: a. Renovation Of Office Or Administrative Space To Include Installation Of Electrical Wiring And Interconnection With Existing Mechanical Systems. b. Projects Similar In Size To This Project Include: a. Renovation Of Office Space Of 500sf Or Greater based On Definitions Above, For Each Project Submitted Include: current Percentage Of Construction Complete And The Date When It Was Or Will Be Completed. size Of The Project scope Of The Project the Dollar Value Of The Construction Contract the Percentage Of Work That Was Self-performed As Project And/or Construction Management Services Or Physical Construction Type Work. Must Be At Least 15% Self-performed. identify The Number Of Subcontractors By Construction Trade Utilized For Each Project. small Businesses Are Reminded Under Far 52.219-14, Limitations On Subcontracting; They Must Perform At Least 15% Of The Cost Of The Contract, Not Including The Cost Of Materials, With The Firm’s Own Employees For General Construction-type Procurement. Include The Percentage Of Work That Will Be Self-performed On This Project, And How It Will Be Accomplished. note: Total Submittal Package Shall Be No Longer Than 8 Pages. Please Only Include A Narrative Of The Requested Information; Additional Information Will Not Be Reviewed. email Responses And Any Questions To Morgan Greenwell At Morgan.l.greenwell@usace.army.mil. This Is Not A Request For Proposal And Does Not Constitute Any Commitment By The Government. Responses To This Sources Sought Notice Will Be Used By The Government To Make Appropriate Acquisition Decisions. All Interested Sources Must Respond To Future Solicitation Announcements Separately For Responses To This Market Survey. notice: The Following Information Is Provided For Situational Awareness And Is Not Required To Respond To This Sources Sought. all Contractors Must Be Registered In The System For Award Management (www.sam.gov) Prior To Award Of A Contract. All Proposed Contractors Are Highly Encouraged To Review Far Clause 52.232-33 Payments By Electronic Funds Transfer – System For Award Management, Which Indicates “all Payments By The Government Under This Contract Shall Be Made By Electronic Funds Transfer (eft).” Those Not Currently Registered Can Obtain Registration By Going To The Website Http://www.sam.gov. The Process Can Usually Be Completed From 24 To 48 Hours After Submission. Contractors Will Need To Obtain A Unique Entity Identifier (formerly Duns Number) For Processing Their Registration. If You Do Not Already Have A Unique Entity Identifier, One Can Be Obtained From Http://www.sam.gov. Refer To Www.sam.gov For Information Formerly Found In Ccr, Epls, Orca And Fedreg. please Begin The Registration Process Immediately In Order To Avoid Delay Of The Contract Award Should Your Firm Be Selected. alert: You Must Submit A Notarized Letter Appointing The Authorized Entity Administrator Before Your Registration Will Be Activated. This Requirement Now Applies To Both New And Existing Entities. Effective 29 April 2018, The Notarized Letter Process Is Now Mandatory On All Current Registrants At Sam Who Have A Requirement To Update Data On Their Sam Record. The Notarized Letter Is Mandatory And Is Required Before The Gsa Federal Service Desk (fsd) Will Activate The Entity's Registration. effective 29 June 2018, Vendors Creating Or Updating Their Registration Can Have Their Registration Activated Prior To The Approval Of The Required Notarized Letter. However, The Signed Copy Of The Notarized Letter Must Be Sent To The Gsa Federal Service Desk (fsd) Within 30 Days Of Activation Or The Vendor Risks No Longer Being Active In Sam. vendors Can Check Whether An Account Is Active By Performing A Query By Their Cage Or Unique Entity Identifier (known As Duns). The New Registration Process May Now Take Several Weeks, So Vendors Are Highly Encouraged To Begin Registering As Soon As Possible To Avoid Any Possible Delays In Future Contract Awards. Remember, There Is No Cost To Use Sam. to Find Out Additional Information About The Changes Of The Sam Registration Process, Contractors Should Visit The Frequently Asked Questions (faq) Link Located At The Top Of The Sam Homepage (www.sam.gov).

Details: Pre-solicitation Synopsis For Solicitation No: Tbd single Award Indefinite Delivery Indefinite Quantity (idiq) Contract For Repair And Alteration (r&a) / General Construction Services In Richmond, Va And Surrounding Areas the General Services Administration (gsa) Mid-atlantic Region Intends To Solicit Proposals For A Single Award Indefinite Delivery Indefinite Quantity (idiq) Contract For The Provision Of Repair And Alteration Construction Services With Design-build Capabilities At Government Owned And Leased Facilities Located In Richmond, Va And Surrounding Areas. the Government Intends To Award One (1) Contract Under This Solicitation. This Procurement Will Be A Total Small Business Set-aside For 8(a) Small-businesses In Accordance With Far 19.8. general Description Of Scope Of Services the General Contractor (gc) Shall Supervise, Administer, And Perform All Construction Activities Required To Complete Task Order Projects Under The Idiq. Construction Activities For The Anticipated Solicitation Include But Are Not Limited To Commercial Office Construction And/or Renovations/repairs, Mep (mechanical/electrical/plumbing) Repairs/modifications/replacement, Fire Sprinkler Systems Repairs/modification/replacement, Sitework, Exterior Construction Repair And Alterations (including Facades And Roofs), Demolition (including Abatement Of Hazardous Materials), Elevator Modernizations And Any Other Construction Activities The Government May Require. the Scope Of This Proposed Procurement Includes The Provision Of The Following Services: construction Services, Including, But Not Limited To: General Office Renovation; Interior Construction; Exterior Construction Repair; General Repair And Alteration Work; Installation Of New And The Alteration Of Existing Power Panels; Carpet And Carpet Tile Replacement; Painting; Hvac Ductwork Modification; Modification Of Existing Building Fire Sprinkler Systems; Plastering And Plaster Repair Work; Sidewalk Repairs/replacement; Asphalt/concrete Paving; Ability To Provide Asbestos Assessments And Any Environmental Remediation Work Such As Mold Remediation, Asbestos Abatement, Or Lead Abatement; alteration Services, Including, But Not Limited To: Electrical, Carpentry, Masonry, Plumbing, Mechanical, Architectural, Landscaping, Storm Drainage, Exterior Restoration, Waterproofing, Re-pointing, Cleaning, Sealing; Roofing Involving Installation, Repair And Alteration, And Removal; Paving Relevant To Property And Roads Owned, Leased Or Otherwise Under The Control Of Gsa, Or Other Authorized Federal Agencies; And Other Related Work. design Work Incidental To Construction As Well As Design/build Work Are Included. the Gc May Be Required To Utilize The Following Deliver Methods To Deliver Projects For The Gsa: 1. Design/bid/build (dbb) Traditional 2. Design/build (d/b) naics Code the North American Industry Classification System (naics) Code For This Procurement Is 236220, “commercial And Institutional Building Construction”. The Small Business Size Standard Is $45 Million. contract Value the Anticipated Maximum Ordering Limit (mol) For This Contract Vehicle Is $5,000,000.00 For The Entire Duration Of The Contract. The Cumulative Total For All Task Orders Awarded Against This Single Award Idiq Shall Not Exceed $5,000,000.00. the Anticipated Ordering Limits Are Expected To Be Between $2,000.00 And The Simplified Acquisition Threshold Defined In Far 2.101 (currently $250,000.00); However, There May Be Individual Orders With Higher Costs Placed Against This Contract. The Typical Task Order Is Expected To Be Between $6,000.00 And $60,000.00. ordering Periods the Period Of Performance Will Be A One (1) Base Year With Four (4) One (1) Year Options. base Period: October 1, 2024 – September 30, 2025 option Period 1: October 1, 2025 – September 30, 2026 option Period 2: October 1, 2026 – September 30, 2027 option Period 3: October 1, 2027 – September 30, 2028 option Period 4: October 1, 2028 – September 30, 2029 location Of Services the Geographic Location For This Requirement Is Richmond, Va, And Surrounding Areas, To Include: The City Of Richmond, City Of Chesapeake, City Of Hampton, City Of Newport News, City Of Norfolk, City Of Portsmouth, City Of Virginia Beach, City Of Suffolk, City Of Charlottesville, Henrico County, Albemarle County, Chesterfield County, Hanover County, Gloucester County, And Sussex County. source Selection Approach the Approach To Source Selection For This Procurement Will Be Pursuant To The Best Value Tradeoff Concept As Identified In Far Part 15.101-1 And Far Part 15.3. It Is The Government’s Intention To Award A Contract To The Offeror Whose Proposal Conform To The Rfp Requirements And Are Considered Most Advantageous To The Government, Price And Technical Factors Considered. Competitive Proposals Will Be Evaluated And Assessed; Based On The Factors Specified In This Solicitation. For This Solicitation, The Combined Weight Of The Technical Evaluation Factors Are More Important Than Price (far 15.101-1 – Trade Offs.) the Government Intends To Evaluate Proposals And Award A Contract Without Discussions With Offerors (other Than Exchanges Conducted For The Purpose Of Minor Clarifications). However, The Government Reserves The Right To Conduct Discussions If Later Determined By The Contracting Officer To Be Necessary. Therefore, Each Initial Offer Should Contain The Offeror's Best Terms From A Price And Technical Standpoint. the Technical (non-price) Factors Are Listed In Descending Order Of Importance: prior Experience On Relevant Projects approach & Management Plan past Performance On Relevant Projects the Award Will Be Made To The Firm That Represents The Best Value To The Government. In Accordance With Far 15.404, Price Analysis Will Be Used To Determine Price Reasonableness And The Offeror’s Understanding Of The Work Requirements/line Items (i.e. Unreasonably High Prices, As Compared To Other Offers Received And The Government Estimate, May Indicate The Offeror Does Not Fully Understand The Requirements/line Items Of The Rfp) And The Ability To Perform The Contract. contract Pricing this Contract Will Include Line Item Pricing Based On The 2024 Facilities Construction Costs Book (rsmeans). Offerors Will Be Required To Submit A Bid Coefficient (factor) As Part Of Their Price Proposal. The Bid Coefficient, In Conjunction With The Line Item Pricing, Will Be Used To Establish Proposed Pricing For Individual Requirements At The Task Order Level. procurement Schedule (will Be Updated At Time Of Solicitation) issue Request For Proposal / Solicitation – May 2, 2024 pre-proposal Conference – May 15, 2024, Time Tbd proposal Due Date – June 3, 2024, 2:00 Pm Est award Date – On Or About August 30, 2024 ordering Period Start Date – On Or About October 1, 2024

Details: Synopsis: Introduction: In Accordance With Federal Acquisition Regulation (far) 10.002(b)(2), This Sources Sought Notice Is For Market Research And Information Purposes Only At This Time And Shall Not Be Construed As A Solicitation Or As An Obligation On The Part Of The Department Of Veterans Affairs (va). The Department Of Veterans Affairs, Veterans Health Administration (vha), Program Contracting Activity Central (pcac) Is Conducting A Market Survey And Is Seeking Potential Sources For The Expand And Renovate Space For New Mri Construction Project Located At 830 Chalkstone Avenue, Providence, Ri 02908. Project Description: Contractor Shall Completely Prepare The Site For Building Operations, Including Demolition And Removal Of Existing Structures/equipment, And Furnish Labor And Materials And Perform Work For Expand And Renovate Space For New Mri Construction Project At The Veterans Affairs Medical Center, Providence, Rhode Island As Required By Drawings And Specifications And Per The Description Herein. This Project Shall Include, But Not Be Limited To, General Construction, Alterations, Civil Site Work, Finishes, Hvac, Electrical Work, Plumbing, Fire Alarm And Suppression, Security, And Other Items As Contained Within The Construction Documents. Procurement Information: The Proposed Project Will Be A Competitive, Firm-fixed-price Contract Utilizing The Design-bid-build Approach (final Specifications And Drawings Will Be Provided). The Anticipated Solicitation Will Be Issued Either As A Request For Proposal (rfp) In Accordance With Far Part 15, Considering Technical And Price Factors Or As An Invitation For Bid (ifb) In Accordance With Far Part 14, Considering Price Only. Please Indicate Your Preference For Solicitation. The Results And Analysis Of The Market Research Will Finalize The Determination Of The Procurement Method. The Type Of Socio-economic Set-aside, If Any, Will Depend Upon The Responses To This Notice And Any Other Information Gathered During The Market Research Process. This Project Is Planned For Advertising In July Or August 2024. In Accordance With Vaar 836.204, The Magnitude Of Construction Is Between $10,000,000 And $20,000,000. The North American Industry Classification System (naics) Code 236220 (size Standard $45.0 Million) Applies To This Procurement. The Duration Of The Project Is Currently Estimated At 600 Calendar Days From The Issuance Of A Notice To Proceed. The Services For This Project Will Include Providing All Construction Related Services Such As: Providing Labor, Materials And Equipment Required To Complete The Project As Per Contract Documents Prepared By An Independent Architect-engineer Firm. Capability Statement: Respondents Shall Provide A General Capabilities Statement To Include The Following Information: Section 1: Provide Company Name, Duns Number And Unique Entity Identifier (uei), Company Address, Point-of-contact Name, Phone Number And Email. Section 2: Provide Company Business Size Based On Naics Code 236220. Also, Provide Business Type (i.e., Large Business, Small Business, Service-disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-owned Small Business, Hub Zone Small Business, Etc.). Section 3: Provide A Statement Of Interest In The Project. Section 4: Provide The Prime Contractor S Available Bonding Capacity In The Form Of A Letter Of Intent From Your Bonding Company With This Submission. *please Ensure That The Individual Bonding Capacity Is In Line With The Vaar Magnitude Of Construction Listed Above. Section 5: Provide The Type Of Work Your Company Has Performed In The Past In Support Of The Same Or Similar Requirement. This Section Is Important As It Will Help To Determine The Type Of Socio-economic Set-aside, If Any. Please Provide The Following In Your Response: No More Than Three (3) Contracts That Your Company Has Performed Within The Last Seven (7) Years That Are Of Comparable Size, Complexity, And Scope To This Requirement. Include The Project Name, Project Owner And Contact Information As This Person May Be Contacted For Further Information, Project Scope, Project Size (example: Square Footage), Building Use (example: Medical Facility, Office Building, Etc.), Project Dollar Value, Start And Completion Dates. Provide Specific Examples That Relate Aspects Of Previous Projects To The Proposed Project. Describe Specific Technical Skills And Key Personnel Your Company Possess To Perform The Requirements Described Under Description Of Work. Describe Your Self-performed** Effort (as Either A Prime Or Subcontractor). Describe Self-performed Work In Terms Of Dollar Value And Description. **self-performed Means Work Performed By The Offeror Themselves, Not Work Performed By Another Company For Them For Any Of The Project Examples Provided. It Is Requested That Interested Contractors Submit A Response (electronic Submission) Of No More Than Eight (8) Single Sided Pages, Single-spaced, 12-point Font Minimum That Addresses The Above Information. This Response Must Be Submitted As A Single Application-generated (not Scanned) Pdf Document That Is Less Than Or Equal To 4mb In Size. Please Note That Hard Copies Will Not Be Accepted. Please Also Include A Cover Page, Which Includes, At A Minimum: The Company S Name, Address, Dun & Bradstreet Number, Unique Entity Identifier (if Available), Socio-economic Status, Point-of-contact Name, Phone Number, And E-mail Address. Responses Must Include The Sources Sought Number And Project Title In The Subject Line Of Their E-mail Response. Submissions (responses) Shall Be Submitted Via Email To The Primary And Secondary Points Of Contact Listed Below By Xxx. No Phone Calls Will Be Accepted. The Capabilities Statement Submitted In Response To This Sources Sought Shall Not Be Considered To Be A Bid Or Proposal. This Notice Is For Information And Planning Purposes Only And Is Neither To Be Construed As A Commitment By The Government Nor Will The Government Pay For Information Solicited. No Evaluation Letters And/or Results Will Be Issued To The Respondents. After Completing Its Analyses, The Government Will Determine Whether To Limit Competition Among The Small Business Categories Listed Above Or Proceed With Full And Open Competition As Other Than Small Business. At This Time No Solicitation Exists; Therefore, Please Do Not Request A Copy Of The Solicitation. If A Solicitation Is Released It Will Be Synopsized In Contract Opportunities At Https://sam.gov/. It Is The Potential Offeror's Responsibility To Monitor This Site For The Release Of Any Solicitation Or Synopsis. Contracting Office Address: Vha Program Contracting Activity Central (vha-pcac) 6100 Oak Tree Blvd. Suite 490 Independence, Oh 44131 Primary Point Of Contact: Kathryn Allison Contract Specialist Kathryn.allison@va.gov Secondary Point Of Contact: Dean W. Flanders Contracting Officer Dean.flanders@va.gov