Water Resources Department Tender

The required prior work experience for the bidder includes specifying the number of years they have been in business, which encompasses experience as a prime contractor, in joint ventures, and as a sub-contractor, both domestically and internationally. Additionally, bidders must provide information on their history of completing projects, including instances of failure to complete work, arbitration, and penalties for delay. For key personnel, specific experience requirements are mentioned: Project Managers or Project Engineers need 10 years of experience in similar work, while Site Engineers and Technical Supervisors require 5 years of experience in similar work. Regarding the value and percentage of similar works completed, bidders are required to submit a statement showing quantities of work executed during the last five years. Minimum quantities for certain items of work are specified, including 14550 RMT of field channel, 700 Cum of concrete, and 30 MT of HYSD, which must have been executed in any one financial year during the last five years. Bidders must also submit a turnover for the last five years and bid capacity, both in terms of Rs. Lakh, as per specific forms. However, specific percentages of similar works completed are not mentioned, except for the requirement to mention participation percentages in joint ventures.