Manpower Tenders

Details: Description Republic Of The Philippines Cordillera Administrative Region Provincial Local Government Unit Of Ifugao Bids And Awards Committee 3rd Floor Peo Bldg., Capitol Compound Lagawe, Ifugao Email Ad.: Bacgoodsifugao13@gmail.com Publication No. 01-2025-c (first Publication) Request For Expression Of Interest For Hydro Energy Development: Pre Fs 1. The Plgu-ifugao, Through The Supplemental Budget No. 2 And Supplemental Budget No. 5 For The Contract Approved By The Sanggunian Panlalawigan For Cy 2024 Intends To Apply The Sum Of Four Million Five Hundred Thousand Pesos (php 4,500,000.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For Publication No. 01-2025-c (first Publication). Bids Received In Excess Of The Abc Shall Be Automatically Rejected At The Opening Of The Financial Proposals. 2. The Plgu-ifugao Now Calls For The Submission Of Eligibility Documents For The Hydro Energy Development: Pre Fs Project Particularly The Pre-application And Pre-feasibility Study Of The Proposed Alimit Hydro Power Plant. Eligibility Documents Of Interested Consultants Must Be Duly Received By The Bac Secretariat On Or Before 1:00 P.m. Basing On The Bac Office - Wall Clock Of January 30, 2025 At The Bids And Awards Committee Office, 3rd Floor, Peo Bldg., Capitol, Lagawe, Ifugao. Opening Of Eligibility Documents Will Be On 2:00 P.m. Of January 30, 2025 At The Address Stated Above. Applications For Eligibility Will Be Evaluated Based On A Non-discretionary “pass/fail” Criterion. 3. Interested Bidders May Obtain Further Information From The Bids And Awards Committee (bac) Of The Provincial Government Of Ifugao And Inspect The Bidding Documents At The Address Given Below During 8:00 O’clock Am To 5:00 O’clock Pm. 4. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 23, 2025 To February 18, 2025 From The Address Below And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of Five Thousand Pesos Only (php 5,000.00). 5. The Bac Shall Draw Up The Short List Of Consultants From Those Who Have Submitted Expression Of Interest, Including The Eligibility Documents, And Have Been Determined As Eligible In Accordance With The Provisions Of Republic Act 9184 (ra 9184), Otherwise Known As The “government Procurement Reform Act”, And Its Implementing Rules And Regulations (irr). The Short List Shall Consist Of Five (5) Prospective Bidders Who Will Be Entitled To Submit Bids. The Criteria And Rating System For Short Listing Are: Applicable Experience Of The Firm (within The Past 10 Years) (30 Points): • Completed Consulting Services Of Size, Complexity And Technical Specialty Comparable (similar/relevant) To The Job Under Consideration, Including Quality Of Performance. • Other Completed Consulting Services Related To The Job Under Consideration • Known Cases Of Prior Performance Including Quality Of Work Conforming To Obligation And Cost Of Services. Qualification Of Officer, Key Organic Personnel To Be Assigned To The Project (50 Points); And Job Capacity (20 Points): • Absorptive Capacity To Do Additional Works Other Than Those Currently Being Undertaken 6. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The Irr Of Ra 9184. Bidding Is Open To All Interested Bidders, Whether Local Or Foreign, Subject To The Conditions For Eligibility Provided In The Irr Of Ra 9184. 7. The Bids Shall Be Evaluated Using The Quality-cost Based Evaluation/selection (qcbe/qcbs) Procedure. The Criteria And Rating System For The Evaluation Of Bids Shall Be Provided In The Instructions To Bidders. 8. The Weight Of The Technical Proposal Shall Be 80% And The Financial Proposal Shall Be 20%. 9. The Contract Shall Be Completed Within One Hundred Twenty (120) Calendar Days, From The Date Of Contract Signing. 10. The Plgu-ifugao Reserves The Right To Reject Any And All Bids, Declare A Failure Of Bidding, Or Not Award The Contract At Any Time Prior To Contract Award In Accordance With Section 41 Of Ra 9184 And Its Irr, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11. For Further Information, Please Refer To: The Bac Secretariat Bids And Awards Committee (bac) Office 3rd Floor Peo Building, Capitol Compound, Poblacion South, Lagawe, Ifugao Bacgoodsifugao13@gmail.com 0953-931-6730 Date Of Posting: January 23, 2025 Carmelita B. Buyuccan Bac Chairperson Annex 1 Item No. General Description Qty. Unit Of Issue Unit Cost Total Cost 1 Hydro Energy Development: Pre Fs 1 Lot See Attached Terms Of Reference ***nothing Follows*** Total 4,500,000.00 Prepared By: Eleanor A. Oyami Bac-secretariat Certified Correct: Arundale Gum-u I. Bunnag Bac-secretariat On Goods & Infrastructure Republic Of The Philippines Cordillera Administrative Region Provincial Local Government Unit Of Ifugao Office Of The Provincial Governor Lagawe, Ifugao Terms Of Reference Project Title : Hydro Energy Development: Pre Fs Budget Item Particulars And Cost: Particulars Cost Cost Of Consultancy For The Hydro Energy Development: Pre Fs Project Particularly The Pre-application And Pre-feasibility Study Of The Proposed Alimit Hydro Power Plant. 4,500,000.00 Funding Source: Cy 2024 Supplemental Budget No. 2 Amounting To Php 2,200,000.00 And Cy 2024 Supplemental Budget No. 5 Amounting To Php 4,000,000.00 Prepared By: Reviewed By: Ericson T. Mammag Carmelita B. Buyuccan Provincial Engineer Provincial Project Development Coordinator Approved By: Jerry U. Dalipog Provincial Governor Table Of Contents Part I. Definition Of Terms ………………………………………………………………………………………. 03 Part Ii. Background ………………………………………………………………………………………………….. 04 1. General Background ...……………………………………………………………………………………05 Part Iii. Objective .………………………………………………………...…………………………………………..06 Part Iv. Scope Of Work: ……………….………………………………...............................................06 1. Field Survey ………………………………….………… ……………………………………………………06 2. Office Work ……………………………………………………………………………………………………07 Part V. Submission Of Output And Schedule …………………………………………………………08 1. Complete Package …………………………..................................................................07 2. Effectivity And End Of Consulting Services ………………………………………...…………..07 Part Vi. Qualification Of Consultants ……………………………………………………………..……08 Criteria For Selection …………………………………………………………………………………………….09 Part Vii. Source Of Fund…………………………….……………………………………………………………….10 Part Viii. Consultant’s Services Fee ………………………………………………………...................10 Approved Budget For The Contract……….………………………………..…...………………………..10 Advance Payment …………………………………………………………………………………………………10 Progress Billing ……………………………………………………………………………………………………..11 Part Ix. Data, Local Services And Personnel To Be Provided By Plgu For Critical Advisories…………………….……..................................................................................................11 Part X. Consultant’s Action Requiring Plgu’s Prior Approval ….…………………………11 Part Xi. Settling Of Disputes …………………………………………………………………….....................11 Part Xii. Consultant’s Liability ……………………………………………………………………………………12 Part Xiii. Annexes ……………………………………………………………………………………………………………12 1. Annex “a”- Criteria For Short Listing……..……………………………………………………12 2. Annex “b” - Certificate Of Availability Of Fund …………………….………………………13 3. Annex “c”- Approved Budget For The Contract …………………………………………..14 Part Xiv. Forms ………………………………………………………………………………………………….…..........15 1. Pf-1: Format Of Curriculum Vitae Of Consultants ………………………………………........15 2. Pf-2: Financial Proposal Form ………………………………………………………………….. ……..16 3. Pf-3: Form Of Contract Agreement ……………………………………………………………………17 4. Pf-4: Omnibus Sworn Statement Form ………………………………………………………………18 Part I Definition Of Terms For Purposes Of This Clause, The Bold Text Is Used To Identify The Defined Terms. 1. Denr – Department Of Environment And Natural Resources 2. Doe – Department Of Energy 3. Ncip – National Commission On Indigenous People 4. Nwrb – National Water Resource Board 5. Plgu - Provincial Local Government Unit Of Ifugao. 6. Sps - Special Project Section At The Provincial Governor’s Office. 7. Pgo - Provincial Governor’s Office. 8. Peo - Provincial Engineering Office. 9. Terms Of Reference (tor) - Refers To These Guidelines Governing The Delivery Of The Pre-application Requirements Of The Construction Of Alimit Hydro Power Plant. 10. Consultant - Is The Consultancy Services Entity Represented By The Manager Whose Proposal Has Been Accepted By The Plgu And To Whom The Contract To Provide The Consultancy Services Was Awarded. 11. Consulting Services – Refers To Services For Infrastructure Projects Or Activities Of The Provincial Local Government Of Ifugao Requiring Adequate External Technical And Professional Expertise That Are Beyond The Capability And/or Capacity Of The Plgu To Undertake Such As Development Of Hydro Power Plants. 12. Contract - Is The Agreement Between Plgu And The Consultant To Execute And Provide The Pre-application And Pre-feasibility Study Requirements Of The Construction Of Alimit Hydro Power Plant. 13. Contract Price - Is The Consultant’s Fee Stated In The Letter Of Acceptance And Thereafter To Be Paid By The Plgu To The Consultant For The Provision Of The Consultancy Services In Accordance With This Contract. 14. Plgu’s Representative - Refers To The Local Chief Executive Or Provincial Governor. 15. Plgu Engineer - Refers To The Provincial Engineer. 16. Re – Renewable Energy Part Ii Background 1. General Background It Has Long Been The Dream Of The People Of Ifugao For A Stable Power Supply To Improve The Delivery Of Government Services, Spur Industrialization And Economic Progress. The Proposed Construction Of Alimit Hydro Power Plant Will Harness The Existing Natural Water Resources Of The Province To Generate Electric Power And Facilitate Or Contribute In The Energization Of The Remaining 4,824 Households Without Power Amongst Ifugao’s And Provide A Stable Power Supply To The Local Industries, Manufacturers, Government And Private Institutions And Generate Additional Income To Finance The Different Programs, Projects And Activities Of The Provincial Government (plgu) Of Ifugao. The Plgu Is About 90% Dependent On The National Tax Allocation (nta) Hence The Need To Increase The Local Revenue. The Pre-application Requirement For The Processing Of The Applications For Renewable Energy Service Contract Is Very New To The Plgu Hence This Project Proposal For Consultancy To Engage Consultants Who Are Experts In The Preparation Of The Requirement Including The Pre-feasibility Study. This Terms Of Reference (tor) Covers The Preparation Of The Pre-application Documents Such As Topographic Survey To Ascertain The Location And Orientation Of The Project And As Basis Of The Area Clearance By The Department Of Energy. The Consultant Or Consultants Shall Also Submit A Pre-feasibility Study Based On Primary And Secondary Data To Check Whether The Proposal Is Worth Pursuing For The Comprehensive Feasibility Study Preparation And Detailed Technical Study With Engineering Design. The Study Includes The Submission And Application Of The Following To The Doe: Pre-application Requirements: A. Legal I) Original Copy Of Sp Resolution Approving The Proposed Project And Authorizing Its Representative To Negotiate And Enter Into Renewable Energy (re) Contract With Doe; Ii) Certified True Copy Of Passport Id Or Any Valid Government Issued Id Of The Authorized Representatives, I.e., Signatory And Witness Under The Re Contract. B. Technical I) Digital And Four (4) Print Copies In 8.5”x13” Bond Paper Of The Work Program In Gantt Chart Following The Approved Template Of The Doe; Ii) Digital And Print Copy Of Proposed Re Project Site/area Location Map And Technical Description As Verified By Doe Itms; Iii) Letter Signifying Intent To Pursue The Application Subject To Compliance With The Requirements Of Ra 11038 (expanded Nipas Of 2018) And Eo No. 23 Being Administered By The Department Of Environment And Natural Resources (denr). The Environmental Compliance Certificate (ecc)/environmental Impact Assessment (eia), Ncip Certification Precondition With Pre-field Base Investigation, Field Base Investigation, Free And Prior Inform Consent (fpic) And Water Permit And Water Sustainability Plan From The National Water Resource Board (nwrb) Are Some Of The Documents To Be Submitted To Form Part Of The Pre-feasibility Study. C. Financial I) Original Copy Or Certified True Copy Of The Latest Annual Report And/or Audited Financial Statements (fs) For The Last Two (2) Years From The Filing Date And Latest Unaudited Fs Duly Signed By The Responsible Official Such As The Chief Finance Officer If The Audited Fs Is More Than Six (6) Months Old At The Time Of Filing; Ii) Bank Certification To Substantiate The Cash Balance In The Audited Fs Or Unaudited Fs. Iii) Projected Cash Flow Statement For The Next Five (5) Years Showing The Fund Sources And Uses Of Funds For The Particular Offered Area, Other Applied Re Areas, Existing Service/operating Contracts With Doe And Other Existing Business With Support From Any Bank Approved Loan/credit Line Earmarked For The Proposed Operation. D. Lgu Endorsement – Barangay And Municipal. Pre-feasibility Study Requirements: A. Topographic Study – Submission Of A Namria Scaled Topographic Map Showing The Appropriate Location Of The Power Plant System. B. Hydrological Study – Submission Of A Hydrology Cycle Based On Actual Site Data And Historical Data From Government Agencies Like Pag-asa, Nia And Dpwh-brs. Determination Of The Minimum And Maximum River Flow Of Tributaries, Design Discharge, Net Head And Projected Annual Generation. C. Geological Study – Submission Of Site Geologic And Geohazard Assessment (ie. Earthquake, Erosion). Determine Rock Characteristics From At Least One Bored Hole At The River Bank Along The Proposed Dam Axis And Its Soil Bearing Capacity. D. Power/market Study – Submission Of Power/market Study To Establish The Supply And Demand Analysis, Generation And Production Cost. E. Benefit Cost Ratio And Economic Internal Rate Of Return (eirr) – Submission Of The Bcr And Eirr Run. F. Social And Environmental Study – Submission Of Environmental Compliance Certificate (ecc)/environmental Impact Assessment (eia), Ncip Certification Precondition With Pre-field Base Investigation, Field Base Investigation, Free And Prior Inform Consent (fpic) And Water Permit And Water Sustainability Plan From The National Water Resource Board (nwrb). G. Preliminary Civil Works And Electro-mechanical Works – Submission Of Technical Description Of The Project And Initial Design Of The Structures And Technical Drawings. Access Road Alignment, Transmission Line Alignment, Dam, Penstock, And Power House Layout And Electro-mechanical Specifications. H. Preliminary Project Cost Estimates – Submission Of Unit Price Analysis And Program Of Work. Part Iii Objective 2. The Primary Objective Of The Engagement Of The Consultant/s Is To Hasten The Preparation Of The Pre-application Requirements For The Processing Of Applications For Renewable Energy Service Contract So That Plgu Ifugao Will Be Awarded The Prior Rights To Develop The Site For A Hydro Power Plant Over Private Developers. 2. The Secondary Objective Is To Augment The Lack Of Expertise Amongst The Plgu Staff Re: Renewable Energy Project Development And Ensure That Proper Guidance Is Provided To Management Whether To Proceed With The Comprehensive Feasibility Study And Detailed Engineering Design. Part Iv Scope Of Work 1. Field Survey – This Activity Will Be Conducted On Site To Gather Information Needed In The Submission Of Documents And Other Requirements For Pre-application And Pre-feasibility Study Such As Preparation Of: A. Letter Of Intent (loi); B. Letter Of Authority Or Board Resolution; C. Location Map; D. Area Clearance; E. Doe Orientation. The Following Activities Are: A. Travel And Courtesy Call To The Governor With Plgu Officials; B. Meeting And Consultation With The Municipal And Barangay Officials And Project Affected Persons; C. Reconnaissance And Topographic Survey; D. Measurement Of Flow, Head And Hydropower Layout; E. Rock Sampling And Geologic Assessment; F. Identification And Inventory Of Social And Environmental Issues; G. Finalize Measurement And Wrapping Up All Surveys; H. Travel And Feedback To The Governor With Plgu Officials. 2. Office Work – This Activity Is The Preparation And Packaging Of The Requirement For Pre-application To The Department Of Energy Prescribed Under Ra 11234- Energy Virtual One-stop Shop Act (evos) And Preliminary Feasibility Study Indicating Whether The Construction Of Alimit Hydro Power Plant Is Worth Pursuing. The Pre-application Should Contain The Legal, Technical And Financial Requirements For The Renewable Energy Service Contracting And Packaging With The Following Pre-feasibility Topic Content Or As Maybe Agreed Upon Engagement: A. Project Proposal – Two To Three Paragraphs Describing The Proposed Construction Of Alimit Hydro Power Plant; B. Executive Summary And Salient Features – The Executive Summary Contains In A Nutshell The Result Of The Study Anchored On The Viability Indicators Such As Social And Environmental, Technical, Market And Economic Parameters. The Salient Features Describes The Characteristics Of The River Source, Discharge, The Available Head, The Projected Hydro Power Plant Capacity, The Project Components (diversion Weir, Power Tunnel, Surge Tank, Penstock, Power House, Out-door Switch Yard And Power Evacuation Line). The Location Of The Project (latitude/longitude), Access Road, Surge Shaft, Penstock, Power House, Turbine And Generator, Power Evacuation And Average Annual Generation; C. Geology – The Rock Profile (type, Characteristics, Bearing Capacity) And Hazard Study Especially Earthquake Intensity Requirement Of The Dam, Power House And Critical Structures; D. Hydrology – Describe The River System, Catchment Area, Historical Rainfall Data And Design River Discharge; E. Estimated Annual Power Generation – Based On Records For At Least Not Less Than 30 Years From January To December; F. Location Sketch – Showing The Different Components Of Hydro Power Plant Overlayed In Google And Topographic Map; G. Social And Environmental Impact Assessment – Describes The Social And Environmental Issues And Mitigating Measures, Social Acceptability And Right Of Way (row) Documentation; H. Power And Market Study – Describes The Current Condition Of The Power Supply In Ifugao And The Desired Demand For A Stable And Affordable Power Supply. I. Ball Park Cost Estimate – Contains The Following As Maybe Applicable: Pre-engineering Cost, Pre-development And Pre-installation Cost, Main Diversion Weir, Power Tunnelling And Civil Works, Surge Shaft, Penstock Civil Works, Power House, Switch Yard, Electrical And Mechanical Packages, Transmission Line, Access Roads, Social Development Expenses, Administrative And Project Management Expenses, Consultancy Fees, Contingency And Taxes. J. Organizational Analysis And Economic/financial Analysis – The Organizational Analysis Spells-out The Appropriate Organizational Structure To Manage The Hydropower Plant Whether In-house Or Out-source Or Hybrid. The Economic/financial Analysis Considers The Capital Cost Against The Potential Value Of The Electricity Generated Per Annum To Determine The Payback Period, Return On Investment Or Determination Of The Economic Internal Rate Of Return As Maybe Appropriate; K. Construction Schedule – To Be Presented In A Bar Chart From Survey And Site Investigation, Design And Preparation Of Detailed Engineering Design (ded), Approval Of Ded And Securing Statutory Clearances, Construction Of The Different Structures And Facilities, Designing-manufacturing-testing-acceptance Of Electrical And Mechanical (e&m) Equipment, Commissioning, Test Run Of The Project, And Commercial Operation Declaration; L. Technical Specification Of Electrical And Mechanical Packages – The Prospective Source Of Materials And Specifications. Part V Submission Of Output And Schedule 1. Complete Package Of The Pre-application Requirement And Pre-feasibility Study To Be Submitted In Hard Copies (3 Copies) And Electronic Copy Saved In Active And Pdf File. 2. Effectivity And End Of Consultancy Services The Consultancy Services Shall Be Effective Upon Signing And Notarization Of The Consultancy Service Contract. The Submission Of Final Output Is After 120 Calendar Days From Contract Signing And Terminates Upon The Issuance Of The Certificate Of Completion And Acceptance By The Implementing Agency Through A Group Of Reviewers From The Legal, Technical, Financial, Administrative Departments And Sanguniang Panlalawigan Of The Plgu. The Review, Compliance And Acceptance Period Will Take Another 30 Calendar Days Including The Approval Of The Head Of The Procuring Entity. Part Vi Qualification Of Consultant/s Consultant/s May Be Any Natural Or Juridical, Local Individual Or Company With Valid Business Permit And Other Documentary Requirements As Specified In The Revised Implementing Rules And Regulations Of Ra 9184 Which Shall Be Defined In The Bidding Documents For The Project. If The Participating Consultant/s Involves A Joint Venture Or Consortium, The Partners Of The Joint Venture (jv) Shall Organize And Create A Corporation Duly Registered Under The Corporation Code Of The Philippines. Further, The Jv Company Shall State The Following In The Bid Proposal: A. Name Of The Partners In The Joint Venture Or Consortium. B. Participation Interest Of Each Partner. Participating Bidder Must Possess The Necessary Technical Capabilities In Terms Of The Following: A. Track Record/experience In Similar Project Or Undertaking Within The Last Ten (10) Years From The Submission And Opening Of Quotations; B. Work Program Containing The Minimum Requirements Of The Project Including The Manpower And Man-days For The Conduct Of Study; C. Curriculum Vitae Of The Management And Technical Personnel; D. List Of Third-party Consultants With Corresponding Service Contract/agreement Showing Their Respective Qualifications. Professional Staff - The Consultant/s Shall In The Delivery Of The Foregoing Services Must Employ The Following Professionals Specified Below: Qualifications And Work Experiences Of Consultant’s Study Team Designation Profession Experience 1 Team Leader Degree In Electrical Or Mechanical Engineering Or Hydro Power Engineering Related Courses At Least 5 Years Relevant Experience 2 Hydrologist Degree Or Diploma And Experienced In Water Resources Engineering At Least 3 Years Relevant Experience 3 Surveyor/ Topographer Geodetic Engineer At Least 3 Years Relevant Experience 4 Civil Engineer Degree In Civil Engineering At Least 5 Years Relevant Experience 5 Geologist Degree In Geology/geotechnical Engineering At Least 3 Years Relevant Experience 6 Driver Experience In Off-road Driving At Least 3 Years Relevant Experience 7 Administrative Staff/survey Crew Degree Holder With Experience In Liaising, Proposal Packaging, Experience In Surveying At Least 1 Year Relevant Experience 8 Environmental Impact Assessment (eia) Preparer Degree In Social Or Environmental Science At Least 3 Years Relevant Experience 9 Social Impact Assessment (sia) Preparer Degree In Social Or Environmental Science At Least 3 Years Relevant Experience Criteria For Selection 1. Prospective Consulting Firm Will Be Shortlisted Based On The Criteria Shown In Annex A (“criteria For Shortlisting”) And As Summarized Below: 1.1. Applicable Experience Of The Firm (within The Past 10 Years); 1.2. Qualification Of Officer, Key Organic Personnel Who May Be Assigned To The Project (in Case Of Nominated Personnel Who Are Not Officers Or Organic Staff, A Notarized Letter Of Commitment For Each Personnel Should Be Submitted); And 1.3. Job Capacity 2. The Consulting Firm Shall Be Selected Using The Quality-cost Based Selection/evaluation (qcbs/qcbe) Procedure Under Republic Act (ra) No. 9184, Rules And Regulation (irr) And Based On The Following Criteria: 2.1. Technical Proposal : 80% 2.2. Financial Proposal : 20% Part Vii Source Of Fund Funds For The Preparation Of Pre-application And Pre-feasibility Study For The Construction Of Alimit Hydro Power Plant Will Be Sourced From The Cy 2024 Supplemental Budget No. 2 Amounting To Php 2,200,000.0 And Cy 2024 General Fund-other Development Fund Amounting To Php 4,000,000.00. Part Viii Consultancy Services Fee 1. The Fee For The Consultancy Service Is Inclusive Of Remuneration Cost (basic Salary, Social Charge, Overhead, Management Fee), Reimbursable Cost, Miscellaneous, Contingency, And Taxes. This Shall Also Be The Basis In Establishing The Approved Budget For The Contract (abc). Approved Budget For The Contract (abc) The Approved Budget For The Contract (abc) Is Four Million Five Hundred Thousand Pesos (php 4,500,000.00) With Details In Annex “c”. No. Item Cost I Remuneration Costs 2,604,481.53 Ii Reimbursable Costs 1,165,000.00 Iii Miscellaneous Expenses 72,375.97 Iv Sub-total (i+ii+iii) 3,841,857.50 V Vat (12% Of Remuneration) 312,549.78 Vi Contingency (8.99% Of Iv) 345,592.72 Vii Grand Total ( Iv+v+vi) 4,500,000.00 2. In All Billing Transactions, The Fee Shall Be Deposited Directly To The Consultant’s Bank Account. In This Connection, The Consultant Shall Provide The Name Of The Bank, Account Name, And Account Number. Advance Payment: I. The Consultant Shall Be Entitled To Fifteen Percent (15%) Advance Payment Upon The Effectivity Of Its Contract And Submission Of The Inception Report Which Shall Be Released In Lumpsum Amount; Ii. The Advance Payment Shall Be Recouped By Deducting In Every Progress Billing Using The Same Percentage Of The Progress Billing For The Deduction. Progress Billing: I) Consultant’s Progress Billing Shall Be Administered Twice With The First Billing At 40% Upon Submission And Application To Doe Of The Requirement For Pre-application Such As The Topographic Map, Legal, Technical And Financial Documents. The Last Billing Shall Be Processed Upon Submission Of The Packaged Pre-feasibility Study Containing The Items Under The Pre-feasibility Study Requirements Or 100% Physical Progress With Issued Certificate Of Completion And Acceptance. Ii) Billing For The Reimbursable Items May Be Requested During Progress Billing Based On Actual Expenses Incurred And Supported By Official Receipts/documents. In The Absence Of Official Receipts/documents, The Firm May Also Be Allowed To Submit A Certification Of Actual Disbursements Made Under Oath. Part Ix Data, Local Services And Personnel To Be Provided By The Plgu For Critical Advisories 1. Plgu Warrants The Availability Of Funds; 2. Plgu Shall Provide All Contract Documents To The Consulting Firm; 3. Plgu Shall Provide Focal Persons From Plo For Legal Review, Peo For Technical Review, Ppdo For Project Development And Pre-fs Evaluation Review, Pto With Sanguniang Panlalawigan (sp) For The Financial Viability Review And Administrator’s Office For The Hydro Power Organizational Structure Review Of The Project In The Contract. Part X Consultant’s Action Requiring Plgu’s Prior Approval Replacement Of Technical Personnel By The Consultant Must Have The Prior Approval Of Plgu. Plgu Will Approve The Replacement, If The Qualifications Of The Substitute Professional Equals Or Surpasses That Of The Professional Staff To Be Replaced. Part Xi Settling Of Disputes Any Dispute Arising From The Delivery Of The Contract For The Consultancy Services Shall Be Settled Amicably By Both Parties. During The Entire Negotiations, The Plgu Shall Be Represented By The Plgu Legal Officer While The Consultant Shall Be Represented By The General Manager/project Manager. Should The Two Parties Fail To Settle Their Dispute Amicably, The Dispute Shall Be Referred To The Dole Ifugao Provincial Office Or Other Appropriate Entity As Agreed By The Contracting Party. Part Xii Consultant’s Liability The Consultant’s Liability Under This Contract Shall Be Provided/governed By Applicable Laws Of The Republic Of The Philippines (i.e. Ra 9184). Part Xiii Annexes Annex “a” Criteria For Shortlisting Rating Factor Points/weight Applicable Experience Of The Firm (within The Past 10 Years) • Completed Consulting Services Of Size, Complexity And Technical Specialty Comparable (similar/relevant) To The Job Under Consideration, Including Quality Of Performance. • Other Completed Consulting Services Related To The Job Under Consideration • Known Cases Of Prior Performance Including Quality Of Work Conforming To Obligation And Cost Of Services. 30 Qualification Of Officer, Key Organic Personnel To Be Assigned To The Project 50 Job Capacity • Absorptive Capacity To Do Additional Works Other Than Those Currently Being Undertaken 20 Note: Similar Projects Refer To Contracts With Scope Of Works Covering The Doe Pre-application For Re Service Contract, Conduct Of Pre-feasibility Study Or Comprehensive Feasibility Study Of Hydropower Plant. Relevant Projects Are Pre-fs And Fs, Detailed Engineering, Or Advisory Services Conducted For Water Resource-related And Power Facilities Related Projects; Detailed Engineering, Advisory Services, Or Components Of An Fs (demand Forecast, Economic, Financial) For Hydropower Project And Construction, Supervision, Civil Works Or Operation And Maintenance Of Projects Pertaining To Hydropower Project. Annex “b” Certificate Of Availability Of Fund Republic Of The Philppines Provincial Local Government Of Ifugao Lagawe, Ifugao Date: Certification To Whom It May Concern: This Is To Certify That The Amount Of Four Million Five Hundred Thousand Pesos (php 4,500,000.00 ) Philippine Currency Is Available For Expenditure For The Hydro Energy Development: Pre Fs. Payment Of The Consultancy Services For The Pre-application And Pre-feasibility Study Of The Construction Of Alimit Hydro Power Plant. At Barangay Alimit , Municipality Of Mayoyao , Province Of Ifugao. Charge To: Cy 2024 Supplemental Budget No. 2 And Cy 2024 Supplemental Budget No. 5 Appropriation Available: Allotment Available: Funds Available: Virgilio T. Marquez Charles P. Baguilat Martha U. Ballangi Provincial Budget Officer Provincial Accountant Oic. Provincial Treasurer Approved By: Jerry U. Dalipog Provincial Governor Annex “c” Approved Budget For The Contract Consultancy Services Position Number Of Personnel Man-days Billing Rate Total Cost I. Remuneration Costs 1 Team Leader / Hydro Specialist 1 70 6,674.15 467,190.53 2 Hydrologist 1 46 6,663.33 306,513.18 3 Surveyor / Topographer 1 54 3,601.71 194,492.12 4 Civil Engineer 1 70 4,140.00 289,800.00 5 Geologist 1 36 3,857.73 138,878.18 6 Environmental Impact Assessment (eia) Preparer 2 184 2,666.91 490,711.94 7 Social Impact Assessment (sia) Preparer 2 184 2,666.91 490,711.94 8 Driver 1 20 1,018.18 20,363.64 9 Administrative Staff (ao 2)/survey Crew 2 & 6 156 1,320.00 205,920.00 Sub-total 2,604,581.53 Ii. Reimbursable Costs Description Unit Quantity Unit Price Total Cost 8 Per Diem – Php 2,000 Per Man-day Man-days 400 2,000.00 800,000.00 9 Fuel For Vehicles Ls 95,000.00 10 Cost Of Field Office Rental And Office Supplies Ls 200,000.00 11 Cost Of Tools And Equipment Or Rental Ls 70,000.00 Sub-total 1,165,000.00 Iii. Miscellaneous Description Unit Quantity Unit Price Total Cost 12 Cost Of Meetings/consultations/investigations/research Ls 72,375.97 Sub-total 72,375.97 13 Vat (12% Of Remuneration Cost) Ls 312,549.78 14 Contingency 10% Of (i+ii+iii) Ls 345,592.72 Total 4,500,000.00 Part Xiv Forms Pf-1. Format Of Curriculum Vitae (cv) For Proposed Consultancy Proposed Position: ________ Name Of Firm: Name Of Staff: Profession: Date Of Birth: ________________ Years With Firm/entity: ______ Nationality: Membership In Professional Societies: Detailed Tasks Assigned: Key Qualifications: [give An Outline Of Staff Member’s Experience And Training Most Pertinent To Tasks At Hand. Describe Degree Of Responsibility Held By Staff Member On Relevant Previous Projects And Give Dates And Locations.] Education: [summarize College/university And Other Specialized Education Of Staff Members, Giving Names Of Schools, Dates Attended, And Degrees Obtained.] Employment Record: [starting With Present Position, List In Reverse Order Every Employment Held. List All Positions Held By Staff Member Since Graduation, Giving Dates, Names Of Employing Organizations, Titles Of Positions Held, And Locations Of Projects. For Experience In Last Ten Years, Also Give Types Of Activities Performed And Client References, Where Appropriate.] Languages: [for Each Language, Indicate Proficiency: Excellent, Good, Fair, Or Poor In Speaking, Reading, And Writing.] Certification: I, The Undersigned, Certify To The Best Of My Knowledge And Belief, These Data Correctly Describe Me, My Qualifications, And My Experience. Date: [signature Of Staff Member Of The Firm] (day/month/year) ___________________________________________________________ (full Name Of Staff Member) Pf-2. Financial Proposal Submission Form [date] The Chairperson Bids And Awards Committee Provincial Local Government Unit Of Ifugao Poblacion South, Lagawe, Ifugao Madam: We, The Undersigned, Offer To Provide The Consulting Services For The Hydro Energy Development: Pre Fs Project Particularly The Pre-application And Pre-fs Of The Construction Of Alimit Hydro Power Plant In Accordance With Your Terms Of Reference (tor) Dated (insert Date). Our Financial Proposal Is For The Sum Of [amount In Words And Figures]. This Amount Is Inclusive Of The Basic Salaries, Social Charges, Overhead, Management Fee, Reimbursable Cost (per Diems, Transportation Expenses, Office Supplies, Cost Of Tools And Equipment), Miscellaneous, Contingencies, And Tax Expenses. Our Financial Proposal Shall Be Binding Upon Us Subject To The Modifications Resulting From Contract Negotiations, Up To The Date Of Award. In Accordance With Clause 4 Of The Omnibus Sworn Statement, We Acknowledge And Accept Plgu’s Right To Inspect And Audit All Records Relating To Our Proposal Irrespective Of Whether We Enter Into A Contract With Plgu As A Result Of This Proposal. We Confirm That We Have Read, Understood And Accepted The Contents Of The Terms Of Reference (tor), The Provisions Relating To The Eligibility Of Consultant’s Technical Staff And The Applicable Guidelines Of The Procurement Rules Of The Plgu, Any And All Supplemental Bulletins Issued And Other Attachments And Inclusions In The Terms Of Reference (tor) Sent To Us. We Understand That Our Financial Proposal Is Fixed Which Shall Not Be Adjusted Regardless Of Whether The Contract Actual Duration Of The Consultancy Contract Package Varies From The Original Contract Duration And That You Are Not Bound To Accept Any Proposal You Receive. Yours Sincerely, Authorized Signature : Name And Title Of Signatory : Name Of Firm : Address : Pf 3. Form Of Contract Agreement This Agreement, Made This _______ Day Of _____________, 2024 Between The Provincial Local Government Unit Of Ifugao (plgu) Hereinafter Called The “entity” And ____________________________ Hereinafter Called The “consultant”. Whereas, The Entity Is Desirous That The Consultant Execute The Consultancy Services Provided In The Tor Hereinafter Called “the Services” And The Entity Has Accepted The Price Proposal For _______________________________________________________________ (php ____________________ ) By The Consultant For The Execution Of The Consultancy Services For The Doe Pre-application And Pre-feasibility Study Of The Construction Of Alimit Hydro Power Plant. Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Terms Of Reference (tor) Hereinafter Referred To. 2. The Following Documents Shall Be Attached, Deemed To Form, And Be Read And Construed As Part Of This Agreement, To Wit: (a) Terms Of Reference (tor); (b) Annexes; (c) Forms; (d) Financial Proposal; (e) Bids And Awards Committee (bac) Resolution Of Award Of Contract And The Consultant’s Conforme Thereto. 3. In Consideration Of The Payments To Be Made By Plgu To The Consultant As Hereinafter Mentioned, The Consultant Hereby Covenants With Plgu To Execute And Complete The Consulting Services In Conformity With The Provisions Of This Contract In All Respects. 4. Plgu Hereby Covenants To Pay The Consultant In Consideration Of The Execution And Completion Of The Consultancy Services For The Pre-application And Pre-feasibility Study Of The Construction Of Alimit Hydro Power Plant, The Contract Price Or Such Other Sum As May Become Payable Under The Provisions Of This Contract At The Time And In The Manner Prescribed By This Contract. In Witness Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of Owner (plgu) Binding Signature Of Consultant _______________________________________ ____________________________ [addendum Showing The Corrections, If Any, Made During The Proposal Evaluation Should Be Attached With This Agreement] P F 4. Omnibus Sworn Statement Republic Of The Philippines ) City/municipality Of Lagawe) S.s. Affidavit I, ___________________________, Of Legal Age, Married, Filipino, And Residing At _________________________________________________, After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. I Am The Owner And Sole Proprietor Of __________________________________ With Office Address At _____________________________________________; As The Owner And Sole Proprietor Of _______________________________, I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Represent It In The Proposal For The Consultancy Services For The Pre-application And Pre-feasibility Study Of The Construction Of Alimit Hydro Power Plant For The Project/s Of Ifugao Plgu. 2._________________________________ Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board; 3. ___________________________________ Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 5. I Am Not Related To The Local Chief Executive (lce) Of Plgu, Members Of The Bac Including The Technical Working Group (twg), The Technical Professionals Who Assisted/drafted The Tor, And The Bac Secretariat By Consanguinity Or Affinity Up To The Third Civil Degree; 6. _____________________________________ Complies With Existing Labor Laws And Standards; And 7. _____________________________________ Is Aware Of And Has Undertaken The Following Responsibilities Of The Service Provider: (a) Carefully Examined The Terms Of Reference (tor); (b) Acknowledge All Conditions, Local Or Otherwise, Affecting The Implementation Of The Service Contract; (c) Made An Estimate Of The Facilities Available And Needed For The Service Contract, If Any; And (d) Inquire Or Secure Supplemental Bulletin(s) Issued For The Consultancy Services For The Topographic Survey And Pre-feasibility Study Of The Construction Of Alimit Hydro Power Plant. In Witness Whereof, I Have Hereunto Set My Hand This ____ Day Of _________________, 20____at Lagawe, Ifugao, Philippines. __________________________________________________________ [consultant’s Name And Signature]

Details: Description Bids & Awards Committee Invitation For Negotiated Procurement - Two-failed Biddings For The Request For Supply & Delivery Of Medical Supplies 2025 1. The Leyte Regional Prison (lrp) Intends To Procure Medical Supplies 2025 With An Approved Budget For The Contract (abc) Amounting To Five Hundred Ninety-six Thousand Four Hundred Seventy-seven Pesos Only (php 596,477.00). 2. The Lrp Bids And Award Committee (bac) Now Invites Technically, Legally, And Financially Capable Suppliers For The Said Project. 3. The Procurement Procedure For This Requirement Is Negotiated Procurement For Two-failed Bidding Pursuant To Section 53.1 Of 2016 Revised Implementing Rules And Regulations (irr) Of Republic Act (ra) No. 9184. The Selection Of The Successful Offer Shall Be Based On The Best And Final Offer That Will Be Submitted On The Set Deadline By The Bac And Which Would Meet The Minimum Technical Specifications Required. 4. The Interested Bidders May Obtain Further Information From The Bac Secretariat At The Address Given Below From 09 January 2025 To 13 January 2025 Before 9:00am. 5. The Lrp Will Hold A Negotiation Meeting On 13 January 2025 At Exactly 9:00am At Conference Room, Admin Building, Lrp, Abuyog, Leyte, Which Shall Be Open To Prospective Bidders. 6. Four (4) Copies Of The Proposals (one Original And Three Copies) Must Be Submitted To The Bac Which Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address Indicated Above On Or Before 5:00 Pm Of 14 January 2025. Late Submission Shall Not Be Accepted. 7. Interested Bidders Shall Submit The Following Documents In Sealed Envelopes, Labeled As “negotiated Procurement For Two-failed Biddings”, With The Title Of The Procurement Project, Name Of The Bidder, Address, And The Contact Details Of The Bidder, Addressed To The Bac. I. Technical Component Envelope Class “a” Documents Legal Documents (a) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; Technical Documents (b) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid, Except Under Conditions Provided For In Sections 23.4.1.3 And 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184, Within The Relevant Period As Provided In The Bidding Documents; And (d) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And (e) Conformity With The Schedule Of Requirements (annex “a”) & Technical Specifications (annex “b”), Which May Include Production/delivery Schedule, Manpower Requirements, And/or After-sales/parts, If Applicable; And (f) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. Financial Documents ⬜ (g) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc) Or A Committed Line Of Credit From A Universal Or Commercial Bank In Lieu Of Its Nfcc Computation. Class “b” Documents ⬜ (h) If Applicable, A Duly Signed Joint Venture Agreement (jva) In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (i) Original Of Duly Signed And Accomplished Financial Bid Form; And ⬜ (j) Original Of Duly Signed And Accomplished Price Schedule(s). 8. The Special Conditions Of The Contract (annex “c”) Shall Form Part Of The Contract. Other Conditions Of The Contract Shall Be Governed By The Implementation Of The Rules And Regulations Of Ra 9184 And Other Related And Applicable Laws. Issued This 8th Day Of January 2025. Mr. Tracy B. Soriano, Msca Chairperson, Bids And Awards Committee Company Letterhead Statement Of Ongoing Government & Private Contracts Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Statement Of All Its Ongoing Government And Or Private Contracts Including Contracts Awarded But Not Yet Started, If Any Whether Similar Or Not Similar In Nature. Name Of Contract Date Of Contract Contract Duration Owner’s Name And Address Kind Of Goods Amount Of Contract Value Of Outstanding Contract Total Value Of Outstanding Contract: Certified Correct: Name And Signature Of Authorized Representative Position Date Company Letterhead Statement Of Single Largest Completed Contract Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Statement Of Single (1) Largest Completed Contract Of Similar In Nature Within The Last Two (2) Years From The Date Of Submission And Receipt Of Bids Amounting To At Least Twenty-five Percent (25%) Of The Approved Budget Of The Contract (abc) Name Of Contract Date Of Contract Contract Duration Owner’s Name And Address Kind Of Goods Amount Of Contract Amount Of Completed Contracts, Adjusted By The Bidder To Current Prices Using Psa’s Consumer Price Index, If Necessary Date Of Delivery End User’s Acceptance Or Official Receipt(s) Or Sales Invoice Issued For The Contract, (attached Copy) Certified Correct: Name And Signature Of Authorized Representative Position Date Company Letterhead Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Republic Of The Philippines) City Of _______________________) S.s. X------------------------------------------------------x Bid Securing Declaration Invitation To Bid: [insert Reference Number] To: Leyte Regional Prison I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I/we Will Be Automatically Disqualified From Bidding For Any Contract With Any Procuring Entity For A Period Of Two (2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen (15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1, Except 69.1(f), Of The Irr Of Ra 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid Securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am/we Are Declared Ineligible Or Post-disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; (c) I Am/we Are Declared The Bidder With The Lowest Calculated Responsive Bid, And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I/we Have Hereunto Set My/our Hand/s This ____ Day Of [month] [year] At [place Of Execution]. [insert Name Of Bidder’s Authorized Representative] [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me This ___ Day Of [month] [year] At [place Of Execution], Philippines. Affiant/s Is/are Personally Known To Me And Was/were Identified By Me Through Competent Evidence Of Identity As Defined In The 2004 Rules On Notarial Practice (a.m. No. 02-8-13-sc). Affiant/s Exhibited To Me His/her [insert Type Of Government Identification Card Used], With His/her Photograph And Signature Appearing Thereon, With No. ________ And His/her Community Tax Certificate No. _______ Issued On ____ At ______. Witness My Hand And Seal This ___ Day Of [month] [year]. Name Of Notary Public Serial No. Of Commission _______________ Notary Public For _______ Until __________ Roll Of Attorneys No. __________________ Ptr No. ______ [date Issued], [place Issued] Ibp No. ______ [date Issued], [place Issued] Doc. No. _____ Page No. _____ Book No. _____ Series Of _____ Section Vi. Schedule Of Requirements Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. # Description Qty Dosage Form Delivered, Weeks/months 1 Acid Fast Stain, Medic (ziel-neelsen Hot Method) 3 Pcs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 2 Acepto Bulb Syringe 5 Pcs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 3 Adult Pulse Oximeter Fingertip (durable) 5 Pcs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 4 Alcohol 70% Gallon 100 Gallon Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 5 Aneroid Sphygmomanometer W/ Stethoscope (durable) 10 Set Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 6 Battery Double Aa (heavy Duty) 50 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 7 Battery Triple Aaa (heavy Duty) 50 Capsule Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 8 Blood Collection Tube 5ml (lavender) 1 Box Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 9 Blood Collection Tube 5ml (yellow) 1 Box Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 10 Cold Compress Bag 5 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 11 Denatured Alcohol 1l 2 Gallon Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 12 Disinfectant Solution 10 Litrs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 13 Drug Testing Kit (urine) 1000 Unit Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 14 Dsn 10cc 500 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. I/we Hereby Commit To Comply And Deliver All The Requirement In Accordance With The Above Stated Schedule. Conforme: Name Of Company In Print Signature Printed Name Of Authorized Representative Date Section Vi. Schedule Of Requirements Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. # Description Qty Dosage Form Delivered, Weeks/months 15 Dsn 3cc 700 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 16 Dsn 5cc 700 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 17 Dsn 1cc 500 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 18 Easy Touch Blood Glucose Strips 25's 20 Bottle Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 19 Easy Touch Blood Cholesterol Strips 25's 30 Bottle Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 20 Easy Touch Blood Uric Strips 25's 30 Bottle Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 21 Examination Disposable Latex Gloves Powder Free 100 Box Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 22 Face Mask 50's 100 Box Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 23 Heplock 20 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 24 Hot Water Bag 10 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 25 Hydrogen Peroxide 10 Volume 20 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 26 Iv Infusion Set Adult 500 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 27 Kidney Basin Stainless 4 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 28 Lubricating Jelly 80gms 50 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. I/we Hereby Commit To Comply And Deliver All The Requirement In Accordance With The Above Stated Schedule. Conforme: Name Of Company In Print Signature Printed Name Of Authorized Representative Date Section Vi. Schedule Of Requirements Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. # Description Qty Dosage Form Delivered, Weeks/months 29 Medical Penlight 5 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 30 Medical Oxygen Regulator 5 Pcs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 31 Muriatic Acid Solution 50 Gallon Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 32 Na Hypochlorite Solution 30 Gallon Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 33 Nebulizer 2 Set Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 34 One Touch Select Simple Test Strip 25's 50 Bottle Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 35 Oxygen Mask Cannula 150 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 36 Oxygen Trolley (5-20 Lbs) 2 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 37 Petroleum Jelly 25gms 100 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 38 Plastic Canister 3 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 39 Plastic Splint Adult 10 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 40 Rotahaler 50 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 41 Sphygmomanometer Valve With Bulb 20 Set Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed 42 Sterile Latex Surgical Gloves #7, 50pairs/box 5 Box Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed I/we Hereby Commit To Comply And Deliver All The Requirement In Accordance With The Above Stated Schedule. Conforme: Name Of Company In Print Signature Printed Name Of Authorized Representative Date Section Vi. Schedule Of Requirements Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. # Description Qty Dosage Form Delivered, Weeks/months 43 Soluset Infusion Set 5 Pcs Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 44 Urinal (male) 10 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. 45 Urine Container 50ml 1000 Pieces Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. I/we Hereby Commit To Comply And Deliver All The Requirement In Accordance With The Above Stated Schedule. Conforme: Name Of Company In Print Signature Printed Name Of Authorized Representative Date Section Vii. Technical Specifications Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Item No. Qty. Dosage Form Agency Specification Bidder’s Statement Of Compliance 1 3 Pcs Acid Fast Stain, Medic (ziel-neelsen Hot Method) 2 5 Pcs Acepto Bulb Syringe 3 5 Pcs Adult Pulse Oximeter Fingertip (durable) 4 100 Gallon Alcohol 70% Gallon 5 10 Set Aneroid Sphygmomanometer W/ Stethoscope (durable) 6 50 Pieces Battery Double Aa (heavy Duty) 7 50 Capsule Battery Triple Aaa (heavy Duty) 8 1 Box Blood Collection Tube 5ml (lavender) 9 1 Box Blood Collection Tube 5ml (yellow) 10 5 Pieces Cold Compress Bag 11 2 Gallon Denatured Alcohol 1l 12 10 Litrs Disinfectant Solution 13 1000 Unit Drug Testing Kit (urine) 14 500 Pieces Dsn 10cc 15 700 Pieces Dsn 3cc 16 700 Pieces Dsn 5cc 17 500 Pieces Dsn 1cc I Hereby Certify That The Statement Of Compliance To The Foregoing Technical Specifications Are True And Correct, Otherwise, If Found To Be False Either During Bid Evaluation Or Post- Qualification, The Same Shall Give Rise To Automatic Disqualification Of Our Bid. ___________________________________________ Name Of Company In Print ___________________________________________ Signature Over Printed Name Of Authorized Representative Section Vii. Technical Specifications Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Item No. Qty. Dosage Form Agency Specification Bidder’s Statement Of Compliance 18 20 Bottle Easy Touch Blood Glucose Strips 25's 19 30 Bottle Easy Touch Blood Cholesterol Strips 25's 20 30 Bottle Easy Touch Blood Uric Strips 25's 21 100 Box Examination Disposable Latex Gloves Powder Free 22 100 Box Face Mask 50's 23 20 Pieces Heplock 24 10 Pieces Hot Water Bag 25 20 Pieces Hydrogen Peroxide 10 Volume 26 500 Pieces Iv Infusion Set Adult 27 4 Pieces Kidney Basin Stainless 28 50 Pieces Lubricating Jelly 80gms 29 5 Pieces Medical Penlight 30 5 Pcs Medical Oxygen Regulator 31 50 Gallon Muriatic Acid Solution 32 30 Gallon Na Hypochlorite Solution 33 2 Set Nebulizer 34 50 Bottle One Touch Select Simple Test Strip 25's I Hereby Certify That The Statement Of Compliance To The Foregoing Technical Specifications Are True And Correct, Otherwise, If Found To Be False Either During Bid Evaluation Or Post- Qualification, The Same Shall Give Rise To Automatic Disqualification Of Our Bid. ___________________________________________ Name Of Company In Print ___________________________________________ Signature Over Printed Name Of Authorized Representative Section Vii. Technical Specifications Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Item No. Qty. Dosage Form Agency Specification Bidder’s Statement Of Compliance 35 150 Pieces Oxygen Mask Cannula 36 2 Pieces Oxygen Trolley (5-20 Lbs) 37 100 Pieces Petroleum Jelly 25gms 38 3 Pieces Plastic Canister 39 10 Pieces Plastic Splint Adult 40 50 Pieces Rotahaler 41 20 Set Sphygmomanometer Valve With Bulb 42 5 Box Sterile Latex Surgical Gloves #7, 50pairs/box 43 5 Pcs Soluset Infusion Set 44 10 Pieces Urinal (male) 45 1000 Pieces Urine Container 50ml I Hereby Certify That The Statement Of Compliance To The Foregoing Technical Specifications Are True And Correct, Otherwise, If Found To Be False Either During Bid Evaluation Or Post- Qualification, The Same Shall Give Rise To Automatic Disqualification Of Our Bid. ___________________________________________ Name Of Company In Print ___________________________________________ Signature Over Printed Name Of Authorized Representative Company Letterhead Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Omnibus Sworn Statement Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor, Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For Supply & Delivery Of Medical Supplies 2025 Of The Leyte Regional Prison As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For The Supply & Delivery Of Medical Supplies 2025 Of The Leyte Regional Prison, As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g., Duly Notarized Secretary’s Certificate, Board/partnership Resolution, Or Special Power Of Attorney, Whichever Is Applicable;)]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledge All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Made An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquire Or Secure Supplemental/bid Bulletin(s) Issued For The Supply & Delivery Of Medical Supplies 2025. 9. [name Of Bidder] Did Not Give Or Pay Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. In Witness Whereof, I Have Hereunto Set My Hand This __ Day Of ___, 20__ At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory Subscribed And Sworn To Before Me This ___ Day Of [month] [year] At [place Of Execution], Philippines. Affiant/s Is/are Personally Known To Me And Was/were Identified By Me Through Competent Evidence Of Identity As Defined In The 2004 Rules On Notarial Practice (a.m. No. 02-8-13-sc). Affiant/s Exhibited To Me His/her [insert Type Of Government Identification Card Used], With His/her Photograph And Signature Appearing Thereon, With No. ________ And His/her Community Tax Certificate No. _______ Issued On ____ At ______. Witness My Hand And Seal This ___ Day Of [month] [year]. Name Of Notary Public Serial No. Of Commission _______________ Notary Public For _______ Until __________ Roll Of Attorneys No. __________________ Ptr No. ______ [date Issued], [place Issued] Ibp No. ______ [date Issued], [place Issued] Doc. No. _____ Page No. _____ Book No. _____ Series Of _____ Company Letterhead Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Certificate Of Net Financial Contracting Capacity (please Show Figures At How You Arrived At The Nfcc) This Is To Certify That Our Net Financial Contracting Capacity (nfcc) Is _________________________(p____________) Which Is At Least Equal To The Total Ceiling Price We Are Bidding. The Amount Is Computed As Follows: (please Show Computation Of Nfcc) Nfcc = (ca-cl) (15) – C Where: Ca = Current Assets Cl = Current Liabilities C = Value Of All Outstanding Or Uncompleted Portions Of The Projects Under Going Contracts, Including Awarded Contracts Yet To Be Started Coinciding With The Contract For This Project Note: The Values Of The Bidder’s Current Assets And Current Liabilities Shall Be Based On The Audited Financial Statement Submitted To The Bir. Issued This _______day Of __________2025. _______________________________________________ Name & Signature Of Authorized Representative ____________________ Position _______________ Date Company Letterhead Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Bid Form Date: Invitation To Bid No: Bid 2024-08 To: Mr. Tracy B. Soriano, Msca Bac Chairperson Leyte Regional Prison Abuyog, Leyte Gentlemen And/or Ladies: Having Examined The Bidding Documents Including Bid Bulletin Numbers Bid2024-08, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Offer To Supply & Deliver Of Medical Supplies 2025 In Conformity With The Said Bidding Documents For The Sum Of __________________________________________₱ ________ Or Such Other Sums As May Be Ascertained In Accordance With The Schedule Of Prices Attached Herewith And Made Part Of This Bid. We Undertake, If Our Bid Is Accepted, To Deliver The Goods In Accordance With The Delivery Schedule Specified In The Schedule Of Requirements. If Our Bid Is Accepted, We Undertake To Provide A Performance Security In The Form, Amounts, And Within The Times Specified In The Bidding Documents. Until A Formal Contract Is Prepared And Executed, This Bid, Together With Your Written Acceptance Thereof And Your Notice Of Award, Shall Be Binding Upon Us. We Understand That You Are Not Bound To Accept The Lowest Calculated Bid Or Any Bid You May Receive. We Certify/confirm That We Comply With The Eligibility Requirements Of The Bidding Documents. I/we Likewise Certify/confirm That The Undersigned, [for Sole Proprietorships, Insert]: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], Has The Full Power And Authority To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract, On The Latter’s Behalf For The Supply & Delivery Of Medical Supplies 2025. We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including The Attached Schedule Of Prices, Shall Be A Ground For The Rejection Of Our Bid. Dated This ________________ Day Of ________________ 20______. [signature] [in The Capacity Of] Duly Authorized To Sign Bid For And On Behalf Of ____________________________ Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Schedule Of Prices Qty. Unit Of Issue Agency Specification Abc Unit Price Total Bid Price Inclusive Of Vat 3 Pcs Acid Fast Stain, Medic (ziel-neelsen Hot Method) 12,441.00 5 Pcs Acepto Bulb Syringe 350.00 5 Pcs Adult Pulse Oximeter Fingertip (durable) 10,500.00 100 Gallon Alcohol 70% Gallon 42,000.00 10 Set Aneroid Sphygmomanometer W/ Stethoscope (durable) 39,000.00 50 Pieces Battery Double Aa (heavy Duty) 5,400.00 50 Capsule Battery Triple Aaa (heavy Duty) 5,400.00 1 Box Blood Collection Tube 5ml (lavender) 130.00 1 Box Blood Collection Tube 5ml (yellow) 1,200.00 5 Pieces Cold Compress Bag 720.00 2 Gallon Denatured Alcohol 1l 1,200.00 10 Litrs Disinfectant Solution 21,600.00 1000 Unit Drug Testing Kit (urine) 108,000.00 500 Pieces Dsn 10cc 5,000.00 700 Pieces Dsn 3cc 4,900.00 [signature] [in The Capacity Of] Duly Authorized To Sign Bid For And On Behalf Of ____________________________ Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Schedule Of Prices Qty. Unit Of Issue Agency Specification Abc Unit Price Total Bid Price Inclusive Of Vat 700 Pieces Dsn 5cc 5,600.00 500 Pieces Dsn 1cc 3,500.00 20 Bottle Easy Touch Blood Glucose Strips 25's 20,400.00 30 Bottle Easy Touch Blood Cholesterol Strips 25's 30,600.00 30 Bottle Easy Touch Blood Uric Strips 25's 30,600.00 100 Box Examination Disposable Latex Gloves Powder Free 42,000.00 100 Box Face Mask 50's 9,600.00 20 Pieces Heplock 360.00 10 Pieces Hot Water Bag 1,080.00 20 Pieces Hydrogen Peroxide 10 Volume 2,640.00 500 Pieces Iv Infusion Set Adult 25,000.00 4 Pieces Kidney Basin Stainless 2,976.00 50 Pieces Lubricating Jelly 80gms 4,200.00 5 Pieces Medical Penlight 3,000.00 5 Pcs Medical Oxygen Regulator 12,000.00 [signature] [in The Capacity Of] Duly Authorized To Sign Bid For And On Behalf Of ____________________________ Supply & Delivery Of Medical Supplies For Cy 2025 Bid Reference No.: Bid2024-08 Schedule Of Prices Qty. Unit Of Issue Agency Specification Abc Unit Price Total Bid Price Inclusive Of Vat 50 Gallon Muriatic Acid Solution 15,000.00 30 Gallon Na Hypochlorite Solution 9,000.00 2 Set Nebulizer 3,840.00 50 Bottle One Touch Select Simple Test Strip 25's 51,000.00 150 Pieces Oxygen Mask Cannula 11,700.00 2 Pieces Oxygen Trolley (5-20 Lbs) 8,400.00 100 Pieces Petroleum Jelly 25gms 7,200.00 3 Pieces Plastic Canister 3,600.00 10 Pieces Plastic Splint Adult 10,800.00 50 Pieces Rotahaler 6,000.00 20 Set Sphygmomanometer Valve With Bulb 6,520.00 5 Box Sterile Latex Surgical Gloves #7, 50pairs/box 4,500.00 5 Pcs Soluset Infusion Set 500.00 10 Pieces Urinal (male) 1,020.00 1000 Pieces Urine Container 50ml 6,000.00 Total Bid Price Inclusive Of Vat In Words [signature] [in The Capacity Of] Duly Authorized To Sign Bid For And On Behalf Of ____________________________ Special Conditions Of Contract Gcc Clause 1 Delivery And Documents – Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi. Schedule Of Requirements. Upon Delivery Of The Goods To The Project Site, The Supplier Shall Notify The Procuring Entity And Present The Following Documents To The Procuring Entity: (i) Original And Four Copies Of The Supplier’s Invoice Showing Goods’ Description, Quantity, Unit Price, And Total Amount; (ii) Delivery Receipt Detailing Number And Description Of Items Received Signed By The Procuring Entity’s Representative At The Project Site; (iii)certificate Of Acceptance/inspection Report Signed By The Procuring Entity’s Representative At The Project Site; For Purposes Of The Contract, “exw (extra Work),” “fob (“free On Board” Shipping Point),” “fca (“free Carrier” Shipping Point),” “cif (cost Insurance And Freight.),” “cip (carriage And Insurance Paid),” “ddp (delivered Duty Paid)” And Other Trade Terms Used To Describe The Obligations Of The Parties Shall Have The Meanings Assigned To Them By The Current Edition Of Incoterms Published By The International Chamber Of Commerce, Paris. The Delivery Terms Of This Contract Shall Be As Follows: The Delivery Terms Applicable To This Contract Are Ddp Delivered To Supply Office, Leyte Regional Prison, Abuyog, Leyte. Risk And Title Will Pass From The Supplier To The Procuring Entity Upon Receipt And Final Acceptance Of The Goods At Their Final Destination.” Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi (schedule Of Requirements). For Purposes Of This Clause The Procuring Entity’s Representative At The Project Site Is The Lrp Health And Welfare Services Section Chief As The End-user. All Medical Supplies Must Be Delivered On Working Days And Not Later Than 1:00pm, Forty-five (45) Calendar Days From The Receipt Of Notice To Proceed. Incidental Services – The Supplier Is Required To Provide All Of The Following Services, Including Additional Services, If Any, Specified In Section Vi. Schedule Of Requirements: The Contract Price For The Goods Shall Include The Prices Charged By The Supplier For Incidental Services And Shall Not Exceed The Prevailing Rates Charged To Other Parties By The Supplier For Similar Services. Packaging – The Supplier Shall Provide Such Packaging Of The Goods As Is Required To Prevent Their Damage Or Deterioration During Transit To Their Final Destination, As Indicated In This Contract. The Packaging Shall Be Sufficient To Withstand, Without Limitation, Rough Handling During Transit And Exposure To Extreme Temperatures, Salt And Precipitation During Transit, And Open Storage. Packaging Case Size And Weights Shall Take Into Consideration, Where Appropriate, The Remoteness Of The Goods’ Final Destination And The Absence Of Heavy Handling Facilities At All Points In Transit. The Packaging, Marking, And Documentation Within And Outside The Packages Shall Comply Strictly With Such Special Requirements As Shall Be Expressly Provided For In The Contract, Including Additional Requirements, If Any, Specified Below, And In Any Subsequent Instructions Ordered By The Procuring Entity. The Outer Packaging Must Be Clearly Marked On At Least Four (4) Sides As Follows: Name Of The Procuring Entity Name Of The Supplier Contract Description Final Destination Gross Weight Any Special Lifting Instructions Any Special Handling Instructions Any Relevant Hazchem Classifications A Packaging List Identifying The Contents And Quantities Of The Package Is To Be Placed On An Accessible Point Of The Outer Packaging If Practical. If Not Practical The Packaging List Is To Be Placed Inside The Outer Packaging But Outside The Secondary Packaging. Additional Requirements On Box Or Bottle, Blister Packs, Inhaler And Tube. The Following Is Legibly Imprinted Or Stamped In Any Color. Date Of Manufacture __________________ Date Of Expiry ___________________ Transportation – Where The Supplier Is Required Under Contract To Deliver The Goods Cif (cost Insurance And Freight.), Cip (carriage And Insurance Paid), Or Ddp (delivered Duty Paid), Transport Of The Goods To The Port Of Destination Or Such Other Named Place Of Destination In The Philippines, As Shall Be Specified In This Contract, Shall Be Arranged And Paid For By The Supplier, And The Cost Thereof Shall Be Included In The Contract Price. Where The Supplier Is Required Under This Contract To Transport The Goods To A Specified Place Of Destination Within The Philippines, Defined As The Project Site, Transport To Such Place Of Destination In The Philippines, Including Insurance And Storage, As Shall Be Specified In This Contract, Shall Be Arranged By The Supplier, And Related Costs Shall Be Included In The Contract Price. Where The Supplier Is Required Under Contract To Deliver The Goods Cif (cost Insurance And Freight.), Cip (carriage And Insurance Paid), Or Ddp (delivered Duty Paid), Goods Are To Be Transported On Carriers Of Philippine Registry. In The Event That No Carrier Of Philippine Registry Is Available, Goods May Be Shipped By A Carrier Which Is Not Of Philippine Registry Provided That The Supplier Obtains And Presents To The Procuring Entity Certification To This Effect From The Nearest Philippine Consulate To The Port Of Dispatch. In The Event That Carriers Of Philippine Registry Are Available But Their Schedule Delays The Supplier In Its Performance Of This Contract The Period From When The Goods Were First Ready For Shipment And The Actual Date Of Shipment The Period Of Delay Will Be Considered Force Majeure. The Procuring Entity Accepts No Liability For The Damage Of Goods During Transit Other Than Those Prescribed By Incoterms For Ddp Deliveries. In The Case Of Goods Supplied From Within The Philippines Or Supplied By Domestic Suppliers Risk And Title Will Not Be Deemed To Have Passed To The Procuring Entity Until Their Receipt And Final Acceptance At The Final Destination. Intellectual Property Rights – The Supplier Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 2.1 Partial Payment Is Not Allowed 4 The Inspections And Tests That Will Be Conducted Are: Partial/complete Delivery Of Goods Shall Be Inspected By The Lrp Inspection And Acceptance Committee. Inspection And Acceptance Will Be Conducted By The Lrp Inspection And Acceptance Committee To The Actual Delivery At The Project Site (lrp). Goods With Defect Or Non-compliant With The Required Specifications As Stipulated In The Approved Purchase Order/technical Specifications Shall Be Rejected And Shall Be Replaced By The Supplier Free Of Cost To The Procuring Entity Within Seven (7) Calendar Days The Goods Shall Be Accepted By The End User After Passing The Inspection Of The Lrp Inspection And Acceptance Committee. The Inspections And Tests That Will Be Conducted Are; 1.) Upon Delivery, The Goods Shall Undergo Physical Inspection By The Lrp Inspection And Acceptance Committee Of The Procuring Entity To Ascertain The Physical Condition And Acceptability Of The Goods. 2.) Actual Counting Inspection To Determine The Quantity And Completeness Of The Medical Supplies Delivered In Accordance To The Schedule Of Requirements Set In The Bidding Documents.

Details: Amendment 0004: amendment 0004 Is Issued To Extend The Sf 330 Submission Date Regarding N0016425r1025. amendment 0003: amendment 0003 Is Issued To Provide Answers To Industry Questions Received Thus Far Regarding N0016425r1025. amendment 0002: amendment 0002 Is Issued To Provide Answers To Industry Questions Received Thus Far Regarding N0016425r1025. amendment 0001: amendment 0001 Is Issued To Provide Answers To Industry Questions Received Thus Far Regarding N0016425r1025. original Posting: n0016425r1025 Indefinite Delivery/indefinite Quantity (idiq) Contract For Multi‐ Discipline Architect‐engineer (a‐e) Services In Support Of Naval Surface Warfare Center Crane Division (nswc Crane) Facilities Projects At Naval Support Activitys Crane (nsa Crane), Crane, Indiana And Lake Glendora Test Facility (lgtf), Sullivan In. description: All Information Needed For Interested Parties To Submit A Standard Form Sf 330, Architect Engineer Qualifications Is Contained Herein. There Is No Separate Request For Proposals (rfp) Package To Download. related Notices: N0016422snb83, N0016424snb55, N0016424r1025, N0016424snc12, N0016425snb08 background: the Naval Surface Warfare Center Crane Division (nswc Crane) Requires A-e Services In Support Of Various Projects At Nsa Crane And Lgtf. This Procurement Will Result In One Single-award Idiq Contract For Multi‐discipline A‐e Services For Planning, Design, Construction, Evaluation Of New Construction, And Renovation Projects. These Services Will Be Procured In Accordance With 40 United States Code (usc) Chapter 11, Selection Of Architects And Engineers, As Implemented By Federal Acquisition Regulation (far) Subpart 36.6. The Idiq Contract Will Be For A Five-year Ordering Period. This Is A Five-year Contract, With No Option Years. The Maximum Value For The Contract Term, Including All Awards, Shall Not Exceed $12,000,000. There Will Be No Minimum Dollar Limit Per Order And The Maximum Dollar Limit Per Order Will Be $5m In Compliance With The $9m Fy24 Ndaa Prescription. The Guaranteed Minimum For The Contract Ordering Period Is $5,000 And Will Be Satisfied By Simultaneous Award Of The Initial Task Order With The Basic Contract. Firm‐fixed Price Task Orders Will Be Negotiated At The Task Order Level. In Accordance With Dfars Subpart 236.6, The Contract Price Or The Estimated Cost And Fee For Production And Delivery Of Designs, Plans, Drawings, And Specifications Shall Not Exceed Ten (10) Percent Of The Estimated Construction Cost Of The Public Work Or Construction, Excluding Fees. there Will Be No Minimum Dollar Limits Per Task Order. The Estimated Award Date Is October 2025. this Proposed Contract Is Anticipated To Be A Full And Open Procurement. The North American Industry Classification System (naics) Code Is 541330, Engineering Services, And The Small Business Size Standard Is $25,500,000. The Product And Services Code (psc) Is C219 Architect And Engineering- General: Structural Engineering. The Government Seeks The Most Highly Qualified Firm To Perform The Required Services, Based On The Demonstrated Competence And Qualifications, In Accordance With The Selection Criteria Included Herein. comprehensive A‐e Services Are Required For The New Construction, Repair, Replacement, Demolition, Alteration, And/or Improvement Of Facility Projects. Projects May Include Single Or Multiple Disciplines, Such As: Structural, Civil, Mechanical, Electrical, Architectural, Planning, Environmental, Fire Protection, Cost Estimating, And/or Geotechnical. The Types Of Projects May Include: Building Renovations; Building Additions; Site Work Required To Support New Work; New Construction; Parking Areas; Foundations; Retaining Walls; Failure Investigation Including Destructive And Non‐destructive Testing; Seismic Evaluation And Design; Progressive Collapse Analysis; Blast Resistant Design; Structural Engineering Investigations; Utility Systems Including sanitary And Storm; Water Systems; Electrical Power Systems, Storm Water Management; Surveying; Pavement Design; And Civil Engineering Studies. the Selected Offeror Will Be Solely Responsible For The Designs Produced On The Resulting Task Order Contracts And Will Be Recorded As The Designer Of Record. The Successful Offeror Shall Also Be Accountable And Responsible For Contributions To Design-build Rfp Preparation And All Other Requirement Submittals To The Government. in Accordance With Far 36.604 And The Supplements Thereto, And Upon Final Acceptance Or Termination, All Task Orders Above $35,000 Will Receive A Performance Evaluation. A Performance Evaluation May Be Prepared For Lesser Task Orders And Interim Performance Evaluations May Be Prepared At Any Time. Performance Evaluations Will Be Maintained For Use In Future Source Selections For Architect-engineer Services. performance Location(s): crane, Indiana sullivan, Indiana requirements: for Complete Details On This Requirement See Attachment 1, “statement Of Work (sow).” Specific Types Of A‐e Services That May Be Required Under This Contract Include: facility Planning And Project Development: Services May Include Work Such As The Following: Prepare Master Plans, Project/site Plans For Proposed Facility/infrastructure Projects. Facility Planning May Be Requested For Renovation, Addition, Repair And New Construction Projects. development Of Design‐bid‐build (dbb) Packages: Services May Include Preparation Of Drawings And Specifications For Renovation, Addition, Repair Or New Construction Projects. Design Meetings With The Government May Be Required In Order To Agree On Design Solution(s) That Meet The Government’s Project Requirements. Electronic Document Delivery Details Will Be Specified At The Order Level. Electronic Delivery Shall Include Both .pdf And .dwg Formats. development Of Design‐build (db) Request For Proposal (rfp) Packages: Services May Include Working With A Construction Manager As Part Of A Design-build Team To Prepare Drawings And Specifications For Renovation, Additions, Repair Or New Construction Projects. Design Meetings With The Government May Be Required In Order To Agree On Design-build Solution(s) That Meet The Government’s Project Requirements. Electronic Document Delivery Details Will Be Specified At The Order Level. Electronic Delivery Shall Be Include Both .pdf And .dwg Formats. preparation Of Cost Estimates Using Unit Guidance, Parametric Methodologies, And Detailed Cost Estimating: Services May Include Preparing Cost Estimates To Include Rough Order Of Magnitude Through Construction Working Estimates For Renovation, Addition, Repair And/or New Construction Projects Based On Prepared Design Documents, As Called Out In The Task Order. development Of Alternatives And Economic Analysis: Service May Include Providing Alternate Design Solutions And Associated Economic Impacts For Renovation, Addition, Repair Or New Construction Projects. condition Assessment: Services May Include Performing Studies Of Existing Buildings And/or Components Of Buildings To Validate Existing Conditions That May Then Be Used To Inform Future Proposed Design Solutions. Site Visits May Be Required To Document Existing Facility/infrastructure Conditions. field Investigations (including Utility And Geotechnical): Services May Include Conducting Field Surveys/investigations Of Existing Sites, Buildings Or Specific Components Of A Building (i.e., Hvac Or Electrical Systems) In Order To Document Current Status Of A Facility’s Infrastructure. The Results Of Any Field Investigations May Then Be Used To Assist With The Preparation Of Design Documents For A Particular Project. surveying And Mapping: Services May Include Surveying And/or Mapping Of Existing Or Proposed Sites For A New Construction Project Or Building Addition. Survey Work May Be Required In Order To Document Existing Site Conditions To Support Site/civil Design Solutions. preparation Of Engineering Evaluations: Services May Include Performing Engineering Calculations To Support Civil, Mechanical, Electrical, Plumbing Or Fire Protection Design Solutions. incorporation Of Sustainable Engineering Design Practices: Services May Include Incorporation Of Design Principles For Renovation, Addition, Repair And/or New Construction Projects To Support Sustainable Design Solutions And/or Leadership In Energy And Environmental Design (leed) Certification. consultations: Services May Include Collaborating With Other Specialty Design Professionals To Offer And Propose Design Solutions Required To Respond To Unique Project Requirements. energy Computations: Services May Include Preparation Of Energy Calculations To Verify Proposed Design Solutions Comply With Required Building Codes, Federal, State And/or Local Energy Requirements. geotechnical Investigations: Services May Include Conducting Soil Boring Testing In Order To Identify Minimum Design Requirements For New Construction Projects Or Building Additions. obtaining Permits And Regulatory Approvals: Services May Include Submitting Design Documents To Local, State And/or Federal Jurisdictions For Review And Approval Prior To Proceeding With Renovation/construction Work. environmental Investigation And Consultation: Services May Include Providing Design Services Required To Meet Environmental/epa Regulations On Facility/infrastructure Projects And Providing Consultation(s)/collaboration With The Government To Discuss Acceptable Environmental Design Alternatives And Solutions. review Of Construction Contractor Submittals: Services May Include Review Of Project Submittals (such As Product Data Or Product Samples) In Order To Validate Proposed Materials/products Comply With Design Drawings And/or Specifications. field Consultation And Inspection During Construction: Services May Include Responding To Contractor Requests For Information (rfis) During Construction In Order To Address Design Questions That May Arise During Construction/renovation Projects. commissioning: Services May Include Supporting The Commissioning Process By Attending Commissioning Meetings In Order To Validate Engineered Design Solutions Are Incorporated Into The Project In Accordance With Design Specifications. operation And Maintenance Support Information (omsi): Services May Include Providing The Government With O&m Documentation And Training, Where Applicable, Based On The Final Design Solution And Construction. Electronic Document Delivery Details Shall Be Included With Each Order. Electronic Delivery Shall Include Both .pdf And .dwg Formats. as‐built Drawing Preparation: Services May Include Updating Design Documents Including Drawings And Specifications To Accurately Reflect Construction Field Changes And Document Final As-built Construction/renovation Projects. Electronic Document Delivery Details Shall Be Included With Each Order. Electronic Delivery Shall Include Both .pdf And .dwg Formats functional Analysis Concept Development (facd)/design Charrette/other Design And Construction Related Workshops And Meetings: Contractor Shall Attend Design Meetings To Collaborate With Government Representatives To Consider Design Options And Build Consensus Regarding Preferred Design Solution(s). Contractor Shall Provide Meeting Minutes (cdrl A005). document Deliverable Requirements: cdrl did Number did Title did Description/scope deliverable Schedule a001 di-misc-80508b technical Report - Study/services studies And Specifications at Milestone/ Asreq a002 di-fncl-81116 Not 2 manhour Estimate, Technical Cost Proposals manpower And Cost Estimate To Implement The Statement Of Work (sow) at Milestone a003 di-mgmt-80061a Not 2 engineering And Technical Services Accomplishment Report production Report weekly a004 di-misc-81274 Not 2 environmental Permits outlines Submittal Procedures To Be Applied To All Permits asreq a005 di-admn-81250c meeting Minutes meeting Minutes 2 Days After Meeting a006 di-mgmt-81597 personnel Resumes contractor’s Personnel Roster With Relevant Qualifications And Certifications post Award Kickoff a007 di-mgmt-80507 project Planning Chart schedule post Award Kick Off a008 di-admn-81249c meeting Agenda meeting Agenda 1 Day Before Meeting a009 di-facr-82278 installation Design Package designs And Drawings asreq other Special Considerations: as Defined By Paragraph 1‐5 Of United Facilities Criteria (ufc) 3‐ 600‐01, Fire Protection Engineering For Facilities, This Contract Requires The Services Of A Licensed Fire Protection Engineer Or Consultant. asbestos And/or Lead‐based Paint Assessments May Be Required On This Contract To Determine The Presence Of Hazardous Material During Removals/demolition Or At Utility Points Of Connections. Work On And Around Waterfront Structures, Including Under Deck And Underwater, And Work In Confined Spaces May Be Required On This Contract. A‐e Firms Must Be Able To Accept Work That Involves Asbestos, Lead Paint, Poly‐chlorinated Biphenyls (pcbs), And Other Hazardous Materials, Work On And Under Waterfront Structures, And In Confined Spaces. all Engineering And Design Services Shall Comply With The Most Current Edition Of Facilities Criteria (fc) 1‐300‐09n Design Procedures, And Other Requirements As Indicated On The Whole Building Design Guide (wbdg) Web Site (www.wbdg.org). The Selected A-e Contractor Shall Have Online Access To Web‐based Support Programs Capable Of Creating Auto-cad Documents For Government Review, And Email Via The Internet For Routine Exchange Of Correspondence. The Selected A-e Contractor Shall Submit And Maintain An A‐e Accident Prevention Plan (app) In Accordance With U.s. Army Corp Of Engineers (usace) Em 385‐1‐1 For Each Project On This Contract And Activity Hazard Analysis (aha) For Each In‐field Action. Key Personnel, Including Consultants, Must Be U.s. Citizens. a‐e Firms Are Advised That The Selected Firm, Its Subsidiaries Or Affiliates, And Its Consultants Which Design, Prepare, Or Provide Engineering Services In Support Of Construction Contract Documents Cannot Provide Construction Services For The Same Contract. This Includes Concept Design, Preparation Of Project Programming Documents (dd Form 1391), Facility Siting Studies, Environmental Assessments, Geotechnical Services, Engineering Studies And Services, Design‐build Request For Proposals (rfps), Or Other Activities That Result In Identification Of Project Scope And Cost. The Awarded Contract Will Be Subject To Specific Provisions Addressing The Avoidance Of Organizational Conflicts Of Interest, Including H-209-h003, Required Disclosure Of Organizational Conflict Of Interest (navsea) (nov 2022). The Prime Firm For This Contract Will Be Required To Perform Throughout The Contract Term. in Accordance With Far 19.702, Each Solicitation Of Offers To Perform A Contract That Is Expected To Exceed $750,000 ($1.5 Million For Construction) And That Has Subcontracting Possibilities, Shall Require The Apparently Successful Offeror To Submit An Acceptable Small Business Subcontracting Plan. If The Apparently Successful Offeror Fails To Negotiate A Subcontracting Plan Acceptable To The Contracting Officer Within The Time Limit Prescribed By The Contracting Officer, The Offeror Will Be Ineligible For Award. submission Requirements: submission Requirements - Sf 330 Part I typed, 12 Point Times New Roman, Shall Not Exceed 100 Single‐sided 8.5 By 11 Inch Pages criterion criterion Title criterion Requirements criterion 1 specialized Experience sf 330, Part I, Section F - Minimum Of Three (3) And Maximum Of Five (5) Projects Completed (project Completion To Be Defined As Receiving Final Design Acceptance From Client) Within The Past Seven (7) Years criterion 2 professional Qualifications And Technical Competence sf 330, Part I, Section E – Resumes For All Proposed Key Personnel That Illustrate Experience In The Type Of Work Proposed Under This Contract. Resumes Are Limited To Three Pages And Should Indicate: Professional Registration, Certification, Licensure And/or Accreditation In Appropriate Disciplines; Cite Recent (within The Past 10 Years) Project‐specific Experience In Work Relevant To The Services Required Under This Contract; And Indicate Proposed Role In This Contract. Indicate Participation Of Key Personnel In Example Projects In The Sf 330, Part I, Section G. criterion 3 past Performance submit A Completed Cpars/acass/ppq Evaluation For Each Project Under Criterion 1 criterion 4 quality Control describe The Quality Control Program That Will Be Utilized For All Deliverables Of This Contract And The Management Approach For Quality Control Processes And Procedures. criterion 5 program Management And Capacity 1. Provide An Organizational Chart For The Team And Discuss The Management Plan For This Contract And Personnel Roles In The Organization. Include Small Business Participation Specifics. 2. Describe The Firm’s Present Workload And The Availability Of The Project Team (including Consultants) For The Specified Contract Performance Period. 3. Describe The Firm’s Ability To Sustain The Loss Of Key Personnel While Accomplishing Work Within Required Time Limits, To Ensure Continuity Of Services And Ability To Meet Surges In Unexpected Project Demands And Ability To Adhere To Schedules And Budgets. criterion 6 knowledge Of General Geographic Area 1. Indicate Location Of The Office(s) That Will Be Performing The Work, Including Main Offices, Branch Offices, And Offices Of Team Members. 2. Provide A Narrative Describing The Team’s Knowledge And Previous Experience Of The Primary Geographic Areas To Be Covered By This Contract. 3. Provide A Narrative To Describe The Team’s Ability To Provide Timely Response To Requests For On‐site Support. criterion 7 volume Of Work firms Shall Not Submit Data For This Factor. a‐e Firms Desiring To Be Considered For This Contract Shall Submit A Completed Sf 330 Package By Dod Safe To The Contracting Officer And The Contract Specialist. The Sf 330 Shall Be Typed, 12 Point Times New Roman. Part I Shall Not Exceed 100 Single‐sided 8.5 By 11 Inch Pages (the 100 Page Limit Does Not Include The First Eight (8) Instructional Pages Of The Sf 330, Individual Subcontracting Reports (isrs), The Small Business Subcontracting Plan Or Certificates/licenses, Nor Does The Page Limit Include Cover Sheets Or Dividers, Provided That These Do Not Contain Any Substantive Information Submitted In Response To The Synopsis Or Intended To Demonstrate The Qualifications Of The Firm). Part I Pages Shall Be Numbered Sequentially. Introductions Shall Be Included In Sections E And F. A-e Firm Submissions Shall Include Its Unique Entity Identifier (uei), Commercial And Government Entity (cage), And Taxpayer Identification Number (tin) Numbers In Block 30 Of The Sf 330. submissions To This Proposal Announcement Must Be Submitted Electronically Through Dod Safe. No Paper Copies, Email, Cd-roms Or Facsimile Submissions Will Be Accepted. Electronic Proposal Submission Is Required Through The Army’s Electronic File Sharing Service, Dod Safe (https://safe.apps.mil). The Dod Safe Application Is Used To Send Large Files To Individuals That Would Normally Be Too Large To Send Via Email. There Are No User Accounts For Dod Safe. Authentication Is Handled Via Email. anyone Has Access To Dod Safe And The Application Is Available For Use By Anyone. The Dod Safe “getting Started Guide” Has Information On How To Utilize The System (https://safe.apps.mil/about.php). Instructions For Uploading Are As Follows: send An Email To The Contracting Officer And Contract Specialist To Receive The Link To Drop Off Your Proposal. This Will Need To Be Completed Five (5) Business Days Prior To The Proposal Due Date. contract Specialist, Aaron Hohl, Aaron.m.hohl.civ@us.navy.mil contracting Officer, Jared Myers, Jared.s.myers3.civ@us.navy.mil . you Will Receive An Email With The Link To Submit Your Drop Off. The Link Will Be Provided No Later Than Two (2) Business Days Prior To The Proposal Due Date. short Note To The Recipients: Click The Add Files Or Drag And Drop Your Files. For File Description, Enter N0016425r1025-firmname. click Upload Button To Send Documents. guest Users Will Need To Check Their Email To Verify Their Email Address Before The Recipients Will Be Notified. (government-issued Common Access Cards (cacs) Are Not Required). file Size Limitations: Offerors Are Advised To Follow The Dod Safe Instruction For Uploading Files. Dod Safe Supports Delivery Up To 8gb. If Needed, Offerors Are Advised To Break The Files Down To Smaller Sections In Order To Upload It To The System. In Such Cases, Please Divide The Sections As Logically As Possible And Be Sure To Clearly Name The Files As Specified Below. file Naming Convention: To Ensure Your Submission Is Received And Processed Appropriately, It Is Important That Interested Parties Carefully Ensure Their Electronic Files Adhere To The Following Naming Convention: xxx- Firmname- Volume I xxx- Firmname- Volume Ii each File Name Shall Begin With The Solicitation Number Followed By The Firm’s Name And A Brief File Description. Please See Examples Above. file Organization: Although Hard Copies Are Not Accepted, Each File Shall Be Clearly Indexed, And Logically Assembled. Font Size Shall Be 12 Or Larger. Pages Shall Be Letter Sized (larger Page Sizes (such As 11x17 Foldouts, Etc.) Will Be Counted As One Page. Proposals Shall Be In Narrative Format, Organized, And Titled So That Each Section Of The Proposal Follows The Order And Format Of The Criterion. Information Presented Should Be Organized So As To Pertain To Only The Evaluation Factor In The Section That The Information Is Presented. Information Pertaining To More Than One Evaluation Factor Should Be Repeated In Each Section For Each Factor. upload Completion And Deadline: Interested Offerors Shall Submit Proposals No Later Than The Date And Time Specified In This Synopsis. The Time And Date Of The Proposal Receipt Will Be Upload Completion/delivery Time And Date Recorded Within Dod Safe Site. Do Not Assume That Electronic Submission Will Occur Instantaneously. Large Files (e.g. 10mb Or More) Will Take Some Time To Upload. Offerors Should Time Their Upload Effort With Prudence By Not Waiting Until The Last Few Minutes- This Will Allow For Unexpected Delays In The Transmittal Process. Offerors Are Encouraged To Keep A Copy Of The Upload Confirmation For Their Record. Submissions After The Deadline Will Be Considered Late And Will Be Processed In Accordance With Far 15.208. electronic Files: Files Shall Be In Their Native Format (i.e .,.docx, .xlsx, .ppt, Etc.), Or If In .pdf Format, Shall Be In Searchable Text. Text And Graphics Portfolios Of The Electronic Copies Shall Be In A Format Readable By Microsoft Office Or Adobe Applications. Data Submitted In A Spreadsheet Format Shall Be Readable By Ms Excel (all Cells And Formulars Shall Be Unlocked). all Contractors Are Advised That Registration In System For Award Management (sam) Database Is Required Prior To Award Of A Contract. Failure To Register In The Sam Database May Render Your Firm Ineligible For Award. For More Information, Check The Sam Web Site: Https://www.sam.gov. the Technical Data Package May Contain Information That Is Export Controlled. Only Those Companies That Have Completed Dd Form 2345 And Are Certified Under The Joint Certification Program (jcp) In An Active Status Are Authorized To Receive Export Controlled Information. Only Jcp Certified Firms Will Be Eligible For Any Future Award Made Related To This Effort. Additional Information About Jcp Is Available At Https://www.dla.mil/hq/logisticsoperations/services/jcp/. offerors Shall Restrict The Disclosure Or Use Of Its Proposal, (and) A Proper Legend Must Be Included On Materials Provided. Individual Subcontractor/vendor Proprietary Information May Be Submitted Separately. In Addition, If Proposal Volumes Include Technical Requirements That Have Been Identified As Cui, The Markings Shall Apply To The Technical Information Included In The Technical Volume. offeror Shall Mark Proposal Documents As Cui In Accordance With Nist Sp 800-171. Possible Categories For Use Include But Are Not Limited To The Following: cui Category: General Proprietary Business Information https://www.archives.gov/cui/registry/category-detail/proprietary-business-info.html#authority-list banner Marking For Specified Authorities: Cui//sp-propin banner Marking For Basic Authorities: Cui category Description: material And Information Relating To, Or Associated With, A Company's Products, Business, Or Activities, Including But Not Limited To Financial Information; Data Or Statements; Trade Secrets; Product Research And Development; Existing And Future Product Designs And Performance Specifications. *at A Minimum Technical Proposals Shall Safeguard In Accordance With Markings And Distributions Statements On All Technical Documents Within The Solicitation (sow, Specification, Drawings, Etc.). cui Category: Controlled Technical Information* https://www.archives.gov/cui/registry/category-detail/controlled-technical-info.html#authority-list banner Marking: Cui//sp-cti category Description: controlled Technical Information Means Technical Information With Military Or Space Application That Is Subject To Controls On The Access, Use, Reproduction, Modification, Performance, Display, Release, Disclosure, Or Dissemination. Controlled Technical Information Is To Be Marked With One Of The Distribution Statements B Through F, In Accordance With Department Of Defense Instruction 5230.24, "distribution Statements Of Technical Documents." The Term Does Not Include Information That Is Lawfully Publicly Available Without Restrictions. "technical Information" Means Technical Data Or Computer Software, As Those Terms Are Defined In Defense Federal Acquisition Regulation Supplement Clause 252.227-7013, "rights In Technical Data - Noncommercial Items" (48 Cfr 252.227-7013). Examples Of Technical Information Include Research And Engineering Data, Engineering Drawings, And Associated Lists, Specifications, Standards, Process Sheets, Manuals, Technical Reports, Technical Orders, Catalog-item Identifications, Data Sets, Studies And Analyses And Related Information, And Computer Software Executable Code And Source Code. category Marking: cti *at A Minimum Technical Proposals Shall Safeguard In Accordance With Markings And Distributions Statements On All Technical Documents Within The Solicitation (sow, Specification, Drawings, Etc.). cui Category: General Procurement And Acquisition https://www.archives.gov/cui/registry/category-detail/procurement-acquisition.html#authority-list banner Marking: Cui//sp-procure category Description: material And Information Relating To, Or Associated With, The Acquisition And Procurement Of Goods And Services, Including But Not Limited To, Cost Or Pricing Data, Contract Information, Indirect Costs And Direct Labor Rates. category Marking: procure cui Category: Source Selection https://www.archives.gov/cui/registry/category-detail/source-selection banner Marking For Specified Authorities: Cui//sp-ssel banner Marking For Basic Authorities: Cui category Description: per Far 2.101: Any Of The Following Information That Is Prepared For Use By An Agency For The Purpose Of Evaluating A Bid Or Proposal To Enter Into An Agency Procurement Contract, If That Information Has Not Been Previously Made Available To The Public Or Disclosed Publicly: (items 1-10). category Marking: ssel each Volume Submitted Shall Be Properly Marked With At A Minimum Ssel As Follows: a Cover Page Including The “cui” Marking In The Header And Footer As Required, As Well As The Requiredcui Designator Block If The Volume Contains Cui. This Designator Block Shall Be Included At The Bottom Right Portion Of The Cover Page And Read As Follows: controlled By: Department Of The Navy controlled By: Nswc Crane Code 02 cui Category: Propin/cti/procure/ssel distribution/dissemination Control: Fedcon poc: Nswccr 0253 Branch Head all Subsequent Pages Of The Document Shall Include The “cui” Marking In The Header And Footer. If Other Information Is Included In The Header Or Footer, The "cui" Marking Shall Be Centered On Its Own Line Within The Header And Footer. in Accordance With The Federal Acquisition Regulations (far) 36.601-4(b), The A-e Firm Must Be A Professional A-e Firm Permitted By Law To Practice The Professions Of Architecture Or Engineering In The State Of Indiana. This Requirement Can Be Achieved By Providing The Firm’s Indiana Secretary Of State Registration, And Currently Employing At Least Two (2) State Of Indiana Registered A-e Professionals. A-e Firms Shall Provide Proof That The Firm Is Permitted By Law To Practice The Professions Of Architecture Or Engineering In Indiana (e.g., Indiana Secretary Of State Registration And Employee’s State Of Indiana Professional Engineering License With Stamp Or State Of Indiana Registered Architect License With Stamp). Failure To Submit The Required Proof Will Result In A Firm’s Elimination From Consideration. all Businesses Intending To Conduct Business In Indiana, Except Sole Proprietors And General Partnerships, Must Register With The Indiana Secretary Of State. If A Business Needs To Be Registered, Please Do So At Www.inbiz.in.gov. jv Offerors Must Ensure That Both Entities Are Either State Registered Individually In Accordance With The Information Above, Or State Registered As A Jv In Accordance With The Information Above. only Those Companies That Have Completed Dd Form 2345 And Are Certified Under The Joint Certification Program (jcp) In An Active Status Are Authorized To Receive Export-controlled Information. Only Jcp Certified Firms Will Be Eligible For Any Future Award Made Related To This Effort. please Provide A-e Professional Licensure Proof Within Sf 330, Part I, Section E. Please Provide Secretary Of State Registration Information Within Sf 330, Part I, Section H. please Provide Jcp Registration Specifics Within Sf 330, Part I, Section E. Include Jcp Certification Number, Jcp Status, And Jcp Expiration Date. If Currently Working To Acquire Jcp Certification, You May Provide A Brief Explanation Of Your Firm’s Progress Towards Certification. However, Only Actively Jcp Certified Firms Will Be Eligible For Award. Jcp Active Status Will Be Confirmed Via Https://www.public.dacs.dla.mil/jcp/ext/ On The Day Of Proposal Submission. firms Must Also Acknowledge All Amendments To The Solicitation Within Their Proposal. A Statement Of Amendment Acknowledgement Within Sf 330, Part I, Section H Will Suffice. Please Address Individual Amendments Along With Corresponding Date Of Issuance On Sam.gov With Your Proposal. A Signed Copy Of The Amendments Is Not Required. if An Sf 254/sf 255 Is Submitted For This Request, It Will Not Be Reviewed Or Considered. As Required Above, Provide Verifiable Evidence That Your Firm Is Permitted By Law To Practice The Professions Of Architecture Or Engineering (e.g., State Registration Number). interested Firms Shall Submit Proposals To Both The Contract Specialist And The Contracting Officer Via Dod Safe. sf 330 Submissions Are Due No Later Than 9 January 2025 At 12:00 Pm (est). Late Responses Will Be Handled In Accordance With Federal Acquisition Regulations (far) 52.215‐1. The Points Of Contact For This Acquisition Are Contract Specialist, Aaron Hohl, At Aaron.m.hohl.civ@us.navy.mil And Jared Myers, Contracting Officer, At Jared.s.myers3.civ@us.navy.mil. inquiries Concerning This Procurement Should Reference The Solicitation Number (n0016425r1025) And Title And Be Forwarded Via Email To The Points Of Contact Identified Above. Questions Pertaining To This Requirement Are Due No Later Than Fourteen (14) Days After Posting Of This Requirement In Sam.gov. list Of Attachments: statement Of Work (sow) cdrls past Performance Questionnaire (ppq) key Personnel Criteria dd 254 selection Criteria: firms Responding To This Special Notice Will Be Evaluated To Determine The Most Highly Qualified Firms To Perform The Required Services In Accordance With The Published Selection Criteria. failure To Comply With Instructions Or Provide Complete Information May Affect The Firm’s Evaluation Or Disqualify The Firm From Further Consideration. Evaluation Criteria (1) Through (4) Are Considered Most Important And Are Equal Among Themselves; Criteria (5) Through (6) Are Less Important And Are Equal Among Themselves; Criteria (7) Will Only Be Used As A Tie‐breaker Among Technically Equal Firms. Specific Selection Criteria Include: specialized Experience professional Qualifications And Technical Competence past Performance quality Control program Management And Capacity knowledge Of General Geographic Area volume Of Work (no Data Submission Required) criterion 1 —specialized Experience (sf 330, Part I, Section F): firms Will Be Evaluated On Specialized Experience In Performance Of Services Similar To Those Anticipated Under This Contract Through Evaluation Of Experience In: infrastructure/facility Design Utilizing The Following Criteria, Including, But Not Limited To, Unified Facilities Criteria (ufcs) And Military Standard (milstd); conducting On‐site Design Development Workshops, Charrettes, Functional Analysis, Schematic Design, Or Space Programming, Including Supporting Budgetary Or Parametric Cost Estimating; demonstrated Ability To Design To Project Budget And Schedule; experience Preparing Design‐bid‐build; experience Preparing Design‐build Rfp Packages; And designing Projects In Accordance With Dod, Navy, Or Other Government Agencies’ Criteria. use Of Specsintact For Package Generation And Submittal To The Government specialized Design Experience To Include Antiterrorism Force Protection (atfp), Seismic Design And Analysis, And Design Of Secure Spaces firms May Be Considered More Favorably Under Criterion 1 By Demonstrating The Following: demonstrated Experience On Military Bases Within The Primary Geographic Area Of The Contract. experience In The Delivery Of Multiple Types Of A‐e Services Identified In The Requirements Above. experience On Multiple Facility Types, Such As Business, Educational, Industrial, Assembly, Health Care, Residential, Storage, Laboratory, And Mixed-use Occupancies, Identified In The Requirements Above. demonstrated Experience Using Rsmeans-based (or Equal) Electronic Cost Estimating Software. demonstrated Experience Designing Modifications To Existing Structures And Developing Construction Phasing While Associated Facilities Are Required To Remain In Service. demonstrated Experience Specific To Navy Facility Projects, Illustrating The Capability Of The A‐e Firm And Individual Design Team Members (a‐e Staff, Key Personnel, Consultants) To Work Within The Navy Project Planning Process Including: dd Form 1391 Development In The Navy’s Electronic Procurement Generator (epg), dd Form 1391 Validation Procedures Including Cost Validation. demonstrated Understanding Of Procedures And Timely Submission Of Base Access Documents In Adherence With Security, Safety, Environmental, And Accident Prevention Regulations In Order To Support A‐e Activities And Maintain Project Schedules. experience Of A‐e Firm And Individual Design Team Members (a‐e Staff, Key Personnel, Sub‐ Consultants) With Facilities Located In Historic Areas That Will Require Consultation With State Historic Preservation Officer (shpo) Throughout The Design Process. criterion 1 Submission Requirements: provide Up To A Minimum Of Three (3) And Maximum Of Five (5) Projects Completed (project Completion To Be Defined As Receiving Final Design Acceptance From Client) Within The Past Seven (7) Years Immediately Preceding The Date Of Issuance Of This Notice That Best Demonstrate Specialized Experience Of The Proposed Team In The Areas Outlined Above. Sufficient Information To Determine The Date Of Completion Of The Project Must Be Included In The Project Description Or The Project Will Not Be Considered. If More Than The Maximum Number Of Projects Is Submitted, The Government Will Only Evaluate Projects Up To The Maximum Number Authorized In The Order Submitted. all Projects Provided In The Sf 330 Must Be Completed By The Actual Office/branch/regional Office/ Individual Team Member Proposed To Manage And Perform Work Under This Contract. Projects Not Meeting This Requirement Will Be Excluded From Consideration In The Evaluation. To Enable Verification, Firms Should Include The Uei And Cage Along With Each Firm Name In The Sf 330 Part I, Section F, Block 25, “firm Name.” Include A Contract Number Or Project Identification Number In Block 21. Include An E‐mail Address And Phone Number For The Point Of Contact In Block 23(c). In Block 24, Include In The Project Description The Contract Period Of Performance, Award Contract Value, Current Contract Value, And A Summary Of The Work Performed That Demonstrates Relevance To Specialized Experience As Outlined Above. For Projects Performed As A Sub-contractor Or A Joint Venture Involving Different Partners, Specifically Indicate The Value Of The Work Performed As A Subcontractor Or By Those Firms Proposed For This Contract, And Identify The Specific Roles And Responsibilities Performed As A Sub-contractor Or By Those Firms On The Project Rather Than The Work Performed On The Project As A Whole. If The Project Description Does Not Clearly Delineate The Work Performed By The Entity/entities Offering/teaming On This Contract, The Firm Will Be Eliminated From Award Consideration. note: If The Firm Is A Joint Venture, Projects Performed By The Joint Venture Should Be Submitted; However, If There Are No Projects Performed By The Joint Venture, Projects Must Be Submitted For Each Joint Venture Partner, Not To Exceed A Total Of Five (5) Projects For Both Partners Combined. Each Partner Within A Jv May Not Be Responsible For More Than Three (3) Projects Within The Past Performance Submission. Firms Failing To Provide Projects From All Joint Venture Partners Will Be Considered To Have Not Met The Requirements Of The Criterion. projects Shall Be Submitted On The Sf 330 At Part I, Section F And Shall Be Completed Projects. Projects Not Completed Will Be Excluded From Evaluation Consideration. For Submittal Purposes, A Task Order On An Idiq Contract Is Considered A Project, As Is A Stand‐alone Contract Award. Do Not Submit An Idiq Base Contract As An Example Project. Instead, List Relevant Task Orders Or Stand‐ Alone Contract Awards That Fit Within The Definition Above. The Government Will Not Evaluate Information Provided For An Idiq Contract. Examples Of Project Work Submitted That Do Not Conform To This Requirement Will Not Be Evaluated. all Information For Criterion 1 Shall Be Submitted In The Sf 330, Part I, Section F. The Government Will Not Consider Information Submitted In Addition To Part I, Section F In The Evaluation Of Criterion 1. criterion 2—professional Qualifications And Technical Competence (sf 330, Part I, Sections E & G): films Will Be Evaluated On Professional Qualifications, Competence, And Experience Of The Proposed Key Personnel In Providing Services To Accomplish The Tasks Required Under This Contract, Including Participation In Example Projects In The Sf 330, Part I, Section G. Key Personnel Are Individuals Who Will Have Major Contract Or Project Management Responsibilities And/or Will Provide Unusual Or Unique Expertise. Specific Disciplines That Must Be Included In Key Personnel Are: project Manager, Registered Architect Or Professional Engineer, 10 Years quality Control Specialist, Architect Or Professional Engineer, 15 Years architect, Senior, Registered Architect, 15 Years architect, Junior, Registered Architect, 10 Years civil Engineer, Senior, Registered Professional Engineer, 15 Years civil Engineer, Junior, Registered Professional Engineer, 10 Years structural Engineer, Senior, Registered Professional Engineer, 15 Years structural Engineer, Junior, Registered Professional Engineer, 10 Years mechanical Engineer, Senior, Registered Professional Engineer, 15 Years mechanical Engineer, Junior, Registered Professional Engineer, 10 Years electrical Engineer, Senior, Registered Professional Engineer, 15 Years electrical Engineer, Junior, Registered Professional Engineer, 10 Years registered Communication Distribution Design (rcdd), 15 Years fire Protection Engineer, Registered Professional Engineer, 15 Years cost Estimator, Certified Cost Professional Or Equivalent, 15 Years key Personnel, Including Consultants, Shall Be U.s. Citizens. submissions Must Demonstrate Key Personnel Relevant Experience, Formal Education (e.g. Bachelor’s Or Master’s Degrees), And Relevant Professional Development Or Professional Certifications. See Key Personnel Attachment For Specific Qualification Criteria. If An Offeror Is Unable To Meet Key Personnel Requirement List In Its Entirety, The Government Still Urges A Response For Consideration Which Illustrates The Firm’s Maximum Personnel Capabilities. If Certain Key Personnel Roles Cannot Be Fulfilled, Please Indicate Those Role Vacancies Individually With A Course Of Action For Fulfillment. criteria 2 Submission Requirements: sf 330, Part I, Section E – Provide Resumes For All Proposed Key Personnel That Illustrate Experience In The Type Of Work Proposed Under This Contract. Resumes Are Limited To Three (3) Single-sided Pages And Should Indicate: Professional Registration, Certification, Licensure And/or Accreditation In Appropriate Disciplines To Include Document/licensure Numbers; Cite Recent (within The Past 10 Years) Project‐specific Experience In Work Relevant To The Services Required Under This Contract; And Indicate Proposed Role In This Contract. Indicate Participation Of Key Personnel In Example Projects In The Sf 330, Part I, Section G. The Firm Must Hold A Current And Active License In The State Of Indiana As Well As Currently Employ At Least Two (2) State Of Indiana Registered A-e Professionals. offeror Will Not Be Permitted To Simultaneously Fulfill Multiple Roles With An Individual On The Same Project. The Individuals Identified As Key Personnel On The Sf330 May Not Have Multiple Duties Or Be “dual-hatted.” Offerors Shall Provide Individual Resumes In Sf330 Section E For Each Of The Individuals Listed Above. criterion 3—past Performance (sf 330, Part I, Section H): firms Will Be Evaluated On Past Performance With Government Agencies And Private Industry In Terms Of Work Quality, Compliance With Schedules, Cost Control, And Stakeholder/customer Satisfaction. evaluating Past Performance And Experience Will Include Information Provided In The Contract performance Assessment Reporting System (cpars) / Architect-engineer Contract Administration Support System (acass) Or A Completed Past Performance Questionnaire (ppq) For Criterion 1 Projects And May Include Customer Inquiries, Government Databases, And Other Information Available To The Government Including Contacts With Points Of Contact In Other Criteria. Failure To Provide Requested Data, Accessible Points Of Contact, Or Valid Phone Numbers Could Result In A Firm Being Considered Less Qualified. criteria 3 Submission Requirements: submit A Completed Cpars/acass/ppq Evaluation For Each Project Under Criterion 1. firms May Provide Any Information On Problems Encountered And The Corrective Actions Taken On Projects Submitted Under Criterion 1—specialized Experience. Firms May Also Address Any Adverse Past Performance Issues. Information For Each Past Performance Submission Shall Not Exceed Five Single‐sided Pages In Total. offeror Shall Submit One (1) Past Performance Questionnaire Provided As An Attachment To This Synopsis To Each Of Its Customer Pocs Identified In Criterion 1 For Referenced Projects With No Cpars/acass Available. In Order To Expedite The Assessment Process, The Offeror May Complete The “contract Information” Portion Of The Past Performance Questionnaire For The Convenience Of The Customer Poc. A Ppq Submission Is Not Required For Criterion 1 Projects Accompanied By A Cpars/acass. However, A Ppq Submission For Every Criterion 1 Project, Including Those With A Cpars/acass Evaluation On Record, Would Assist The Government In Evaluation Accuracy And Is Encouraged. the Offeror Shall Not, However, Complete Any Other Section Of The Past Performance Questionnaire. The Questionnaire Shall Be Provided To The Customer Poc With Instructions To Complete And Submit It Directly To The Contracting Officer And/or The Point Of Contact Identified In This Announcement On Or Before The Proposal Due Date. Electronic Submission Via Encrypted E-mail By The Customer Is Required. under No Circumstances Shall The Questionnaires Be Returned To The Offerors After Completion. Any Information Provided By The Offeror’s References Is Subject To Verification/validation By The Government During The Evaluation Process. The Government May Make Contact And Follow Up With The Listed References Identified On The Contractor Past Performance Data Documents/data. The Offeror May Provide Information On Problems Encountered On The Identified Contracts As Well As The Offeror’s Corrective Actions. The Government Reserves The Right To Solicit Feedback Beyond What Is Identified In The Questionnaire. awards, Letters Of Commendation, Certificates Of Appreciation, Etc., Shall Not Be Submitted And Will Not Be Considered In The Evaluation. criterion 4—quality Control Program (sf 330, Part I, Section H): firms Will Be Evaluated On The Strength Of The Quality Control Program Proposed By The Firm To Ensure Quality Products And Services Under This Contract And Means Of Ensuring Quality Services From Their Consultants/subcontractors. criteria 4 Submission Requirements: describe The Quality Control Program That Will Be Utilized For All Deliverables Of This Contract And The Management Approach For Quality Control Processes And Procedures. The Description Shall: describe Specific Quality Control Processes And Procedures Proposed For This Contract To Achieve Technical Accuracy Of And Assurance Of Overall Coordination Of Plans And Specifications, And Engineering And Design Services. provide A Quality Control Process Chart Showing The Inter‐relationship Of The Management And Team Components. identify The Key Personnel (submitted Under Criterion 2—professional Qualifications And Technical Competence) Responsible For The Quality Control Program And A Description Of Their Roles And Responsibilities. describe How The Firm’s Quality Control Program Extends To Management Of Sub-contractors. explain The Quality Control Program Including An Example Of How The Plan Has Worked For One Of The Projects Submitted As Part Of Sf 330, Section F Or How The Plan Will Work If It Has Not Been Used Previously. criterion 5—program Management And Capacity (sf 330, Part I, Section H): firms Will Be Evaluated On The Firm’s Ability To Plan For And Manage Work Under The Contract And The Capacity To Accomplish The Work In The Required Time. criteria 5 Submission Requirements: provide An Organizational Chart For The Team And Discuss The Management Plan For This Contract And Personnel Roles In The Organization. Describe The Ability Of The Firm To Manage, Coordinate And Work Effectively With Team Members, Both Internal Staff, Sub- Contractors And Consultants. Discuss The History Of Working Relationships With Team Members, Including Joint Venture Partners Where Applicable. describe The Firm’s Present Workload And The Availability Of The Project Team (including Consultants) For The Specified Contract Performance Period. Describe The Workload/availability Of The Key Personnel During The Anticipated Contract Performance Period And The Ability Of The Firm To Provide Qualified Backup Staffing For Key Personnel To Ensure Continuity Of Services. General Statements Of Availability/capacity May Be Considered Less Favorably. describe The Firm’s Ability To Sustain The Loss Of Key Personnel While Accomplishing Work Within Required Time Limits, To Ensure Continuity Of Services And Ability To Meet Surges In Unexpected Project Demands And Ability To Adhere To Schedules And Budgets. include Small Business Subcontracting Plan Specifics Which Detail Level Of Participation Of Small Business, Small Disadvantaged Business, Woman-owned Small Business, Hubzone Small Business, Service-disabled Veteran-owned Small Business And Veteran Owned Small Business Team Members. attach A Small Business Subcontracting Plan Which Estimates The Proposed Extent Of Participation Of Small Business, Small Disadvantaged Business, Woman-owned Small Business, Hubzone Small Business, Service-disabled Veteran-owned Small Business And Veteran Owned Small Business Team Members In The Contract Team. Clearly Specify Each Small Business Firm That Is A Team Member, Their Small Business Category, And Their Proposed Level Of Participation Measured As A Percentage Of The Overall Estimated Effort. The Small Business Subcontracting Plan Draft Will Not Count Against The Total Page Count Limitation For The Firm’s Response. The Small Business Subcontracting Plan Should Be Included As An Attachment To The Sf 330 Response. Small Business Subcontracting Plan Specifics May Be Referenced Within The Sf 330 Response, But The Subcontracting Plan Should Also Be Attached In Its Entirety. criterion 6— Knowledge Of General Geographic Area (sf 330, Part I, Section H) firms Will Be Evaluated On The Locations Of Their Office Or Offices That Will Be Performing The Work Under This Contract And Demonstrated Knowledge Of The General Geographic Areas In Which Projects Could Be Located. Evaluation Of Firms Will Include Consideration Of Their Location Within The General Geographic Area Of The Anticipated Projects (primarily At Naval Surface Warfare Center Crane Division, Crane, In). criteria 6 Submission Requirements: indicate Location Of The Office(s) That Will Be Performing The Work, Including Main Offices, Branch Offices, And Offices Of Team Members. provide A Narrative Describing The Team’s Knowledge And Previous Experience Of The Primary Geographic Areas To Be Covered By This Contract. provide A Narrative To Describe The Team’s Ability To Provide Timely Response To Requests For On‐site Support. Provide Timelines And Examples Of The Team’s Success In Providing This Response. Include Both Primary And Sub‐contractor Support As Required. Teams With A Demonstrated History Of Providing Timely Support May Be Considered More Favorably. criterion 7—volume Of Work (sf 330, Part 1, Section H) (tie-breaker) in The Event Of A Tie Among Equally Rated Firms, Those Firms Will Be Evaluated In Accordance With Dod Federal Acquisition Regulation Supplement (dfars) Procedures, Guidance And Information (pgi) 236.602‐1, From Data Extracted From The Federal Procurement Data System (fpds). Firms Will Be Evaluated In Terms Of Work Previously Awarded To The Firm By Dod Within The Past Twelve (12) Months With The Objective Of Effecting An Equitable Distribution Of Contracts Among Qualified A‐e Firms Including Small, Disadvantaged Business Firms, And Firms That Have Not Had Prior Dod A‐e Contracts. criterion 7 Submission Requirements: firms Shall Not Submit Data For This Factor.

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Supply & Delivery Of Hardware/materials For The Improvement/rehabilitation Of Brgy. San Isidro Communal Irrigation System 1. The Local Government Unit Of Irosin, Through The Mdrrmo(5% Calamity Fund) Intends To Apply The Sum Of Six Hundred Eighty Six Thousand Four Hundred Two Pesos (p 686,402.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Supply & Delivery Of Hardware/materials For The Improvement/rehabilitation Of Brgy. San Isidro Communal Irrigation System, Good-03-2025. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Supply & Delivery Of Hardware/materials For The Improvement/rehabilitation Of Brgy. San Isidro Communal Irrigation System Brief Description: 549.26 Kgs 16mm Diam Rsb/618.28 Kgs 12mm Diam Rsb/20kgs #16 Tie Wire/20 Pcs Hacksaw Blade/58 Pcs ½” Thk. Penolic Board/3000 Bd.ft. Coco Lumber/175 Kgs Assorted Cw Nail/96 Cu.m. Boulder/696 Bags Portland Cement/88 Cu.m. Washed Sand/22 Cu.m. Gravel Pea-size Approved Budget For The Contract : P 686,402.00 Contract Duration : 30 Calendar Days Delivery Period : 7 Calendar Days After The Issuance Of Notice To Proceed Source Of Fund : Mdrrmo(5% Calamity Fund) 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Delivery Of The Goods Is Required By Seven(7) Calendar Days. Bidders Should Have Completed For The Last Two(2) Years From The Date Of Submission And Receipt Of Bids, A Contract Similar To The Project. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). Bidding Is Restricted To Filipino Citizens/sole Proprietorships, Partnerships, Or Organizations With At Least Sixty Percent(60%) Interest Or Outstanding Capital Stock Belonging To Citizens Of The Philippines, And To Citizens Or Organizations Of A Country The Laws Or Regulations Of Which Grant Similar Rights Or Privileges To Filipino Citizens, Pursuant To Ra No. 5183. 4. Prospective Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 21, 2025 Until January 28, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of One Thousand Pesos (p 1,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Not Hold A Pre-bid Conference. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before January 28, 2025, 8:59 Am At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On January 28, 2025, 9:00 Am At The Given Address Below At The Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Benjamin M. Gabionza,ce/fritzie Riva L. Michelena Mun. Engineer/mdrrmo Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Publication: January 21, 2025 _____________________ Noel D. Mercado Ii Bac Chairman Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Supply & Delivery Of Hardware/materials For The Improvement/rehabilitation Of Brgy. San Isidro Communal Irrigation System With Project Identification Number Good-03-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website. The Procurement Project (referred To Herein As “project”) Is Composed Of 1 Lot Hardware/materials, The Details Of Which Are Described In Section Vii (technical Specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below For Mdrrmo(5% Calamity Fund) In The Amount Of Six Hundred Eighty Six Thousand Four Hundred Two Pesos (p 686,402.00). 2.2. The Source Of Funding Is: Six Hundred Eighty Six Thousand Four Hundred Two Pesos (p 686,402.00) 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Requirements Of This Project, Including Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Suppliers, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. A.foreign Ownership Exceeding Those Allowed Under The Rules May Participate Pursuant To: Iii. When The Goods Sought To Be Procured Are Not Available From Local Suppliers; Or B. Foreign Ownership Limited To Those Allowed Under The Rules May Participate In This Project. 5.3. Pursuant To Section 23.4.1.3 Of The 2016 Revised Irr Of Ra No. 9184, The Bidder Shall Have An Slcc That Is At Least One(1) Contract Similar To The Project The Value Of Which, Adjusted To Current Prices Using The Psa’s Cpi, Must At Least Equivalent To: A. For The Procurement Of Non- Expandable Supplies And Services: The Bidder Must Have Completed A Single Contract That Is Similar To This Project, Equivalent To At Least Fifty Percent (50%) Of The Abc. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un, Subject To Domestic Preference Requirements Under Itb Clause 18. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Twenty Percent (20%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.2 Subcontracting Is Not Allowed During The Bidding. 7.3 Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.4 Subcontracting Of Any Portion Of The Project Does Not Relieve The Supplier Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Not Hold A Pre-bid Conference. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 10.2. The Bidder’s Slcc As Indicted In Itb Clause 5.3 Should Have Completed Within The Last Two(2) Years Prior To The Deadline For The Submission And Receipt Of Bids. 10.3. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. Similar To The Required Authentication Above, For Contracting Parties To The Apostile Convention, Only The Translated Documents Shall Be Authenticated Through The Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 11.2. If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity, A Certification From Dti Shall Be Provided By The Bidder In Accordance With Section 43.1.3 Of The 2016 Revised Irr Of Ra No. 9184. 11.3. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.4. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 3184. 12. Bid Prices 12.1 Prices Indicated On The Price Schedule Shall Be Entered Separately In The Following Manner: A.for Goods Offered From Within The Procuring Entity’s Country: I. The Price Of The Goods Quoted Exw(ex-works,ex-factory,ex-warehouse,ex-showroom, Or Off The Shelf, As Applicable); Ii. The Cost Of All Custom Duties And Sales And Other Taxes Already Paid Or Payable; Iii. The Cost Of Transportation, Insurance, And Other Costs Incidental To Delivery Of The Goods To Their Final Destination; And Iv. The Price Of Other(incidental) Services, If Any, Listed In The Bds. 13. Bid And Payment Currencies 14.1. For Goods That The Bidder Will Supply From Outside The Philippines, The Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Adopted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreigh Currencies, Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 14. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 15. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 16. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 17. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 18. Domestic Preference 18.1 The Procuring Entity Will Grant A Margin Of Preference For The Purpose Of Comparison Of Bids In Accordance With Section 43.1.2 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, Bidders May Submit A Proposal On Any Of The Lots Or Items And Evaluation Will Be Undertaken On A Per Lot Or Item Basis, As The Case Maybe. In This Case, The Bid Security As Required By Itb Clause 14 Shall Be Submitted For Each Lot Or Item Separately. 19.3. The Descriptions Of The Lots Or Items Shall Be Indicated In Section Vii(technical Specifications), Although The Abcs Of These Lots Or Items Are Indicated In The Bds For Purposes Of The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184. The Nfcc Must Be Sufficient For The Total Of The Abcs For All The Lots Or Items Participated In By The Prospective Bidder. 19.4. The Project Shall Be Awarded As Follows: Option 1- One Project Having Several Items That Shall Be Awarded As One Contract. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.3 For This Purpose, Contracts Similar To The Project Shall Be: A. Supply & Delivery Of Hardware/materials For The Improvement/rehabilitation Of Brgy. San Isidro Communal Irrigation System Brief Description: 549.26 Kgs 16mm Diam Rsb/618.28 Kgs 12mm Diam Rsb/20kgs #16 Tie Wire/20 Pcs Hacksaw Blade/58 Pcs ½” Thk. Penolic Board/3000 Bd.ft. Coco Lumber/175 Kgs Assorted Cw Nail/96 Cu.m. Boulder/696 Bags Portland Cement/88 Cu.m. Washed Sand/22 Cu.m. Gravel Pea-size B. Completed Within The Last Two(2) Years From The Date Of The Submission Of Bids 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 12 The Price Of Goods Shall Be Quoted Ddp Lgu-irosin, Irosin, Sorsogon. 14.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.3 Hardware/materials 549.26 Kgs 16mm Diam Rsb/618.28 Kgs 12mm Diam Rsb/20kgs #16 Tie Wire/20 Pcs Hacksaw Blade/58 Pcs ½” Thk. Penolic Board/3000 Bd.ft. Coco Lumber/175 Kgs Assorted Cw Nail/96 Cu.m. Boulder/696 Bags Portland Cement/88 Cu.m. Washed Sand/22 Cu.m. Gravel Pea-size 20.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: None General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. Additional Requirements For The Completion Of This Contract Shall Be Provided In The Special Conditions Of Contract(scc). 2. Advance Payment 2.1 Advance Payment Of The Contract Amount Is Provided Under Annex “d” Of The Revised 2016 Irr Of Ra No. 9184. 2.2 The Procuring Entity Is Allowed To Determine The Terms Of The Payment On The Partial Or Staggered Delivery Of The Goods Procured, Provided Such Partial Payment Shall Correspond To The Value Of The Goods Delivered And Accepted In Accordance With Prevailing Accounting And Auditing Rules And Regulations. The Terms Of Payment Are Indicated In The Scc. 3. Performance Security Within Ten (10) Calendar Days From Receipt Of The Notice Of Award By The Bidder From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 4. Inspection And Tests The Procuring Entity Or Its Representatives Shall Have The Right To Inspect And/or The Test The Goods To Confirm Their Conformity To The Project. In Addition To Tests In The Scc, Section Vii(technical Specifications) Shall Specify What Inspections And/or Tests The Procuring Entity Requires, And Where They Are To Be Conducted. The Procuring Entity Shall Notify The Supplier In Writing, In A Timely Manner, Of The Identify Of Any Representatives Retained For These Purposes. All Reasonable Facilities And Assistance For The Inspection And Testing Of Goods, Including Access To Drawings And Production Data, Shall Be Provided By The Supplier To The Authorized Inspectors At No Charge To The Procuring Entity. 5. Warranty 7.1. In Order To Assure The Manufacturing Defects Shall Be Corrected By The Supplier, A Warranty Shall Be Required From The Supplier As Provided Under Section 62.1 Of The 2016 Revised Irr Of Ra No. 9184. 7.2. The Procuring Entity Shall Promptly Notify The Supplier In Writing Of Any Claims Arising Under This Warranty. Upon Receipt Of Such Notice, The Supplier Shall, Repair Or Replace The Defective Goods Or Parts Thereof Without Cost To The Procuring Entity, Pursuant To The Generic Procurement Manual. 6. Liability Of The Supplier The Supplier’s Liability Under This Contract Shall Be Provided By The Laws Of The Republic Of The Philippines. If The Supplier Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. Special Conditions Of Contract Gcc Clause 1 Delivery And Documents – For Purposes Of The Contract, “exw,” “fob,” “fca,” “cif,” “cip,” “ddp” And Other Trade Terms Used To Describe The Obligations Of The Parties Shall Have The Meanings Assigned To Them By The Current Edition Of Incoterms Published By The International Chamber Of Commerce, Paris. The Delivery Terms Of This Contract Shall Be As Follows: [for Goods Supplied From Within The Philippines] “the Delivery Terms Applicable To This Contract Are Delivered [indicate Place Of Destination]. Risk And Title Will Pass From The Supplier To The Procuring Entity Upon Receipt And Final Acceptance Of The Goods At Their Final Destination.” Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi (schedule Of Requirements). For Purposes Of This Clause The Procuring Entity’s Representative At The Project Site Is Wilson G. Baliwas. Incidental Services – The Supplier Is Required To Provide All Of The Following Services, Including Additional Services, If Any, Specified In Section Vi. Schedule Of Requirements: A. Performance Or Supervision Of On-site Assembly And/or Start-up Of The Supplied Goods; B. Furnishing Of Tools Required For Assembly And/or Maintenance Of The Supplied Goods; C. Furnishing Of A Detailed Operations And Maintenance Manual For Each Appropriate Unit Of The Supplied Goods; D. Performance Or Supervision Or Maintenance And/or Repair Of The Supplied Goods, For A Period Of Time Agreed By The Parties, Provided That This Service Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And E. Training Of The Procuring Entity’s Personnel, At The Supplier’s Plant And/or On-site, In Assembly, Start-up, Operation, Maintenance, And/or Repair Of The Supplied Goods. F. No Additional Incidental Service Requirements. The Contract Price For The Goods Shall Include The Prices Charged By The Supplier For Incidental Services And Shall Not Exceed The Prevailing Rates Charged To Other Parties By The Supplier For Similar Services. Spare Parts – The Supplier Is Required To Provide All Of The Following Materials, Notifications, And Information Pertaining To Spare Parts Manufactured Or Distributed By The Supplier: 1. Such Spare Parts As The Procuring Entity May Elect To Purchase From The Supplier, Provided That This Election Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And 2. In The Event Of Termination Of Production Of The Spare Parts: I. Advance Notification To The Procuring Entity Of The Pending Termination, In Sufficient Time To Permit The Procuring Entity To Procure Needed Requirements; And Ii. Following Such Termination, Furnishing At No Cost To The Procuring Entity, The Blueprints, Drawings, And Specifications Of The Spare Parts, If Requested. The Spare Parts And Other Components Required Are Listed In Section Vi (schedule Of Requirements) And The Costs Thereof Are Included In The Contract Price. The Supplier Shall Carry Sufficient Inventories To Assure Ex-stock Supply Of Consumable Spare Parts Or Components For The Goods For A Period Of Ninety (90) Calendar Days. Spare Parts Or Components Shall Be Supplied As Promptly As Possible, But In Any Case, Within Ninety (90) Calendar Days Of Placing The Order. Packaging – The Supplier Shall Provide Such Packaging Of The Goods As Is Required To Prevent Their Damage Or Deterioration During Transit To Their Final Destination, As Indicated In This Contract. The Packaging Shall Be Sufficient To Withstand, Without Limitation, Rough Handling During Transit And Exposure To Extreme Temperatures, Salt And Precipitation During Transit, And Open Storage. Packaging Case Size And Weights Shall Take Into Consideration, Where Appropriate, The Remoteness Of The Goods’ Final Destination And The Absence Of Heavy Handling Facilities At All Points In Transit. The Packaging, Marking, And Documentation Within And Outside The Packages Shall Comply Strictly With Such Special Requirements As Shall Be Expressly Provided For In The Contract, Including Additional Requirements, If Any, Specified Below, And In Any Subsequent Instructions Ordered By The Procuring Entity. The Outer Packaging Must Be Clearly Marked On At Least Four (4) Sides As Follows: Name Of The Procuring Entity Name Of The Supplier Contract Description Final Destination Gross Weight Any Special Lifting Instructions Any Special Handling Instructions Any Relevant Hazchem Classifications A Packaging List Identifying The Contents And Quantities Of The Package Is To Be Placed On An Accessible Point Of The Outer Packaging If Practical. If Not Practical The Packaging List Is To Be Placed Inside The Outer Packaging But Outside The Secondary Packaging. Transportation – Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip, Or Ddp, Transport Of The Goods To The Port Of Destination Or Such Other Named Place Of Destination In The Philippines, As Shall Be Specified In This Contract, Shall Be Arranged And Paid For By The Supplier, And The Cost Thereof Shall Be Included In The Contract Price. Where The Supplier Is Required Under This Contract To Transport The Goods To A Specified Place Of Destination Within The Philippines, Defined As The Project Site, Transport To Such Place Of Destination In The Philippines, Including Insurance And Storage, As Shall Be Specified In This Contract, Shall Be Arranged By The Supplier, And Related Costs Shall Be Included In The Contract Price. Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip Or Ddp, Goods Are To Be Transported On Carriers Of Philippine Registry. In The Event That No Carrier Of Philippine Registry Is Available, Goods May Be Shipped By A Carrier Which Is Not Of Philippine Registry Provided That The Supplier Obtains And Presents To The Procuring Entity Certification To This Effect From The Nearest Philippine Consulate To The Port Of Dispatch. In The Event That Carriers Of Philippine Registry Are Available But Their Schedule Delays The Supplier In Its Performance Of This Contract The Period From When The Goods Were First Ready For Shipment And The Actual Date Of Shipment The Period Of Delay Will Be Considered Force Majeure. The Procuring Entity Accepts No Liability For The Damage Of Goods During Transit Other Than Those Prescribed By Incoterms For Ddp Deliveries. In The Case Of Goods Supplied From Within The Philippines Or Supplied By Domestic Suppliers Risk And Title Will Not Be Deemed To Have Passed To The Procuring Entity Until Their Receipt And Final Acceptance At The Final Destination. Intellectual Property Rights – The Supplier Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 2.2 Partial Payment Is Not Applicable. 4 The Inspections And Tests That Will Be Conducted Are: Inspection Of The Hardware/materials If It Follows The Technical Specification Set By The End-user Unit. Section Vi. Schedule Of Requirements The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. Item Number Description Quantity Total Delivered, Weeks/months Remarks Indicate Here Any Other Appropriate Information As May Be Necessary. Signature Over Printed Name Position Department/division Section Vii. Technical Specifications Item Specification Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution Subject To The Applicable Laws And Issuances.] Technical Specifications Technical Specifications Item / Service Maximum Quantity Technical Specifications / Scope Of Work Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution.] Checklist Of Technical And Financial Documents I. Technical Component Envelope Class “a” Documents Legal Documents ⬜ (a) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; (b) Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives (c) Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located (d) Tax Clearance Per Eo 398 (e) Tax Clearance For Collection Purposes Technical Documents ⬜ (f) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And ⬜ (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid, Except Under Conditions Provided For In Sections 23.4.1.3 And 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184, Within The Relevant Period As Provided In The Bidding Documents; And ⬜ (d) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And ⬜ (e) Conformity With The Technical Specifications, Which May Include Production/delivery Schedule, Manpower Requirements, And/or After-sales/parts, If Applicable; And ⬜ (f) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. Financial Documents ⬜ (g) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc) Or A Committed Line Of Credit From A Universal Or Commercial Bank In Lieu Of Its Nfcc Computation. (h) Audited Financial Statement(afs) Audited Financial Statement Stamped, Received By The Bir Or Its Duly Accredited And Authorized Institutions, For The Immediately Preceding Calendar Year, Showing The Total Assets And Liabilities Which Should Not Be Earlier Than Two(2) Years From The Date Of Bid Submission Class “b” Documents ⬜ (i) If Applicable, A Duly Signed Joint Venture Agreement (jva) In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (j) Original Of Duly Signed And Accomplished Financial Bid Form; And ⬜ (k) Original Of Duly Signed And Accomplished Price Schedule(s). Other Documentary Requirements Under Ra No. 9184 (as Applicable) ⬜ (l) [for Foreign Bidders Claiming By Reason Of Their Country’s Extension Of Reciprocal Rights To Filipinos] Certification From The Relevant Government Office Of Their Country Stating That Filipinos Are Allowed To Participate In Government Procurement Activities For The Same Item Or Product. ⬜ (m) Certification From The Dti If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity.   Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. ______ To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025. Bid Form For The Procurement Of Goods (shall Be Submitted With The Bid) Bid Form Date: _____________________________ Project Identification No.: _____________ To: [name And Address Of Procuring Entity] Having Examined The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers_____, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Offer To (supply/deliver/perform) (description Of The Goods) In Conformity With The Said Pbds For The Sum Of (total Bid Amount In Words And Figures) Or The Total Calculated Bid Price, As Evaluated And Corrected For Computational Errors , And Other Bid Modifications In Accordance With The Price Schedules Attached Herewith And Made Part Of This Bid. The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To (specify The Applicable Taxes, E.g. (i) Value Added Tax, (ii) Income Tax, (iii) Local Taxes, And (iv) Other Fiscal Levies And Duties), Which Are Itemized Herein Or In The Price Schedules. If Our Bid Is Accepted, We Undertake: A.to Deliver The Goods In Accordance With The Delivery Schedule Specified In The Schedule Of Requirements Of The Philippine Bidding Documents(pbds); B. To Provide A Performance Security In The Form, Amounts, And Within The Times Prescribed In The Pbds; C. To Abide By The Bid Validity Specified In The Pbds And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period. Until A Formal Contract Is Prepared And Executed, This Bid, Together With Your Written Acceptance Thereof And Your Notice Of Award, Shall Be Binding Upon Us. We Understand That You Are Not Bound To Accept The Lowest Calculated Bid Or Any Bid You May Receive. We Certify/conform That We Comply With The Eligibility Requirements Pursuant To The Pbds. The Undersigned Is Authorized To Submit The Bid On Behalf Of (name Of The Bidder) As Evidenced By The Attached (state The Written Authority). We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including, The Attached Schedule Of Prices, Shall Be A Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Goods(revised) __________________________________________________________________________ This Agreement, Made The _________ Day Of _______________, ________ Between [name And Address Of Procuring Entity] Of The Philippines (hereinafter Called The“entity”) Of The One Part And [name Of Supplier] (hereinafter Called The “supplier”) Of The Other Part. Whereas, The Entity Invited Bids For Certain Goods And Ancillary Services, Particularly (brief Description Of Goods And Services) And Has Accepted A Bid By The Supplier For The Supply Of Those Goods And Services In The Sum Of (contract Price In Words And Figures In Specified Currency) (hereinafter Called The “contract Price”). Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: I. Philippine Bidding Documents(pbds) I. Schedule Of Requirements; Ii.technical Specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins, If Any Ii. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Supplier: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Bill Of Quantities Item No. Item Quantity Unit Unit Price Total Price Prepared By: ______________ Proprietor

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Supply & Delivery Of Dietary Supplements For Philippine Multisectoral Nutrition Project(pmnp) 1. The Local Government Unit Of Irosin, Through The Trust Fund(pmnp) Intends To Apply The Sum Of Seven Hundred Thirty Nine Thousand Eight Hundred Thirty One Pesos And Fifty Centavos(p 739,831.50) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Supply & Delivery Of Dietary Supplements For Philippine Multisectoral Nutrition Project(pmnp), Good-02-2025. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Supply & Delivery Of Dietary Supplements For Philippine Multisectoral Nutrition Project(pmnp) Brief Description: 560packs Instant Beef Bulalo With Vegetables 100grms/ 560packs Instant Chicken Arroz Caldo With Vegetables 100grms/ 480packs Instant Chicken Tinola With Malunggay 100grms/ 480packs Instant Champorado 100grms/560packs Chicken Sopas With Vegetables100 Grms/ 480packs Cheese Macaroni Soup 100grms/ 480packs Nutri Oats Sweet Corn 100grms/ 560packs Nutri Mongo And Pasas 100grms/ 560packs Nutricookies Squash 100grms/ 480packs High Protein Biscuits-butter 100grms/ 560packs Nutricookies With Real Strawberries 100grms/ 480packs Vegetables Crackers Malunggay 100grms/ 480packs Nutricookies Lemon 100grms/480 Packs Nutricookines Butter 100grms/ 1350packs Instant Beef Bulalo With Vegetables 60grms/ 1350packs Instant Chicken Arroz Caldo With Vegetables 60grms/ 1350packs Instant Chicken Tinola With Malunggay 6-grms/ 1200packs Instant Champorado 60grms/ 1350packs Ready To Cook Ginataang Monggo With Alugbati 60grms/1200packs Chicken Sopas With Vegetables 60grms/ 1350packs Cheese Macaroni Soup 60grms/ 1200packs Nutri Oats Sweet Corn 60grms/ 4050packs Instant Nutriblend Chocolate 60grms/ 1350packs Nutricookies Squash 60grms/ 1350packs High Protein Biscuits-butter 60grms/ 1350packs Nutricookies With Real Strawberries 60grms/ 1200packs Vegetable Crackers Malunggay 60grms/ 1200packs Nutricookies Lemon 60grms/ 1200packs Nutricookies Butter 60grms Approved Budget For The Contract : P 739,831.50 Contract Duration : 30 Calendar Days Delivery Period : 7 Calendar Days After The Issuance Of Notice To Proceed Source Of Fund : Trust Fund-phic Reimbursement (e-konsulta Package) 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Delivery Of The Goods Is Required By Seven(7) Calendar Days. Bidders Should Have Completed For The Last Two(2) Years From The Date Of Submission And Receipt Of Bids, A Contract Similar To The Project. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). Bidding Is Restricted To Filipino Citizens/sole Proprietorships, Partnerships, Or Organizations With At Least Sixty Percent(60%) Interest Or Outstanding Capital Stock Belonging To Citizens Of The Philippines, And To Citizens Or Organizations Of A Country The Laws Or Regulations Of Which Grant Similar Rights Or Privileges To Filipino Citizens, Pursuant To Ra No. 5183. 4. Prospective Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 8, 2025 Until January 15, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of One Thousand Pesos (p 1,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Not Hold A Pre-bid Conference. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before January 15, 1:59 Pm At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On January 15, 2025, 2:00 Pm At The Given Address Below At The Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Emelyn A. Vidar Mnao Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Publication: January 8, 2025 _____________________ Noel D. Mercado Ii Bac Chairman Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Supply & One(1) Unit Dietary Supplements For Philippine Multisectoral Nutrition Project(pmnp) With Project Identification Number Good-02-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website. The Procurement Project (referred To Herein As “project”) Is Composed Of 1 Lot Dietary Supplements, The Details Of Which Are Described In Section Vii (technical Specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below For Trust Fund Pmnp) In The Amount Of Seven Hundred Thirty Nine Thousand Eight Hundred Thirty One Pesos And Fifty Centavos(p 739,831.50). 2.2. The Source Of Funding Is: Trust Fund(pmnp) 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Requirements Of This Project, Including Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Suppliers, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. A.foreign Ownership Exceeding Those Allowed Under The Rules May Participate Pursuant To: Iii. When The Goods Sought To Be Procured Are Not Available From Local Suppliers; Or B. Foreign Ownership Limited To Those Allowed Under The Rules May Participate In This Project. 5.3. Pursuant To Section 23.4.1.3 Of The 2016 Revised Irr Of Ra No. 9184, The Bidder Shall Have An Slcc That Is At Least One(1) Contract Similar To The Project The Value Of Which, Adjusted To Current Prices Using The Psa’s Cpi, Must At Least Equivalent To: A. For The Procurement Of Non- Expandable Supplies And Services: The Bidder Must Have Completed A Single Contract That Is Similar To This Project, Equivalent To At Least Fifty Percent (50%) Of The Abc. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un, Subject To Domestic Preference Requirements Under Itb Clause 18. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Twenty Percent (20%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.2 Subcontracting Is Not Allowed During The Bidding. 7.3 Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.4 Subcontracting Of Any Portion Of The Project Does Not Relieve The Supplier Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Hold Not A Pre-bid Conference. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 10.2. The Bidder’s Slcc As Indicted In Itb Clause 5.3 Should Have Completed Within The Last Two(2) Years Prior To The Deadline For The Submission And Receipt Of Bids. 10.3. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. Similar To The Required Authentication Above, For Contracting Parties To The Apostile Convention, Only The Translated Documents Shall Be Authenticated Through The Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 11.2. If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity, A Certification From Dti Shall Be Provided By The Bidder In Accordance With Section 43.1.3 Of The 2016 Revised Irr Of Ra No. 9184. 11.3. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.4. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 3184. 12. Bid Prices 12.1 Prices Indicated On The Price Schedule Shall Be Entered Separately In The Following Manner: A.for Goods Offered From Within The Procuring Entity’s Country: I. The Price Of The Goods Quoted Exw(ex-works,ex-factory,ex-warehouse,ex-showroom, Or Off The Shelf, As Applicable); Ii. The Cost Of All Custom Duties And Sales And Other Taxes Already Paid Or Payable; Iii. The Cost Of Transportation, Insurance, And Other Costs Incidental To Delivery Of The Goods To Their Final Destination; And Iv. The Price Of Other(incidental) Services, If Any, Listed In The Bds. 13. Bid And Payment Currencies 14.1. For Goods That The Bidder Will Supply From Outside The Philippines, The Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Adopted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreigh Currencies, Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 14. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 15. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 16. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 17. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 18. Domestic Preference 18.1 The Procuring Entity Will Grant A Margin Of Preference For The Purpose Of Comparison Of Bids In Accordance With Section 43.1.2 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, Bidders May Submit A Proposal On Any Of The Lots Or Items And Evaluation Will Be Undertaken On A Per Lot Or Item Basis, As The Case Maybe. In This Case, The Bid Security As Required By Itb Clause 14 Shall Be Submitted For Each Lot Or Item Separately. 19.3. The Descriptions Of The Lots Or Items Shall Be Indicated In Section Vii(technical Specifications), Although The Abcs Of These Lots Or Items Are Indicated In The Bds For Purposes Of The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184. The Nfcc Must Be Sufficient For The Total Of The Abcs For All The Lots Or Items Participated In By The Prospective Bidder. 19.4. The Project Shall Be Awarded As Follows: Option 1- One Project Having Several Items That Shall Be Awarded As One Contract. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.3 For This Purpose, Contracts Similar To The Project Shall Be: A. Supply & Delivery Of Dietary Supplements For Philippine Multisectoral Nutrition Project(pmnp) Brief Description: 560packs Instant Beef Bulalo With Vegetables 100grms/ 560packs Instant Chicken Arroz Caldo With Vegetables 100grms/ 480packs Instant Chicken Tinola With Malunggay 100grms/ 480packs Instant Champorado 100grms/560packs Chicken Sopas With Vegetables100 Grms/ 480packs Cheese Macaroni Soup 100grms/ 480packs Nutri Oats Sweet Corn 100grms/ 560packs Nutri Mongo And Pasas 100grms/ 560packs Nutricookies Squash 100grms/ 480packs High Protein Biscuits-butter 100grms/ 560packs Nutricookies With Real Strawberries 100grms/ 480packs Vegetables Crackers Malunggay 100grms/ 480packs Nutricookies Lemon 100grms/480 Packs Nutricookines Butter 100grms/ 1350packs Instant Beef Bulalo With Vegetables 60grms/ 1350packs Instant Chicken Arroz Caldo With Vegetables 60grms/ 1350packs Instant Chicken Tinola With Malunggay 6-grms/ 1200packs Instant Champorado 60grms/ 1350packs Ready To Cook Ginataang Monggo With Alugbati 60grms/1200packs Chicken Sopas With Vegetables 60grms/ 1350packs Cheese Macaroni Soup 60grms/ 1200packs Nutri Oats Sweet Corn 60grms/ 4050packs Instant Nutriblend Chocolate 60grms/ 1350packs Nutricookies Squash 60grms/ 1350packs High Protein Biscuits-butter 60grms/ 1350packs Nutricookies With Real Strawberries 60grms/ 1200packs Vegetable Crackers Malunggay 60grms/ 1200packs Nutricookies Lemon 60grms/ 1200packs Nutricookies Butter 60grms B. Completed Within The Last Two(2) Years From The Date Of The Submission Of Bids 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 12 The Price Of Goods Shall Be Quoted Ddp Lgu-irosin, Irosin, Sorsogon. 14.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.3 Dietary Supplements 560packs Instant Beef Bulalo With Vegetables 100grms/ 560packs Instant Chicken Arroz Caldo With Vegetables 100grms/ 480packs Instant Chicken Tinola With Malunggay 100grms/ 480packs Instant Champorado 100grms/560packs Chicken Sopas With Vegetables100 Grms/ 480packs Cheese Macaroni Soup 100grms/ 480packs Nutri Oats Sweet Corn 100grms/ 560packs Nutri Mongo And Pasas 100grms/ 560packs Nutricookies Squash 100grms/ 480packs High Protein Biscuits-butter 100grms/ 560packs Nutricookies With Real Strawberries 100grms/ 480packs Vegetables Crackers Malunggay 100grms/ 480packs Nutricookies Lemon 100grms/480 Packs Nutricookines Butter 100grms/ 1350packs Instant Beef Bulalo With Vegetables 60grms/ 1350packs Instant Chicken Arroz Caldo With Vegetables 60grms/ 1350packs Instant Chicken Tinola With Malunggay 6-grms/ 1200packs Instant Champorado 60grms/ 1350packs Ready To Cook Ginataang Monggo With Alugbati 60grms/1200packs Chicken Sopas With Vegetables 60grms/ 1350packs Cheese Macaroni Soup 60grms/ 1200packs Nutri Oats Sweet Corn 60grms/ 4050packs Instant Nutriblend Chocolate 60grms/ 1350packs Nutricookies Squash 60grms/ 1350packs High Protein Biscuits-butter 60grms/ 1350packs Nutricookies With Real Strawberries 60grms/ 1200packs Vegetable Crackers Malunggay 60grms/ 1200packs Nutricookies Lemon 60grms/ 1200packs Nutricookies Butter 60grms 20.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: None General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. Additional Requirements For The Completion Of This Contract Shall Be Provided In The Special Conditions Of Contract(scc). 2. Advance Payment 2.1 Advance Payment Of The Contract Amount Is Provided Under Annex “d” Of The Revised 2016 Irr Of Ra No. 9184. 2.2 The Procuring Entity Is Allowed To Determine The Terms Of The Payment On The Partial Or Staggered Delivery Of The Goods Procured, Provided Such Partial Payment Shall Correspond To The Value Of The Goods Delivered And Accepted In Accordance With Prevailing Accounting And Auditing Rules And Regulations. The Terms Of Payment Are Indicated In The Scc. 3. Performance Security Within Ten (10) Calendar Days From Receipt Of The Notice Of Award By The Bidder From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 4. Inspection And Tests The Procuring Entity Or Its Representatives Shall Have The Right To Inspect And/or The Test The Goods To Confirm Their Conformity To The Project. In Addition To Tests In The Scc, Section Vii(technical Specifications) Shall Specify What Inspections And/or Tests The Procuring Entity Requires, And Where They Are To Be Conducted. The Procuring Entity Shall Notify The Supplier In Writing, In A Timely Manner, Of The Identify Of Any Representatives Retained For These Purposes. All Reasonable Facilities And Assistance For The Inspection And Testing Of Goods, Including Access To Drawings And Production Data, Shall Be Provided By The Supplier To The Authorized Inspectors At No Charge To The Procuring Entity. 5. Warranty 7.1. In Order To Assure The Manufacturing Defects Shall Be Corrected By The Supplier, A Warranty Shall Be Required From The Supplier As Provided Under Section 62.1 Of The 2016 Revised Irr Of Ra No. 9184. 7.2. The Procuring Entity Shall Promptly Notify The Supplier In Writing Of Any Claims Arising Under This Warranty. Upon Receipt Of Such Notice, The Supplier Shall, Repair Or Replace The Defective Goods Or Parts Thereof Without Cost To The Procuring Entity, Pursuant To The Generic Procurement Manual. 6. Liability Of The Supplier The Supplier’s Liability Under This Contract Shall Be Provided By The Laws Of The Republic Of The Philippines. If The Supplier Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. Special Conditions Of Contract Gcc Clause 1 Delivery And Documents – For Purposes Of The Contract, “exw,” “fob,” “fca,” “cif,” “cip,” “ddp” And Other Trade Terms Used To Describe The Obligations Of The Parties Shall Have The Meanings Assigned To Them By The Current Edition Of Incoterms Published By The International Chamber Of Commerce, Paris. The Delivery Terms Of This Contract Shall Be As Follows: [for Goods Supplied From Within The Philippines] “the Delivery Terms Applicable To This Contract Are Delivered [indicate Place Of Destination]. Risk And Title Will Pass From The Supplier To The Procuring Entity Upon Receipt And Final Acceptance Of The Goods At Their Final Destination.” Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi (schedule Of Requirements). For Purposes Of This Clause The Procuring Entity’s Representative At The Project Site Is Wilson G. Baliwas. Incidental Services – The Supplier Is Required To Provide All Of The Following Services, Including Additional Services, If Any, Specified In Section Vi. Schedule Of Requirements: A. Performance Or Supervision Of On-site Assembly And/or Start-up Of The Supplied Goods; B. Furnishing Of Tools Required For Assembly And/or Maintenance Of The Supplied Goods; C. Furnishing Of A Detailed Operations And Maintenance Manual For Each Appropriate Unit Of The Supplied Goods; D. Performance Or Supervision Or Maintenance And/or Repair Of The Supplied Goods, For A Period Of Time Agreed By The Parties, Provided That This Service Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And E. Training Of The Procuring Entity’s Personnel, At The Supplier’s Plant And/or On-site, In Assembly, Start-up, Operation, Maintenance, And/or Repair Of The Supplied Goods. F. No Additional Incidental Service Requirements. The Contract Price For The Goods Shall Include The Prices Charged By The Supplier For Incidental Services And Shall Not Exceed The Prevailing Rates Charged To Other Parties By The Supplier For Similar Services. Spare Parts – The Supplier Is Required To Provide All Of The Following Materials, Notifications, And Information Pertaining To Spare Parts Manufactured Or Distributed By The Supplier: 1. Such Spare Parts As The Procuring Entity May Elect To Purchase From The Supplier, Provided That This Election Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And 2. In The Event Of Termination Of Production Of The Spare Parts: I. Advance Notification To The Procuring Entity Of The Pending Termination, In Sufficient Time To Permit The Procuring Entity To Procure Needed Requirements; And Ii. Following Such Termination, Furnishing At No Cost To The Procuring Entity, The Blueprints, Drawings, And Specifications Of The Spare Parts, If Requested. The Spare Parts And Other Components Required Are Listed In Section Vi (schedule Of Requirements) And The Costs Thereof Are Included In The Contract Price. The Supplier Shall Carry Sufficient Inventories To Assure Ex-stock Supply Of Consumable Spare Parts Or Components For The Goods For A Period Of Three(3)months. Spare Parts Or Components Shall Be Supplied As Promptly As Possible, But In Any Case, Within Three(3)months Of Placing The Order. Packaging – The Supplier Shall Provide Such Packaging Of The Goods As Is Required To Prevent Their Damage Or Deterioration During Transit To Their Final Destination, As Indicated In This Contract. The Packaging Shall Be Sufficient To Withstand, Without Limitation, Rough Handling During Transit And Exposure To Extreme Temperatures, Salt And Precipitation During Transit, And Open Storage. Packaging Case Size And Weights Shall Take Into Consideration, Where Appropriate, The Remoteness Of The Goods’ Final Destination And The Absence Of Heavy Handling Facilities At All Points In Transit. The Packaging, Marking, And Documentation Within And Outside The Packages Shall Comply Strictly With Such Special Requirements As Shall Be Expressly Provided For In The Contract, Including Additional Requirements, If Any, Specified Below, And In Any Subsequent Instructions Ordered By The Procuring Entity. The Outer Packaging Must Be Clearly Marked On At Least Four (4) Sides As Follows: Name Of The Procuring Entity Name Of The Supplier Contract Description Final Destination Gross Weight Any Special Lifting Instructions Any Special Handling Instructions Any Relevant Hazchem Classifications A Packaging List Identifying The Contents And Quantities Of The Package Is To Be Placed On An Accessible Point Of The Outer Packaging If Practical. If Not Practical The Packaging List Is To Be Placed Inside The Outer Packaging But Outside The Secondary Packaging. Transportation – Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip, Or Ddp, Transport Of The Goods To The Port Of Destination Or Such Other Named Place Of Destination In The Philippines, As Shall Be Specified In This Contract, Shall Be Arranged And Paid For By The Supplier, And The Cost Thereof Shall Be Included In The Contract Price. Where The Supplier Is Required Under This Contract To Transport The Goods To A Specified Place Of Destination Within The Philippines, Defined As The Project Site, Transport To Such Place Of Destination In The Philippines, Including Insurance And Storage, As Shall Be Specified In This Contract, Shall Be Arranged By The Supplier, And Related Costs Shall Be Included In The Contract Price. Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip Or Ddp, Goods Are To Be Transported On Carriers Of Philippine Registry. In The Event That No Carrier Of Philippine Registry Is Available, Goods May Be Shipped By A Carrier Which Is Not Of Philippine Registry Provided That The Supplier Obtains And Presents To The Procuring Entity Certification To This Effect From The Nearest Philippine Consulate To The Port Of Dispatch. In The Event That Carriers Of Philippine Registry Are Available But Their Schedule Delays The Supplier In Its Performance Of This Contract The Period From When The Goods Were First Ready For Shipment And The Actual Date Of Shipment The Period Of Delay Will Be Considered Force Majeure. The Procuring Entity Accepts No Liability For The Damage Of Goods During Transit Other Than Those Prescribed By Incoterms For Ddp Deliveries. In The Case Of Goods Supplied From Within The Philippines Or Supplied By Domestic Suppliers Risk And Title Will Not Be Deemed To Have Passed To The Procuring Entity Until Their Receipt And Final Acceptance At The Final Destination. Intellectual Property Rights – The Supplier Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 2.2 Partial Payment Is Not Applicable. 4 The Inspections And Tests That Will Be Conducted Are: Inspection Of The Hematology Analyzer To Be Delivered And If It Follows The Technical Specification Set By The End-user Unit. Section Vi. Schedule Of Requirements The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. Item Number Description Quantity Total Delivered, Weeks/months 1 Remarks Indicate Here Any Other Appropriate Information As May Be Necessary. Signature Over Printed Name Position Department/division Section Vii. Technical Specifications Item Specification Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution Subject To The Applicable Laws And Issuances.] Technical Specifications Technical Specifications Item / Service Maximum Quantity Technical Specifications / Scope Of Work Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution.] Checklist Of Technical And Financial Documents I. Technical Component Envelope Class “a” Documents Legal Documents ⬜ (a) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; (b) Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives (c) Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located (d) Tax Clearance Per Eo 398 Technical Documents ⬜ (e) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And ⬜ (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid, Except Under Conditions Provided For In Sections 23.4.1.3 And 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184, Within The Relevant Period As Provided In The Bidding Documents; And ⬜ (d) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And ⬜ (e) Conformity With The Technical Specifications, Which May Include Production/delivery Schedule, Manpower Requirements, And/or After-sales/parts, If Applicable; And ⬜ (f) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. Financial Documents ⬜ (g) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc) Or A Committed Line Of Credit From A Universal Or Commercial Bank In Lieu Of Its Nfcc Computation. (h) Audited Financial Statement(afs) Audited Financial Statement Stamped, Received By The Bir Or Its Duly Accredited And Authorized Institutions, For The Immediately Preceding Calendar Year, Showing The Total Assets And Liabilities Which Should Not Be Earlier Than Two(2) Years From The Date Of Bid Submission Class “b” Documents ⬜ (i) If Applicable, A Duly Signed Joint Venture Agreement (jva) In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (j) Original Of Duly Signed And Accomplished Financial Bid Form; And ⬜ (k) Original Of Duly Signed And Accomplished Price Schedule(s). Other Documentary Requirements Under Ra No. 9184 (as Applicable) ⬜ (l) [for Foreign Bidders Claiming By Reason Of Their Country’s Extension Of Reciprocal Rights To Filipinos] Certification From The Relevant Government Office Of Their Country Stating That Filipinos Are Allowed To Participate In Government Procurement Activities For The Same Item Or Product. ⬜ (m) Certification From The Dti If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity.   Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2024 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2024 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2024. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. ______ To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2024 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2024 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2024. Bid Form For The Procurement Of Goods (shall Be Submitted With The Bid) Bid Form Date: _____________________________ Project Identification No.: _____________ To: [name And Address Of Procuring Entity] Having Examined The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers_____, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Offer To (supply/deliver/perform) (description Of The Goods) In Conformity With The Said Pbds For The Sum Of (total Bid Amount In Words And Figures) Or The Total Calculated Bid Price, As Evaluated And Corrected For Computational Errors , And Other Bid Modifications In Accordance With The Price Schedules Attached Herewith And Made Part Of This Bid. The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To (specify The Applicable Taxes, E.g. (i) Value Added Tax, (ii) Income Tax, (iii) Local Taxes, And (iv) Other Fiscal Levies And Duties), Which Are Itemized Herein Or In The Price Schedules. If Our Bid Is Accepted, We Undertake: A.to Deliver The Goods In Accordance With The Delivery Schedule Specified In The Schedule Of Requirements Of The Philippine Bidding Documents(pbds); B. To Provide A Performance Security In The Form, Amounts, And Within The Times Prescribed In The Pbds; C. To Abide By The Bid Validity Specified In The Pbds And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period. Until A Formal Contract Is Prepared And Executed, This Bid, Together With Your Written Acceptance Thereof And Your Notice Of Award, Shall Be Binding Upon Us. We Understand That You Are Not Bound To Accept The Lowest Calculated Bid Or Any Bid You May Receive. We Certify/conform That We Comply With The Eligibility Requirements Pursuant To The Pbds. The Undersigned Is Authorized To Submit The Bid On Behalf Of (name Of The Bidder) As Evidenced By The Attached (state The Written Authority). We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including, The Attached Schedule Of Prices, Shall Be A Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Goods(revised) __________________________________________________________________________ This Agreement, Made The _________ Day Of _______________, ________ Between [name And Address Of Procuring Entity] Of The Philippines (hereinafter Called The“entity”) Of The One Part And [name Of Supplier] (hereinafter Called The “supplier”) Of The Other Part. Whereas, The Entity Invited Bids For Certain Goods And Ancillary Services, Particularly (brief Description Of Goods And Services) And Has Accepted A Bid By The Supplier For The Supply Of Those Goods And Services In The Sum Of (contract Price In Words And Figures In Specified Currency) (hereinafter Called The “contract Price”). Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: I. Philippine Bidding Documents(pbds) I. Schedule Of Requirements; Ii.technical Specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins, If Any Ii. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Supplier: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2024. Bill Of Quantities Item No. Item Quantity Unit Unit Price Total Price Prepared By: ______________ Proprietor

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Supply & Delivery Of One(1) Unit High Volume Low Speed Industrial Ceiling Fan(big Ass) 1. The Local Government Unit Of Irosin, Through The General Fund(capital Outlay) Intends To Apply The Sum Of Five Hundred Thousand Pesos (p 500,000.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Supply & Delivery Of One(1) Unit High Volume Low Speed Industrial Ceiling Fan(big Ass), Good-07-2024. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Supply & Delivery Of One(1) Unit High Volume Low Speed Industrial Ceiling Fan)big Ass) Brief Description: One Unit High Volume Low Speed Industrial Ceiling Fan(big Ass): Diameter:24 Feet(7.3 Meters)/voltage: 230v/3 Phase/motor Rpm: 60/motor Size: 2hp(1.5kw)/material: Aluminum/stainless Steel/fan Weight: 116kg/air Volume: 200-300cfm/airfoils: 8 Patented Powerfoils,8 Patent Pending/air Fences/sealed Gearbox And Industrial Motor/machine-cut Hub System/redundant Safety Features/variable Speed Operation With Controller With Delivery And Installation Works/5 Year Warranty Approved Budget For The Contract : P 500,000.00 Contract Duration : 30 Calendar Days Delivery Period : 7 Calendar Days After The Issuance Of Notice To Proceed Source Of Fund : General Fund(capital Outlay) 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Delivery Of The Goods Is Required By Seven(7) Calendar Days. Bidders Should Have Completed For The Last Two(2) Years From The Date Of Submission And Receipt Of Bids, A Contract Similar To The Project. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). Bidding Is Restricted To Filipino Citizens/sole Proprietorships, Partnerships, Or Organizations With At Least Sixty Percent(60%) Interest Or Outstanding Capital Stock Belonging To Citizens Of The Philippines, And To Citizens Or Organizations Of A Country The Laws Or Regulations Of Which Grant Similar Rights Or Privileges To Filipino Citizens, Pursuant To Ra No. 5183. 4. Prospective Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 31, 2025-february 10, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of Five Hundred Pesos (p 500.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Not Hold A Pre-bid Conference. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before February 10, 2025, 1:59 Pm At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On February 10, 2025, 2:00 Pm At The Given Address Below Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Lorenzo G. Ubalde Municipal Administrator Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Publication: January 31, 2025 _____________________ Noel D. Mercado Ii Bac Chairman ```u Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Supply & Delivery Of One(1) Unit Large Industrial Fan For Lgu-irosin, With Project Identification Number Good-07-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website. The Procurement Project (referred To Herein As “project”) Is Composed Of 1 Lot Large Industrial Ceiling Fan, The Details Of Which Are Described In Section Vii (technical Specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below General Fund(capital Outlay) In The Amount Of Five Hundred Thousand Pesos (p 500,000.00). 2.2. The Source Of Funding Is: General Fund(capital Outlay) 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Requirements Of This Project, Including Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Suppliers, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. A.foreign Ownership Exceeding Those Allowed Under The Rules May Participate Pursuant To: Iii. When The Goods Sought To Be Procured Are Not Available From Local Suppliers; Or B. Foreign Ownership Limited To Those Allowed Under The Rules May Participate In This Project. 5.3. Pursuant To Section 23.4.1.3 Of The 2016 Revised Irr Of Ra No. 9184, The Bidder Shall Have An Slcc That Is At Least One(1) Contract Similar To The Project The Value Of Which, Adjusted To Current Prices Using The Psa’s Cpi, Must At Least Equivalent To: A. For The Procurement Of Expandable Supplies: The Bidder Must Have Completed A Single Contract That Is Similar To This Project, Equivalent To At Least Twenty Five Percent (25%) Of The Abc. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un, Subject To Domestic Preference Requirements Under Itb Clause 18. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Twenty Percent (20%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.2 Subcontracting Is Not Allowed During The Bidding. 7.3 Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.4 Subcontracting Of Any Portion Of The Project Does Not Relieve The Supplier Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Not Hold A Pre-bid Conference For This Project. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 10.2. The Bidder’s Slcc As Indicted In Itb Clause 5.3 Should Have Completed Within The Last Two(2) Years Prior To The Deadline For The Submission And Receipt Of Bids. 10.3. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. Similar To The Required Authentication Above, For Contracting Parties To The Apostile Convention, Only The Translated Documents Shall Be Authenticated Through The Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 11.2. If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity, A Certification From Dti Shall Be Provided By The Bidder In Accordance With Section 43.1.3 Of The 2016 Revised Irr Of Ra No. 9184. 11.3. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.4. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 3184. 12. Bid Prices 12.1 Prices Indicated On The Price Schedule Shall Be Entered Separately In The Following Manner: A.for Goods Offered From Within The Procuring Entity’s Country: I. The Price Of The Goods Quoted Exw(ex-works,ex-factory,ex-warehouse,ex-showroom, Or Off The Shelf, As Applicable); Ii. The Cost Of All Custom Duties And Sales And Other Taxes Already Paid Or Payable; Iii. The Cost Of Transportation, Insurance, And Other Costs Incidental To Delivery Of The Goods To Their Final Destination; And Iv. The Price Of Other(incidental) Services, If Any, Listed In The Bds. 13. Bid And Payment Currencies 14.1. For Goods That The Bidder Will Supply From Outside The Philippines, The Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Adopted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreigh Currencies, Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 14. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 15. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 16. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 17. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 18. Domestic Preference 18.1 The Procuring Entity Will Grant A Margin Of Preference For The Purpose Of Comparison Of Bids In Accordance With Section 43.1.2 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, Bidders May Submit A Proposal On Any Of The Lots Or Items And Evaluation Will Be Undertaken On A Per Lot Or Item Basis, As The Case Maybe. In This Case, The Bid Security As Required By Itb Clause 14 Shall Be Submitted For Each Lot Or Item Separately. 19.3. The Descriptions Of The Lots Or Items Shall Be Indicated In Section Vii(technical Specifications), Although The Abcs Of These Lots Or Items Are Indicated In The Bds For Purposes Of The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184. The Nfcc Must Be Sufficient For The Total Of The Abcs For All The Lots Or Items Participated In By The Prospective Bidder. 19.4. The Project Shall Be Awarded As Follows: Option 1- One Project Having Several Items That Shall Be Awarded As One Contract. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.3 For This Purpose, Contracts Similar To The Project Shall Be: A. Supply & Delivery Of One(1) Unit High Volume Low Speed Industrial Ceiling Fan(big Ass) Brief Description: One Unit High Volume Low Speed Industrial Ceiling Fan(big Ass): Diameter:24 Feet(7.3 Meters)/voltage: 230v/3 Phase/motor Rpm: 60/motor Size: 2hp(1.5kw)/material: Aluminum/stainless Steel/fan Weight: 116kg/air Volume: 200-300cfm/airfoils: 8 Patented Powerfoils,8 Patent Pending/air Fences/sealed Gearbox And Industrial Motor/machine-cut Hub System/redundant Safety Features/variable Speed Operation With Controller With Delivery And Installation Works/5 Year Warranty B. Completed Within The Last Two(2) Years From The Date Of The Submission Of Bids 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 12 The Price Of Goods Shall Be Quoted Ddp Lgu-irosin, Irosin, Sorsogon. 14.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.3 One(1) Unit High Volume Low Speed Industrial Ceiling Fan(big Ass) One Unit High Volume Low Speed Industrial Ceiling Fan(big Ass): Diameter:24 Feet(7.3 Meters)/voltage: 230v/3 Phase/motor Rpm: 60/motor Size: 2hp(1.5kw)/material: Aluminum/stainless Steel/fan Weight: 116kg/air Volume: 200-300cfm/airfoils: 8 Patented Powerfoils,8 Patent Pending/air Fences/sealed Gearbox And Industrial Motor/machine-cut Hub System/redundant Safety Features/variable Speed Operation With Controller With Delivery And Installation Works/5 Year Warranty 20.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: None General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. Additional Requirements For The Completion Of This Contract Shall Be Provided In The Special Conditions Of Contract(scc). 2. Advance Payment 2.1 Advance Payment Of The Contract Amount Is Provided Under Annex “d” Of The Revised 2016 Irr Of Ra No. 9184. 2.2 The Procuring Entity Is Allowed To Determine The Terms Of The Payment On The Partial Or Staggered Delivery Of The Goods Procured, Provided Such Partial Payment Shall Correspond To The Value Of The Goods Delivered And Accepted In Accordance With Prevailing Accounting And Auditing Rules And Regulations. The Terms Of Payment Are Indicated In The Scc. 3. Performance Security Within Ten (10) Calendar Days From Receipt Of The Notice Of Award By The Bidder From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 4. Inspection And Tests The Procuring Entity Or Its Representatives Shall Have The Right To Inspect And/or The Test The Goods To Confirm Their Conformity To The Project. In Addition To Tests In The Scc, Section Vii(technical Specifications) Shall Specify What Inspections And/or Tests The Procuring Entity Requires, And Where They Are To Be Conducted. The Procuring Entity Shall Notify The Supplier In Writing, In A Timely Manner, Of The Identify Of Any Representatives Retained For These Purposes. All Reasonable Facilities And Assistance For The Inspection And Testing Of Goods, Including Access To Drawings And Production Data, Shall Be Provided By The Supplier To The Authorized Inspectors At No Charge To The Procuring Entity. 5. Warranty 7.1. In Order To Assure The Manufacturing Defects Shall Be Corrected By The Supplier, A Warranty Shall Be Required From The Supplier As Provided Under Section 62.1 Of The 2016 Revised Irr Of Ra No. 9184. 7.2. The Procuring Entity Shall Promptly Notify The Supplier In Writing Of Any Claims Arising Under This Warranty. Upon Receipt Of Such Notice, The Supplier Shall, Repair Or Replace The Defective Goods Or Parts Thereof Without Cost To The Procuring Entity, Pursuant To The Generic Procurement Manual. 6. Liability Of The Supplier The Supplier’s Liability Under This Contract Shall Be Provided By The Laws Of The Republic Of The Philippines. If The Supplier Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. Special Conditions Of Contract Gcc Clause 1 Delivery And Documents – For Purposes Of The Contract, “exw,” “fob,” “fca,” “cif,” “cip,” “ddp” And Other Trade Terms Used To Describe The Obligations Of The Parties Shall Have The Meanings Assigned To Them By The Current Edition Of Incoterms Published By The International Chamber Of Commerce, Paris. The Delivery Terms Of This Contract Shall Be As Follows: [for Goods Supplied From Within The Philippines] “the Delivery Terms Applicable To This Contract Are Delivered [indicate Place Of Destination]. Risk And Title Will Pass From The Supplier To The Procuring Entity Upon Receipt And Final Acceptance Of The Goods At Their Final Destination.” Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi (schedule Of Requirements). For Purposes Of This Clause The Procuring Entity’s Representative At The Project Site Is Wilson G. Baliwas. Incidental Services – The Supplier Is Required To Provide All Of The Following Services, Including Additional Services, If Any, Specified In Section Vi. Schedule Of Requirements: A. Performance Or Supervision Of On-site Assembly And/or Start-up Of The Supplied Goods; B. Furnishing Of Tools Required For Assembly And/or Maintenance Of The Supplied Goods; C. Furnishing Of A Detailed Operations And Maintenance Manual For Each Appropriate Unit Of The Supplied Goods; D. Performance Or Supervision Or Maintenance And/or Repair Of The Supplied Goods, For A Period Of Time Agreed By The Parties, Provided That This Service Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And E. Training Of The Procuring Entity’s Personnel, At The Supplier’s Plant And/or On-site, In Assembly, Start-up, Operation, Maintenance, And/or Repair Of The Supplied Goods. F. No Additional Incidental Service Requirements. The Contract Price For The Goods Shall Include The Prices Charged By The Supplier For Incidental Services And Shall Not Exceed The Prevailing Rates Charged To Other Parties By The Supplier For Similar Services. Spare Parts – The Supplier Is Required To Provide All Of The Following Materials, Notifications, And Information Pertaining To Spare Parts Manufactured Or Distributed By The Supplier: 1. Such Spare Parts As The Procuring Entity May Elect To Purchase From The Supplier, Provided That This Election Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And 2. In The Event Of Termination Of Production Of The Spare Parts: I. Advance Notification To The Procuring Entity Of The Pending Termination, In Sufficient Time To Permit The Procuring Entity To Procure Needed Requirements; And Ii. Following Such Termination, Furnishing At No Cost To The Procuring Entity, The Blueprints, Drawings, And Specifications Of The Spare Parts, If Requested. The Spare Parts And Other Components Required Are Listed In Section Vi (schedule Of Requirements) And The Costs Thereof Are Included In The Contract Price. The Supplier Shall Carry Sufficient Inventories To Assure Ex-stock Supply Of Consumable Spare Parts Or Components For The Goods For A Period Of Twelve(12) Months. Spare Parts Or Components Shall Be Supplied As Promptly As Possible, But In Any Case, Within Twelve(12) Months Of Placing The Order. Packaging – The Supplier Shall Provide Such Packaging Of The Goods As Is Required To Prevent Their Damage Or Deterioration During Transit To Their Final Destination, As Indicated In This Contract. The Packaging Shall Be Sufficient To Withstand, Without Limitation, Rough Handling During Transit And Exposure To Extreme Temperatures, Salt And Precipitation During Transit, And Open Storage. Packaging Case Size And Weights Shall Take Into Consideration, Where Appropriate, The Remoteness Of The Goods’ Final Destination And The Absence Of Heavy Handling Facilities At All Points In Transit. The Packaging, Marking, And Documentation Within And Outside The Packages Shall Comply Strictly With Such Special Requirements As Shall Be Expressly Provided For In The Contract, Including Additional Requirements, If Any, Specified Below, And In Any Subsequent Instructions Ordered By The Procuring Entity. The Outer Packaging Must Be Clearly Marked On At Least Four (4) Sides As Follows: Name Of The Procuring Entity Name Of The Supplier Contract Description Final Destination Gross Weight Any Special Lifting Instructions Any Special Handling Instructions Any Relevant Hazchem Classifications A Packaging List Identifying The Contents And Quantities Of The Package Is To Be Placed On An Accessible Point Of The Outer Packaging If Practical. If Not Practical The Packaging List Is To Be Placed Inside The Outer Packaging But Outside The Secondary Packaging. Transportation – Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip, Or Ddp, Transport Of The Goods To The Port Of Destination Or Such Other Named Place Of Destination In The Philippines, As Shall Be Specified In This Contract, Shall Be Arranged And Paid For By The Supplier, And The Cost Thereof Shall Be Included In The Contract Price. Where The Supplier Is Required Under This Contract To Transport The Goods To A Specified Place Of Destination Within The Philippines, Defined As The Project Site, Transport To Such Place Of Destination In The Philippines, Including Insurance And Storage, As Shall Be Specified In This Contract, Shall Be Arranged By The Supplier, And Related Costs Shall Be Included In The Contract Price. Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip Or Ddp, Goods Are To Be Transported On Carriers Of Philippine Registry. In The Event That No Carrier Of Philippine Registry Is Available, Goods May Be Shipped By A Carrier Which Is Not Of Philippine Registry Provided That The Supplier Obtains And Presents To The Procuring Entity Certification To This Effect From The Nearest Philippine Consulate To The Port Of Dispatch. In The Event That Carriers Of Philippine Registry Are Available But Their Schedule Delays The Supplier In Its Performance Of This Contract The Period From When The Goods Were First Ready For Shipment And The Actual Date Of Shipment The Period Of Delay Will Be Considered Force Majeure. The Procuring Entity Accepts No Liability For The Damage Of Goods During Transit Other Than Those Prescribed By Incoterms For Ddp Deliveries. In The Case Of Goods Supplied From Within The Philippines Or Supplied By Domestic Suppliers Risk And Title Will Not Be Deemed To Have Passed To The Procuring Entity Until Their Receipt And Final Acceptance At The Final Destination. Intellectual Property Rights – The Supplier Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 2.2 Partial Payment Is Not Applicable. 4 The Inspections And Tests That Will Be Conducted Are: Inspection Of The High Volume Low Speed Industrial Ceiling Fan If It Follows The Technical Specification Set By The End-user Unit. Section Vi. Schedule Of Requirements The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. Item Number Description Quantity Total Delivered, Weeks/months Remarks Indicate Here Any Other Appropriate Information As May Be Necessary. Signature Over Printed Name Position Department/division Section Vii. Technical Specifications Item Specification Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution Subject To The Applicable Laws And Issuances.] Technical Specifications Technical Specifications Item / Service Maximum Quantity Technical Specifications / Scope Of Work Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution.] Checklist Of Technical And Financial Documents Standard Form Number: Sf-good-06 Revised On: May 24, 2004 A. The Eligibility & Technical Envelope Shall Contain The Following: I. Technical Component Envelope Class “a” Documents Legal Documents • Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; • Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives • Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located • Tax Clearance Per Executive Order No. 398 Series Of 2005 Showing The Current Assets And Current Liabilities Of The Taxpayer • Tax Clearance For Collection Purposes Technical Documents • Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid. The Statement Shall Include: (a) Name Of The Contract (b) Date Of The Contract (c) Kinds Of Goods (d) Amount Of Contract And Value Of Outstanding Contracts (e) Date Of Delivery (f) End-user’s Acceptance Of Official Receipts Issued For The Contract • Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid, Except Under Conditions Provided For In Sections 23.4.1.3 And 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184, Within The Relevant Period As Provided In The Bidding Documents; • Audited Financial Statements, Showing Among Others, The Total And Current Assets And Liabilities, Stamped “received By The Bir Or Its Duly Accredited And Authorized Institutions, For The Preceding Calendar Year Which Should Not Be Earlier Tan Two(2) Years From The Date Of Bid Submission • The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc) Or A Committed Line Of Credit From A Universal Or Commercial Bank In Lieu Of Its Nfcc Computation. Class “b” Documents • If Applicable, A Duly Signed Joint Venture Agreement (jva) In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. B. Technical Requirements Consist Of The Following:: • Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration. Bid Security Should Be In The Form Of: O Cash Issued By A Commercial Or Universal Bank – 2% O Bank Draft/guarantee Issued By A Commercial Or Universal Bank – 2% O Bid Securing Declaration • Technical Specification • Production/delivery Schedule • Manpower Requirements • After-sales Service/parts, If Applicable • Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. Checklist Of Financial Envelope Requirements For Bidders Ii.financial Component Envelope The Financial Component Shall Contain The Following: • Original Of Duly Signed And Accomplished Financial Bid Form; • Original Of Duly Signed And Accomplished Price Schedule(s). • Recurring And Maintenance Costs, If Applicable Other Documentary Requirements Under Ra No. 9184 (as Applicable) ⬜ (c) [for Foreign Bidders Claiming By Reason Of Their Country’s Extension Of Reciprocal Rights To Filipinos] Certification From The Relevant Government Office Of Their Country Stating That Filipinos Are Allowed To Participate In Government Procurement Activities For The Same Item Or Product. ⬜ (d) Certification From The Dti If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity.   Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. ______ To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025. Bid Form For The Procurement Of Goods (shall Be Submitted With The Bid) Bid Form Date: _____________________________ Project Identification No.: _____________ To: [name And Address Of Procuring Entity] Having Examined The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers_____, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Offer To (supply/deliver/perform) (description Of The Goods) In Conformity With The Said Pbds For The Sum Of (total Bid Amount In Words And Figures) Or The Total Calculated Bid Price, As Evaluated And Corrected For Computational Errors , And Other Bid Modifications In Accordance With The Price Schedules Attached Herewith And Made Part Of This Bid. The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To (specify The Applicable Taxes, E.g. (i) Value Added Tax, (ii) Income Tax, (iii) Local Taxes, And (iv) Other Fiscal Levies And Duties), Which Are Itemized Herein Or In The Price Schedules. If Our Bid Is Accepted, We Undertake: A.to Deliver The Goods In Accordance With The Delivery Schedule Specified In The Schedule Of Requirements Of The Philippine Bidding Documents(pbds); B. To Provide A Performance Security In The Form, Amounts, And Within The Times Prescribed In The Pbds; C. To Abide By The Bid Validity Specified In The Pbds And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period. Until A Formal Contract Is Prepared And Executed, This Bid, Together With Your Written Acceptance Thereof And Your Notice Of Award, Shall Be Binding Upon Us. We Understand That You Are Not Bound To Accept The Lowest Calculated Bid Or Any Bid You May Receive. We Certify/conform That We Comply With The Eligibility Requirements Pursuant To The Pbds. The Undersigned Is Authorized To Submit The Bid On Behalf Of (name Of The Bidder) As Evidenced By The Attached (state The Written Authority). We Acknowledge That Failure To Sugn Each And Every Page Of This Bid Form, Including, The Attached Schedule Of Prices, Shall Be A Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Goods(revised) __________________________________________________________________________ This Agreement, Made The _________ Day Of _______________, ________ Between [name And Address Of Procuring Entity] Of The Philippines (hereinafter Called The“entity”) Of The One Part And [name Of Supplier] (hereinafter Called The “supplier”) Of The Other Part. Whereas, The Entity Invited Bids For Certain Goods And Ancillary Services, Particularly (brief Description Of Goods And Services) And Has Accepted A Bid By The Supplier For The Supply Of Those Goods And Services In The Sum Of (contract Price In Words And Figures In Specified Currency) (hereinafter Called The “contract Price”). Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: I. Philippine Bidding Documents(pbds) I. Schedule Of Requirements; Ii.technical Specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins, If Any Ii. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Supplier: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Bill Of Quantities Item No. Item Quantity Unit Unit Price Total Price Prepared By: ______________ Proprietor

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Supply & Delivery Of Hardware/materials For The Improvement Of Tourism Facilities-irosin Lake 1. The Local Government Unit Of Irosin, Through The Sglg-if 2024 Intends To Apply The Sum Of One Million One Hundred Fifty Three Thousand Pesos (p 1,153,000.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Supply & Delivery Of Hardware/materials For The Improvement Of Tourism Facilities-irosin Lake, Good-10-2024. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Supply & Delivery Of Hardware/materials For The Improvement Of Tourism Facilities-irosin Lake Brief Description: 944 L.m. 4” Diam Pe Pipe Sdr 11/256 L.m. Pe Pipe Sdr 11/1 Pc 4” Diam Gate Valve/2 Pcs 4” Diam Male Adapter/1 Pc 4”x3” Coupling Reducer/2 Pcs Sandflex Blade/1 Pc Project Signage/permanent Marker Approved Budget For The Contract : P 1,153,000.00 Contract Duration : 30 Calendar Days Delivery Period : 7 Calendar Days After The Issuance Of Notice To Proceed Source Of Fund : Sglg If 2024 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Delivery Of The Goods Is Required By Seven(7) Calendar Days. Bidders Should Have Completed For The Last Two(2) Years From The Date Of Submission And Receipt Of Bids, A Contract Similar To The Project. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). Bidding Is Restricted To Filipino Citizens/sole Proprietorships, Partnerships, Or Organizations With At Least Sixty Percent(60%) Interest Or Outstanding Capital Stock Belonging To Citizens Of The Philippines, And To Citizens Or Organizations Of A Country The Laws Or Regulations Of Which Grant Similar Rights Or Privileges To Filipino Citizens, Pursuant To Ra No. 5183. 4. Prospective Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 31, 2025 Until February 24, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of Five Thousand Pesos (p 5,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Hold A Pre-bid Conference On February 7, 2025, 3:00pm At The Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before February 24, 2024, 3:29 Pm At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On February 24, 2024, 3:30 Pm At The Given Address Below Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Benjamin M. Gabionza,ce Municipal Engineer Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Publication: January 31, 2024 _____________________ Noel D. Mercado Ii Bac Chairman ```u Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Supply & Delivery Of Hardware/materials For The Improvement Of Tourism Fcilities- Irosin Lake, With Project Identification Number Good-10-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website. The Procurement Project (referred To Herein As “project”) Is Composed Of 1 Lot Hardware/materials, The Details Of Which Are Described In Section Vii (technical Specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below Sglg If 2024 In The Amount Of One Million One Hundred Fifty Three Thousand Pesos (p 1,153,000.00). 2.2. The Source Of Funding Is: Office Of The Mayor-special Purpose Appropriations 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Requirements Of This Project, Including Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Suppliers, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. A.foreign Ownership Exceeding Those Allowed Under The Rules May Participate Pursuant To: Iii. When The Goods Sought To Be Procured Are Not Available From Local Suppliers; Or B. Foreign Ownership Limited To Those Allowed Under The Rules May Participate In This Project. 5.3. Pursuant To Section 23.4.1.3 Of The 2016 Revised Irr Of Ra No. 9184, The Bidder Shall Have An Slcc That Is At Least One(1) Contract Similar To The Project The Value Of Which, Adjusted To Current Prices Using The Psa’s Cpi, Must At Least Equivalent To: A. For The Procurement Of Expandable Supplies: The Bidder Must Have Completed A Single Contract That Is Similar To This Project, Equivalent To At Least Twenty Five Percent (25%) Of The Abc. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un, Subject To Domestic Preference Requirements Under Itb Clause 18. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Twenty Percent (20%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.2 Subcontracting Is Not Allowed During The Bidding. 7.3 Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.4 Subcontracting Of Any Portion Of The Project Does Not Relieve The Supplier Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Hold A Pre-bid Conference For This Project On February 7, 2025,3:00pm At The Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 10.2. The Bidder’s Slcc As Indicted In Itb Clause 5.3 Should Have Completed Within The Last Two(2) Years Prior To The Deadline For The Submission And Receipt Of Bids. 10.3. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. Similar To The Required Authentication Above, For Contracting Parties To The Apostile Convention, Only The Translated Documents Shall Be Authenticated Through The Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Viii( Checklist Of Technical And Financial Documents). 11.2. If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity, A Certification From Dti Shall Be Provided By The Bidder In Accordance With Section 43.1.3 Of The 2016 Revised Irr Of Ra No. 9184. 11.3. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.4. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 3184. 12. Bid Prices 12.1 Prices Indicated On The Price Schedule Shall Be Entered Separately In The Following Manner: A.for Goods Offered From Within The Procuring Entity’s Country: I. The Price Of The Goods Quoted Exw(ex-works,ex-factory,ex-warehouse,ex-showroom, Or Off The Shelf, As Applicable); Ii. The Cost Of All Custom Duties And Sales And Other Taxes Already Paid Or Payable; Iii. The Cost Of Transportation, Insurance, And Other Costs Incidental To Delivery Of The Goods To Their Final Destination; And Iv. The Price Of Other(incidental) Services, If Any, Listed In The Bds. 13. Bid And Payment Currencies 14.1. For Goods That The Bidder Will Supply From Outside The Philippines, The Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Adopted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreigh Currencies, Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 14. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 15. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 16. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 17. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 18. Domestic Preference 18.1 The Procuring Entity Will Grant A Margin Of Preference For The Purpose Of Comparison Of Bids In Accordance With Section 43.1.2 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, Bidders May Submit A Proposal On Any Of The Lots Or Items And Evaluation Will Be Undertaken On A Per Lot Or Item Basis, As The Case Maybe. In This Case, The Bid Security As Required By Itb Clause 14 Shall Be Submitted For Each Lot Or Item Separately. 19.3. The Descriptions Of The Lots Or Items Shall Be Indicated In Section Vii(technical Specifications), Although The Abcs Of These Lots Or Items Are Indicated In The Bds For Purposes Of The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184. The Nfcc Must Be Sufficient For The Total Of The Abcs For All The Lots Or Items Participated In By The Prospective Bidder. 19.4. The Project Shall Be Awarded As Follows: Option 1- One Project Having Several Items That Shall Be Awarded As One Contract. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.3 For This Purpose, Contracts Similar To The Project Shall Be: A. Supply & Delivery Of Hardware/materials For The Improvement Of Tourism Facilities-irosin Lake Brief Description: 944 L.m. 4” Diam Pe Pipe Sdr 11/256 L.m. Pe Pipe Sdr 11/1 Pc 4” Diam Gate Valve/2 Pcs 4” Diam Male Adapter/1 Pc 4”x3” Coupling Reducer/2 Pcs Sandflex Blade/1 Pc Project Signage/permanent Marker B. Completed Within The Last Two(2) Years From The Date Of The Submission Of Bids 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 12 The Price Of Goods Shall Be Quoted Ddp Lgu-irosin, Irosin, Sorsogon. 14.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.3 Hardware/materials 944 L.m. 4” Diam Pe Pipe Sdr 11/256 L.m. Pe Pipe Sdr 11/1 Pc 4” Diam Gate Valve/2 Pcs 4” Diam Male Adapter/1 Pc 4”x3” Coupling Reducer/2 Pcs Sandflex Blade/1 Pc Project Signage/permanent Marker 20.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21.2 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: None General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. Additional Requirements For The Completion Of This Contract Shall Be Provided In The Special Conditions Of Contract(scc). 2. Advance Payment 2.1 Advance Payment Of The Contract Amount Is Provided Under Annex “d” Of The Revised 2016 Irr Of Ra No. 9184. 2.2 The Procuring Entity Is Allowed To Determine The Terms Of The Payment On The Partial Or Staggered Delivery Of The Goods Procured, Provided Such Partial Payment Shall Correspond To The Value Of The Goods Delivered And Accepted In Accordance With Prevailing Accounting And Auditing Rules And Regulations. The Terms Of Payment Are Indicated In The Scc. 3. Performance Security Within Ten (10) Calendar Days From Receipt Of The Notice Of Award By The Bidder From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 4. Inspection And Tests The Procuring Entity Or Its Representatives Shall Have The Right To Inspect And/or The Test The Goods To Confirm Their Conformity To The Project. In Addition To Tests In The Scc, Section Vii(technical Specifications) Shall Specify What Inspections And/or Tests The Procuring Entity Requires, And Where They Are To Be Conducted. The Procuring Entity Shall Notify The Supplier In Writing, In A Timely Manner, Of The Identify Of Any Representatives Retained For These Purposes. All Reasonable Facilities And Assistance For The Inspection And Testing Of Goods, Including Access To Drawings And Production Data, Shall Be Provided By The Supplier To The Authorized Inspectors At No Charge To The Procuring Entity. 5. Warranty 7.1. In Order To Assure The Manufacturing Defects Shall Be Corrected By The Supplier, A Warranty Shall Be Required From The Supplier As Provided Under Section 62.1 Of The 2016 Revised Irr Of Ra No. 9184. 7.2. The Procuring Entity Shall Promptly Notify The Supplier In Writing Of Any Claims Arising Under This Warranty. Upon Receipt Of Such Notice, The Supplier Shall, Repair Or Replace The Defective Goods Or Parts Thereof Without Cost To The Procuring Entity, Pursuant To The Generic Procurement Manual. 6. Liability Of The Supplier The Supplier’s Liability Under This Contract Shall Be Provided By The Laws Of The Republic Of The Philippines. If The Supplier Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. Special Conditions Of Contract Gcc Clause 1 Delivery And Documents – For Purposes Of The Contract, “exw,” “fob,” “fca,” “cif,” “cip,” “ddp” And Other Trade Terms Used To Describe The Obligations Of The Parties Shall Have The Meanings Assigned To Them By The Current Edition Of Incoterms Published By The International Chamber Of Commerce, Paris. The Delivery Terms Of This Contract Shall Be As Follows: [for Goods Supplied From Within The Philippines] “the Delivery Terms Applicable To This Contract Are Delivered [indicate Place Of Destination]. Risk And Title Will Pass From The Supplier To The Procuring Entity Upon Receipt And Final Acceptance Of The Goods At Their Final Destination.” Delivery Of The Goods Shall Be Made By The Supplier In Accordance With The Terms Specified In Section Vi (schedule Of Requirements). For Purposes Of This Clause The Procuring Entity’s Representative At The Project Site Is Wilson G. Baliwas. Incidental Services – The Supplier Is Required To Provide All Of The Following Services, Including Additional Services, If Any, Specified In Section Vi. Schedule Of Requirements: A. Performance Or Supervision Of On-site Assembly And/or Start-up Of The Supplied Goods; B. Furnishing Of Tools Required For Assembly And/or Maintenance Of The Supplied Goods; C. Furnishing Of A Detailed Operations And Maintenance Manual For Each Appropriate Unit Of The Supplied Goods; D. Performance Or Supervision Or Maintenance And/or Repair Of The Supplied Goods, For A Period Of Time Agreed By The Parties, Provided That This Service Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And E. Training Of The Procuring Entity’s Personnel, At The Supplier’s Plant And/or On-site, In Assembly, Start-up, Operation, Maintenance, And/or Repair Of The Supplied Goods. F. No Additional Incidental Service Requirements. The Contract Price For The Goods Shall Include The Prices Charged By The Supplier For Incidental Services And Shall Not Exceed The Prevailing Rates Charged To Other Parties By The Supplier For Similar Services. Spare Parts – The Supplier Is Required To Provide All Of The Following Materials, Notifications, And Information Pertaining To Spare Parts Manufactured Or Distributed By The Supplier: 1. Such Spare Parts As The Procuring Entity May Elect To Purchase From The Supplier, Provided That This Election Shall Not Relieve The Supplier Of Any Warranty Obligations Under This Contract; And 2. In The Event Of Termination Of Production Of The Spare Parts: I. Advance Notification To The Procuring Entity Of The Pending Termination, In Sufficient Time To Permit The Procuring Entity To Procure Needed Requirements; And Ii. Following Such Termination, Furnishing At No Cost To The Procuring Entity, The Blueprints, Drawings, And Specifications Of The Spare Parts, If Requested. The Spare Parts And Other Components Required Are Listed In Section Vi (schedule Of Requirements) And The Costs Thereof Are Included In The Contract Price. The Supplier Shall Carry Sufficient Inventories To Assure Ex-stock Supply Of Consumable Spare Parts Or Components For The Goods For A Period Of Three(3) Months. Spare Parts Or Components Shall Be Supplied As Promptly As Possible, But In Any Case, Within Three(3) Months Of Placing The Order. Packaging – The Supplier Shall Provide Such Packaging Of The Goods As Is Required To Prevent Their Damage Or Deterioration During Transit To Their Final Destination, As Indicated In This Contract. The Packaging Shall Be Sufficient To Withstand, Without Limitation, Rough Handling During Transit And Exposure To Extreme Temperatures, Salt And Precipitation During Transit, And Open Storage. Packaging Case Size And Weights Shall Take Into Consideration, Where Appropriate, The Remoteness Of The Goods’ Final Destination And The Absence Of Heavy Handling Facilities At All Points In Transit. The Packaging, Marking, And Documentation Within And Outside The Packages Shall Comply Strictly With Such Special Requirements As Shall Be Expressly Provided For In The Contract, Including Additional Requirements, If Any, Specified Below, And In Any Subsequent Instructions Ordered By The Procuring Entity. The Outer Packaging Must Be Clearly Marked On At Least Four (4) Sides As Follows: Name Of The Procuring Entity Name Of The Supplier Contract Description Final Destination Gross Weight Any Special Lifting Instructions Any Special Handling Instructions Any Relevant Hazchem Classifications A Packaging List Identifying The Contents And Quantities Of The Package Is To Be Placed On An Accessible Point Of The Outer Packaging If Practical. If Not Practical The Packaging List Is To Be Placed Inside The Outer Packaging But Outside The Secondary Packaging. Transportation – Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip, Or Ddp, Transport Of The Goods To The Port Of Destination Or Such Other Named Place Of Destination In The Philippines, As Shall Be Specified In This Contract, Shall Be Arranged And Paid For By The Supplier, And The Cost Thereof Shall Be Included In The Contract Price. Where The Supplier Is Required Under This Contract To Transport The Goods To A Specified Place Of Destination Within The Philippines, Defined As The Project Site, Transport To Such Place Of Destination In The Philippines, Including Insurance And Storage, As Shall Be Specified In This Contract, Shall Be Arranged By The Supplier, And Related Costs Shall Be Included In The Contract Price. Where The Supplier Is Required Under Contract To Deliver The Goods Cif, Cip Or Ddp, Goods Are To Be Transported On Carriers Of Philippine Registry. In The Event That No Carrier Of Philippine Registry Is Available, Goods May Be Shipped By A Carrier Which Is Not Of Philippine Registry Provided That The Supplier Obtains And Presents To The Procuring Entity Certification To This Effect From The Nearest Philippine Consulate To The Port Of Dispatch. In The Event That Carriers Of Philippine Registry Are Available But Their Schedule Delays The Supplier In Its Performance Of This Contract The Period From When The Goods Were First Ready For Shipment And The Actual Date Of Shipment The Period Of Delay Will Be Considered Force Majeure. The Procuring Entity Accepts No Liability For The Damage Of Goods During Transit Other Than Those Prescribed By Incoterms For Ddp Deliveries. In The Case Of Goods Supplied From Within The Philippines Or Supplied By Domestic Suppliers Risk And Title Will Not Be Deemed To Have Passed To The Procuring Entity Until Their Receipt And Final Acceptance At The Final Destination. Intellectual Property Rights – The Supplier Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 2.2 Partial Payment Is Not Applicable. 4 The Inspections And Tests That Will Be Conducted Are: Inspection Of The Hardware/materials If It Follows The Technical Specification Set By The End-user Unit. Section Vi. Schedule Of Requirements The Delivery Schedule Expressed As Weeks/months Stipulates Hereafter A Delivery Date Which Is The Date Of Delivery To The Project Site. Item Number Description Quantity Total Delivered, Weeks/months Remarks Indicate Here Any Other Appropriate Information As May Be Necessary. Signature Over Printed Name Position Department/division Section Vii. Technical Specifications Item Specification Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution Subject To The Applicable Laws And Issuances.] Technical Specifications Technical Specifications Item / Service Maximum Quantity Technical Specifications / Scope Of Work Statement Of Compliance [bidders Must State Here Either “comply” Or “not Comply” Against Each Of The Individual Parameters Of Each Specification Stating The Corresponding Performance Parameter Of The Equipment Offered. Statements Of “comply” Or “not Comply” Must Be Supported By Evidence In A Bidders Bid And Cross-referenced To That Evidence. Evidence Shall Be In The Form Of Manufacturer’s Un-amended Sales Literature, Unconditional Statements Of Specification And Compliance Issued By The Manufacturer, Samples, Independent Test Data Etc., As Appropriate. A Statement That Is Not Supported By Evidence Or Is Subsequently Found To Be Contradicted By The Evidence Presented Will Render The Bid Under Evaluation Liable For Rejection. A Statement Either In The Bidder's Statement Of Compliance Or The Supporting Evidence That Is Found To Be False Either During Bid Evaluation, Post-qualification Or The Execution Of The Contract May Be Regarded As Fraudulent And Render The Bidder Or Supplier Liable For Prosecution.] Checklist Of Technical And Financial Documents Standard Form Number: Sf-good-06 Revised On: May 24, 2004 A. The Eligibility & Technical Envelope Shall Contain The Following: I. Technical Component Envelope Class “a” Documents Legal Documents • Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; • Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives • Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located • Tax Clearance Per Executive Order No. 398 Series Of 2005 Showing The Current Assets And Current Liabilities Of The Taxpayer • Tax Clearance For Collection Purposes Technical Documents • Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid. The Statement Shall Include: (a) Name Of The Contract (b) Date Of The Contract (c) Kinds Of Goods (d) Amount Of Contract And Value Of Outstanding Contracts (e) Date Of Delivery (f) End-user’s Acceptance Of Official Receipts Issued For The Contract • Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid, Except Under Conditions Provided For In Sections 23.4.1.3 And 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184, Within The Relevant Period As Provided In The Bidding Documents; • Audited Financial Statements, Showing Among Others, The Total And Current Assets And Liabilities, Stamped “received By The Bir Or Its Duly Accredited And Authorized Institutions, For The Preceding Calendar Year Which Should Not Be Earlier Tan Two(2) Years From The Date Of Bid Submission • The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc) Or A Committed Line Of Credit From A Universal Or Commercial Bank In Lieu Of Its Nfcc Computation. Class “b” Documents • If Applicable, A Duly Signed Joint Venture Agreement (jva) In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. B. Technical Requirements Consist Of The Following:: • Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration. Bid Security Should Be In The Form Of: O Cash Issued By A Commercial Or Universal Bank – 2% O Bank Draft/guarantee Issued By A Commercial Or Universal Bank – 2% O Bid Securing Declaration • Technical Specification • Production/delivery Schedule • Manpower Requirements • After-sales Service/parts, If Applicable • Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. Checklist Of Financial Envelope Requirements For Bidders Ii.financial Component Envelope The Financial Component Shall Contain The Following: • Original Of Duly Signed And Accomplished Financial Bid Form; • Original Of Duly Signed And Accomplished Price Schedule(s). • Recurring And Maintenance Costs, If Applicable Other Documentary Requirements Under Ra No. 9184 (as Applicable) ⬜ (c) [for Foreign Bidders Claiming By Reason Of Their Country’s Extension Of Reciprocal Rights To Filipinos] Certification From The Relevant Government Office Of Their Country Stating That Filipinos Are Allowed To Participate In Government Procurement Activities For The Same Item Or Product. ⬜ (d) Certification From The Dti If The Bidder Claims Preference As A Domestic Bidder Or Domestic Entity.   Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. ______ To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Subscribed And Sworn To Before Me A Notary Public For And Within The Province/city Pf __________________, On This ________ Day Of _______________, 2025 At __________________________ By The Above Named Affiant With His/her __________________ As The Competent Evidence Of His/her Identity And Avows Under Penalty Of Law That All The Statements Contained On This Instrument Are True And Correct. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025. Bid Form For The Procurement Of Goods (shall Be Submitted With The Bid) Bid Form Date: _____________________________ Project Identification No.: _____________ To: [name And Address Of Procuring Entity] Having Examined The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers_____, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Offer To (supply/deliver/perform) (description Of The Goods) In Conformity With The Said Pbds For The Sum Of (total Bid Amount In Words And Figures) Or The Total Calculated Bid Price, As Evaluated And Corrected For Computational Errors , And Other Bid Modifications In Accordance With The Price Schedules Attached Herewith And Made Part Of This Bid. The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To (specify The Applicable Taxes, E.g. (i) Value Added Tax, (ii) Income Tax, (iii) Local Taxes, And (iv) Other Fiscal Levies And Duties), Which Are Itemized Herein Or In The Price Schedules. If Our Bid Is Accepted, We Undertake: A.to Deliver The Goods In Accordance With The Delivery Schedule Specified In The Schedule Of Requirements Of The Philippine Bidding Documents(pbds); B. To Provide A Performance Security In The Form, Amounts, And Within The Times Prescribed In The Pbds; C. To Abide By The Bid Validity Specified In The Pbds And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period. Until A Formal Contract Is Prepared And Executed, This Bid, Together With Your Written Acceptance Thereof And Your Notice Of Award, Shall Be Binding Upon Us. We Understand That You Are Not Bound To Accept The Lowest Calculated Bid Or Any Bid You May Receive. We Certify/conform That We Comply With The Eligibility Requirements Pursuant To The Pbds. The Undersigned Is Authorized To Submit The Bid On Behalf Of (name Of The Bidder) As Evidenced By The Attached (state The Written Authority). We Acknowledge That Failure To Sugn Each And Every Page Of This Bid Form, Including, The Attached Schedule Of Prices, Shall Be A Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Goods(revised) __________________________________________________________________________ This Agreement, Made The _________ Day Of _______________, ________ Between [name And Address Of Procuring Entity] Of The Philippines (hereinafter Called The“entity”) Of The One Part And [name Of Supplier] (hereinafter Called The “supplier”) Of The Other Part. Whereas, The Entity Invited Bids For Certain Goods And Ancillary Services, Particularly (brief Description Of Goods And Services) And Has Accepted A Bid By The Supplier For The Supply Of Those Goods And Services In The Sum Of (contract Price In Words And Figures In Specified Currency) (hereinafter Called The “contract Price”). Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: I. Philippine Bidding Documents(pbds) I. Schedule Of Requirements; Ii.technical Specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins, If Any Ii. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Supplier: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Bill Of Quantities Item No. Item Quantity Unit Unit Price Total Price Prepared By: ______________ Proprietor

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Facility Enhancement/repair & Maintenance(super Health Center) 1. The Local Government Unit Of Irosin, Through The Trust Fund(philhealth) Intends To Apply The Sum Of Seven Hundred Fourteen Thousand Seven Hundred Three Pesos (p 714,703.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Facility Enhancement/repair & Maintenance(super Health Center), Infr-01-2025. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Facility Enhancement/repair & Maintenance(super Health Center) Brief Description: Chb Laying And Plastering/fabrication/installation Of Forms & Rsb And Tile Setting For Lavatories And Counters/installation Of Plumbing And Electrical Fixtures Approved Budget For The Contract : P 714,703.00 Source Of Fund : Trust Fund(philhealth) 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Completion Of Works Is Sixty (60) Calendar Days. Bidders Should Have Completed At Least One Similar Project For The Last Five(5) Years And Whose Value, Of The Contract, Adjusted To Current Prices Using The Nso Consumer Price Indices Must Be Equal To 50% Of The Abc To Be Bid. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). 4. Interested Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 9, 2025 Until January 31, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of One Thousand Pesos (p 1,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Hold A Pre-bid Conference On January 16, 2025, 9:00am At The Conference Room, Office Of The Municipal Mayor, Municipal Compound, San Julian, Irosin, Sorsogon, Which Shall Be Open To Prospective Bidders. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before January 31, 2025, 8:59 Am At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On January 31, 2025, 9:00 Am At The Given Address Below Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Benjamin M. Gabionza, Ce Municipal Engineer Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph Email Address: Bengabionza@gmail.com 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Posting: January 9, 2025 _____________________ Noel D. Mercado Ii Bac Chairman Standard Form Number: Sf-infr-07 Revised On: July 29, 2004 Checklist Of Technical And Financial Documents I. Technical Component Envelope Class “a” Documents Legal Documents ⬜ A) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; Or B) Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives C) Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located D) Tax Clearance Per Eo 398 E) Tax Clearance For Collection Purposes Technical Documents ⬜ (b) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And ⬜ (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid Completed Within The Last Five(5) Years, Except Under Conditions Provided Under The Rules; And • The Statement Shall Include The Following: (1)name Of The Contract; (2)date Of The Contract; (3)contract Duration; (4)owner’s Name And Address; (5)nature Of Work; (6)contractor’s Role (whether Sole Contractor, Subcontractor, Or Partner In A Jv) And Percentage Of Participation; (7)total Contract Value At Award; (8)date Of Completion Or Estimated Completion Time; (9)total Contract Value At Completion, If Applicable; (10)percentages Of Planned And Actual Accomplishments, If Applicable; (11)value Of Outstanding Works, If Applicable; (12)the Statement Shall Be Supported By The Notices Of Award And/or Notices To Proceed Issued By The Owners; And (13)the Statement Shall Be Supported By The Constructors Performance Evaluation System (cpes) Rating Sheets, And/or Certificates Of Completion And Owner’s Acceptance, If Applicable; ⬜ (d) Valid Pcab License-category B, Size Range Medium A Or Higher/special Pcab License In Case Of Joint Ventures And Registration For The Type And Cost Of The Contract To Be Bid; And ⬜ (e) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And (f) Project Requirements, Which Shall Include The Following: ⬜ A. Organizational Chart For The Contract To Be Bid; ⬜ B. List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen), To Be Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data; ⬜ C. List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership Or Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be; And ⬜ (g) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. (h) Affidavit Of Site Inspection Financial Documents ⬜ (i) Audited Financial Statement Stamped Received By The Bureau Of Internal Revenue(bir) Or Its Duly Authorized Institutions, For The Immediately Preceding Calendar Year, Which Should Not Be Earlier From Two(2) Years From The Date Of Submission (j) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc). Class “b” Documents ⬜ (k) If Applicable, Duly Signed Joint Venture Agreement (jva) In Accordance With Ra No. 4566 And Its Irr In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (l) Original Of Duly Signed And Accomplished Financial Bid Form; And Other Documentary Requirements Under Ra No. 9184 ⬜ (m) Original Of Duly Signed Bid Prices In The Bill Of Quantities; And ⬜ (n) Duly Accomplished Detailed Estimates Form, Including A Summary Sheet Indicating The Unit Prices Of Construction Materials, Labor Rates, And Equipment Rentals Used In Coming Up With The Bid; And ⬜ (o) Cash Flow By Quarter. Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Facility Enhancement/repair & Maintenance(super Health Center), With Project Identification Number Infr-01-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website.] The Procurement Project (referred To Herein As “project”) Is For The Construction Of Works, As Described In Section Vi (specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below For Trust Fund (philhealth) In The Amount Of Seven Hundred Fourteen Thousand Seven Hundred Three Pesos ( P 714,703.00). 2.2. The Source Of Funding Is: Trust Fund(philhealth) 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Characteristics Of The Contracted Works And The Conditions For This Project, Such As The Location And The Nature Of The Work; (b) Climatic Conditions; (c) Transportation Facilities; (c) Nature And Condition Of The Terrain, Geological Conditions At The Site Communication Facilities, Requirements, Location And Availability Of Construction Aggregates And Other Materials, Labor, Water, Electric Power And Access Roads; And (d) Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Contractors, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. The Bidder Must Have An Experience Of Having Completed A Single Largest Completed Contract (slcc) That Is Similar To This Project, Equivalent To At Least Fifty Percent (50%) Of The Abc Adjusted, If Necessary, By The Bidder To Current Prices Using The Psa’s Cpi, Except Under Conditions Provided For In Section 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184. A Contract Is Considered To Be “similar” To The Contract To Be Bid If It Has The Major Categories Of Work Stated In The Bds. 5.3. For Foreign-funded Procurement, The Procuring Entity And The Foreign Government/foreign Or International Financing Institution May Agree On Another Track Record Requirement, As Specified In The Bidding Document Prepared For This Purpose. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Associated Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Fifty Percent (50%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.1. Subcontracting Is Not Allowed During The Bidding. 7.2. Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.3. Subcontracting Of Any Portion Of The Project Does Not Relieve The Contractor Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Hold A Pre-bid Conference For This Project On January 16, 2025, 9:00am And Either At Its Physical Address Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon In A Face-to-face Manner As Indicated In Paragraph 6 Of The Ib. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 10.2. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. For Contracting Parties To The Apostille Convention, Only The Translated Documents Shall Be Authenticated Through An Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 10.3. A Valid Special Pcab License In Case Of Joint Ventures, And Registration For The Type And Cost Of The Contract For This Project. Any Additional Type Of Contractor License Or Permit Shall Be Indicated In The Bds. 10.4. A List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen) Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data Shall Be Provided. These Key Personnel Must Meet The Required Minimum Years Of Experience Set In The Bds. 10.5. A List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership, Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be, Must Meet The Minimum Requirements For The Contract Set In The Bds. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 11.2. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.3. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 9184. 12. Alternative Bids Bidders Shall Submit Offers That Comply With The Requirements Of The Bidding Documents, Including The Basic Technical Design As Indicated In The Drawings And Specifications. Unless There Is A Value Engineering Clause In The Bds, Alternative Bids Shall Not Be Accepted. 13. Bid Prices All Bid Prices For The Given Scope Of Work In The Project As Awarded Shall Be Considered As Fixed Prices, And Therefore Not Subject To Price Escalation During Contract Implementation, Except Under Extraordinary Circumstances As Determined By The Neda And Approved By The Gppb Pursuant To The Revised Guidelines For Contract Price Escalation Guidelines. 14. Bid And Payment Currencies 14.1. Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Accepted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreign Currencies Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 15. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 16. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 17. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 18. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, All Bids And Combinations Of Bids As Indicated In The Bds Shall Be Received By The Same Deadline And Opened And Evaluated Simultaneously So As To Determine The Bid Or Combination Of Bids Offering The Lowest Calculated Cost To The Procuring Entity. Bid Security As Required By Itb Clause 15 Shall Be Submitted For Each Contract (lot) Separately. 19.3. In All Cases, The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184 Must Be Sufficient For The Total Of The Abcs For All The Lots Participated In By The Prospective Bidder. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.2 For This Purpose, Contracts Similar To The Project Refer To Contracts Which Have The Same Major Categories Of Work, Which Shall Be: Facility Enhancement/repair & Maintenance(super Health Center) I.formworks Ii. Concrete And Masonry And Tile Works Iii. Plumbing Works Iv. Electrical Works V. Painting Works Vi. Doors And Windows Spl-1 Ppe’s Spl-2 Project Signage 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 10.3 The Other Contractor’s License Or Permit Required Is Bir Registration. 10.4 The Key Personnel Must Meet The Required Minimum Years Of Experience Set Below: Facility Enhancement/repair & Maintenance(super Health Center) Key Personnel General Experience Relevant Experience 1. Foreman 2. Skilled Worker 3.laborer 10.5 Facility Enhancement/repair & Maintenance(super Health Center) The Minimum Major Equipment Requirements Are The Following: Equipment Capacity Number Of Units 1.enough Hand Tools 12 Value Engineering Clause Is Not Allowed. 15.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.2 Partial Bids Are Not Allowed. 20 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21 Additional Contract Documents Relevant To The Project That May Be Required By Existing Laws And/or The Procuring Entity, Such As Construction Schedule And S-curve, Manpower Schedule, Construction Methods, Equipment Utilization Schedule, Construction Safety And Health Program Approved By The Dole, And Other Acceptable Tools Of Project Scheduling. General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. 2. Sectional Completion Of Works If Sectional Completion Is Specified In The Special Conditions Of Contract (scc), References In The Conditions Of Contract To The Works, The Completion Date, And The Intended Completion Date Shall Apply To Any Section Of The Works (other Than References To The Completion Date And Intended Completion Date For The Whole Of The Works). 3. Possession Of Site 3.1 The Procuring Entity Shall Give Possession Of All Or Parts Of The Site To The Contractor Based On The Schedule Of Delivery Indicated In The Scc, Which Corresponds To The Execution Of The Works. If The Contractor Suffers Delay Or Incurs Cost From Failure On The Part Of The Procuring Entity To Give Possession In Accordance With The Terms Of This Clause, The Procuring Entity’s Representative Shall Give The Contractor A Contract Time Extension And Certify Such Sum As Fair To Cover The Cost Incurred, Which Sum Shall Be Paid By Procuring Entity. 3.2 If Possession Of A Portion Is Not Given By The Above Date, The Procuring Entity Will Be Deemed To Have Delayed The Start Of The Relevant Activities. The Resulting Adjustments In Contract Time To Address Such Delay May Be Addressed Through Contract Extension Provided Under Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 4. The Contractor’s Obligations The Contractor Shall Employ The Key Personnel Named In The Schedule Of Key Personnel Indicating Their Designation, In Accordance With Itb Clause 10.3 And Specified In The Bds, To Carry Out The Supervision Of The Works. The Procuring Entity Will Approve Any Proposed Replacement Of Key Personnel Only If Their Relevant Qualifications And Abilities Are Equal To Or Better Than Those Of The Personnel Listed In The Schedule. 5. Performance Security 5.1. Within Ten (10) Calendar Days From Receipt Of The Notice Of Award From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 5.2. The Contractor, By Entering Into The Contract With The Procuring Entity, Acknowledges The Right Of The Procuring Entity To Institute Action Pursuant To Ra No. 3688 Against Any Subcontractor Be They An Individual, Firm, Partnership, Corporation, Or Association Supplying The Contractor With Labor, Materials And/or Equipment For The Performance Of This Contract. 6. Site Investigation Reports The Contractor, In Preparing The Bid, Shall Rely On Any Site Investigation Reports Referred To In The Scc Supplemented By Any Information Obtained By The Contractor. 7. Warranty 7.1. In Case The Contractor Fails To Undertake The Repair Works Under Section 62.2.2 Of The 2016 Revised Irr, The Procuring Entity Shall Forfeit Its Performance Security, Subject Its Property(ies) To Attachment Or Garnishment Proceedings, And Perpetually Disqualify It From Participating In Any Public Bidding. All Payables Of The Gop In His Favor Shall Be Offset To Recover The Costs. 7.2. The Warranty Against Structural Defects/failures, Except That Occasioned-on Force Majeure, Shall Cover The Period From The Date Of Issuance Of The Certificate Of Final Acceptance By The Procuring Entity. Specific Duration Of The Warranty Is Found In The Scc. 8. Liability Of The Contractor Subject To Additional Provisions, If Any, Set Forth In The Scc, The Contractor’s Liability Under This Contract Shall Be As Provided By The Laws Of The Republic Of The Philippines. If The Contractor Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. 9. Termination For Other Causes Contract Termination Shall Be Initiated In Case It Is Determined Prima Facie By The Procuring Entity That The Contractor Has Engaged, Before, Or During The Implementation Of The Contract, In Unlawful Deeds And Behaviors Relative To Contract Acquisition And Implementation, Such As, But Not Limited To Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices As Stated In Itb Clause 4. 10. Dayworks Subject To The Guidelines On Variation Order In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184, And If Applicable As Indicated In The Scc, The Dayworks Rates In The Contractor’s Bid Shall Be Used For Small Additional Amounts Of Work Only When The Procuring Entity’s Representative Has Given Written Instructions In Advance For Additional Work To Be Paid For In That Way. 11. Program Of Work 11.1. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval The Said Program Of Work Showing The General Methods, Arrangements, Order, And Timing For All The Activities In The Works. The Submissions Of The Program Of Work Are Indicated In The Scc. 11.2. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval An Updated Program Of Work At Intervals No Longer Than The Period Stated In The Scc. If The Contractor Does Not Submit An Updated Program Of Work Within This Period, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From The Next Payment Certificate And Continue To Withhold This Amount Until The Next Payment After The Date On Which The Overdue Program Of Work Has Been Submitted. 12. Instructions, Inspections And Audits The Contractor Shall Permit The Gop Or The Procuring Entity To Inspect The Contractor’s Accounts And Records Relating To The Performance Of The Contractor And To Have Them Audited By Auditors Of The Gop Or The Procuring Entity, As May Be Required. 13. Advance Payment The Procuring Entity Shall, Upon A Written Request Of The Contractor Which Shall Be Submitted As A Contract Document, Make An Advance Payment To The Contractor In An Amount Not Exceeding Fifteen Percent (15%) Of The Total Contract Price, To Be Made In Lump Sum, Or At The Most Two Installments According To A Schedule Specified In The Scc, Subject To The Requirements In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 14. Progress Payments The Contractor May Submit A Request For Payment For Work Accomplished. Such Requests For Payment Shall Be Verified And Certified By The Procuring Entity’s Representative/project Engineer. Except As Otherwise Stipulated In The Scc, Materials And Equipment Delivered On The Site But Not Completely Put In Place Shall Not Be Included For Payment. 15. Operating And Maintenance Manuals 15.1. If Required, The Contractor Will Provide “as Built” Drawings And/or Operating And Maintenance Manuals As Specified In The Scc. 15.2. If The Contractor Does Not Provide The Drawings And/or Manuals By The Dates Stated Above, Or They Do Not Receive The Procuring Entity’s Representative’s Approval, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From Payments Due To The Contractor. Section V. Special Conditions Of Contract Rehabilitation/improvement Of Brgy. Cawayan Level Ii Water System Gcc Clause 2 Sectional Completion Is Not Applicable Since All Works Must Be Completed Within 60 Calendar Days. 4.1 The Schedule Of Delivery Of The Possession Of The Site To The Contractor, Whether Full Or In Part Is Seven(7) Calendar Days After The Issuance Of The Notice To Proceed(ntp). 6 The Site Investigation Reports Are: Completion Of Existing Constructed Building. 7.2 In Case Of Permanent Structures, Such As Buildings Of Types 4 And 5 As Classified Under The National Building Code Of The Philippines And Other Structures Made Of Steel, Iron, Or Concrete Which Comply With Relevant Structural Codes (e.g., Dpwh Standard Specifications), Such As, But Not Limited To, Steel/concrete Bridges, Flyovers, Aircraft Movement Areas, Ports, Dams, Tunnels, Filtration And Treatment Plants, Sewerage Systems, Power Plants, Transmission And Communication Towers, Railway System, And Other Similar Permanent Structures: Fifteen (15) Years. In Case Of Semi-permanent Structures, Such As Buildings Of Types 1, 2, And 3 As Classified Under The National Building Code Of The Philippines, Concrete/asphalt Roads, Concrete River Control, Drainage, Irrigation Lined Canals, River Landing, Deep Wells, Rock Causeway, Pedestrian Overpass, And Other Similar Semi-permanent Structures: Five (5) Years. In Case Of Other Structures, Such As Bailey And Wooden Bridges, Shallow Wells, Spring Developments, And Other Similar Structures: Two (2) Years. 10 A. Dayworks Are Applicable At The Rate Shown In The Contractor’s Original Bid. 11.1 The Contractor Shall Submit The Program Of Work To The Procuring Entity’s Representative Within Not Applicable Days Of Delivery Of The Notice Of Award. Not Applicable Since The End-user, Municipal Engineering Office, Was The One Who Made The Program Of Work(pow). 11.2 The Amount To Be Withheld For Late Submission Of An Updated Program Of Work Is Not Applicable. Reason Was Stated In 11.1. 13 The Amount Of The Advance Payment Shall Not Exceed 15% Of The Total Contract Price And Schedule Of Payment. 14 15.1 The Date By Which Operating And Maintenance Manuals Are Required Is 120 Calendar Days After The Commencement Of Works. The Date By Which “as Built” Drawings Are Required Is 60 Calendar Days After The Commencement Of Works. 15.2 The Amount To Be Withheld For Failing To Produce “as Built” Drawings And/or Operating And Maintenance Manuals By The Date Required Is Not Applicable. Section Vi. Specifications Specifications Is Provided In The Program Of Work(pow) And Detailed Estimates Section Vii. Drawings Please Seek The Drawings At The Office Of The Municipal Engineer Of Local Government Unit Of Irosin. Section Viii. Bill Of Quantities Rehabilitation/improvement Of Brgy. Cawayan Level Ii Water System Item No. Scope Of Work Quantity Unit 1.direct Cost(dc) I Formworks Ii Concrete And Masonry And Tile Works Iii Plumbing Works Iv Electrical Works V Painting Works Vi Doors And Windows Spl-1 Ppe’s Spl-2 Project Signage 2 Indirect Cost(ic), Contractor’s Mark-up 2.1 Contractor’s Profit(10% Of Direct Cost) 2.2 Ocm(15% Of Direct Cost) 2.3 Vat Component (5% Of Contractor’s Profit+dc+ocm) 2.4 Mobilization 2.5 Utilities(professional Fee’s For Electrical Engineers) Total Cost Of All Line Item Includes Cost Of Contractor’s Profit, Taxes And Ocm. Attached Detailed Cost Estimates Section Ix. Bidding Forms Table Of Contents Bid Form Form Of Contract Agreement Omnibus Sworn Statement Affidavit Of Site Inspection Bid Securing Declaration Bid Form Date: Project Id No.: Infr-01-2025 To: [name And Address Of Procuring Entity] Having Examine The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers ______, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Declare That: (a) We Have Reservation To The Pbds, Including The Supplemental Or Bid Bulletins, For The Procurement Projects, Facility Enhancement/repair & Maintenance(super Health Center); (b) We Offer To Execute The Works For This Contract In Accordance With The Pbds; (c) The Total Price Of Our Bid In Words And Figures , Excluding Any Discounts Offered Below Is (insert Information); (d) The Discounts Offered And The Methodology For Their Application Are: [insert Information) (e) The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To: Value Added Tax, Income Tax, Local Taxes And Other Fiscal Levies And Duties Which Are Itemized Herein And Reflected In The Detailed Estimates; (f) Our Bid Shall Be Valid Within A Period Stated In The Pbds, And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period; (g) If Our Bid Is Accepted, We Commit To Obtain A Performance Security In The Amount Of [insert Percentage Amount] Percent Of The Contract Price For The Due Performance Of The Contract, Or A Performance Securing Declaration In Lieu Of The Allowable Forms Of The Performance Security, Subject To The Terms And Conditions Of Issued Gppb Guidelines For This Purpose; (h) We Are Not Participating, As Bidders, In More Than One Bid In This Bidding Process, Other Than Alternative Offers In Accordance With The Bidding Documents; (i) We Understand That This Bid, Together With Your Written Acceptance Thereof Included In Your Notification Of Award, Shall Constitute A Binding Contract Between Us, Until A Formal Contract Is Prepared And Executed; And (j) We Understand That You Are Not Bound To Accept The Lowest Evaluated Bid Or Any Other Bid That You May Receive. (k) We Likewise Certify/confirm That The Undersigned, Is The Duly Authorized Representative Of The Bidder, And Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For The Facility Enhancement/repair & Maintenance(super Health Center). (l) We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including The Bill Of Quantities, Shall Be Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Infrastructure Projects(revised) __________________________________________________________________________ This Agreement, Made This [insert Date] Day Of [insert Month], [insert Year] Between [name And Address Of Procuring Entity] (hereinafter Called The“entity”) And [name And Address Of Contractor] (hereinafter Called The “contractor”). Whereas, The Entity Is Desirous That The Contractor Execute [name And Identification Number Of Contract] (hereinafter Called “the Works”) And The Entity Has Accepted The Bid For [insert The Amount In Specified Currency In Numbers And Words] By The Contractor For The Execution And Completion Of Such Works And The Remedying Of Any Defects Therein. Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: A. Philippine Bidding Documents(pbds) I.drawings/plans; Ii.specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins B. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The Works For The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Contractor: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Municipal Engineer Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Infr-01-2025 Facility Enhancement/repair And Maintenance (super Health Center) Irosin, Sorsogon Standard Form Number: Sf-infr-51 Revised On: August 11, 2004 Affidavit Of Site Inspection I, ________________________, Of Legal Age, _____________, Filipino And Residing At __________________________, Under Oath, Hereby Depose And Say: 1. That I Am The _________________________ Of The ____________________________________________, With Office Address At ______________________________; 2. That I Have Inspected The Site For Facility Enhancement/repair And Maintenance(super Health Center); 3. That I Am Making This Statement As Part Of The Requirement For The Technical Proposal Of The _________________________ Of ___________________________. In Faith Whereof, I Hereby Affix My Signature This ______ Day Of ________, 2025 At _________________________, Philippines. ___________________ Affiant Subscribed And Sworn To Before Me This ____ Day Of _________ 2025, Affiant Exhibiting To Me His/her Community Tax Certificate No. _______________ Issued On ________________ At ______________________________, Philippines. _______________________ Notary Public Until ______________ Ptr No. ______________ Date ______________ Place ______________ Tin ______________ Doc No. __________ Page No. _________ Book No. _________ Series Of _________. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. Infr-01-2025 To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025.

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon 1. The Local Government Unit Of Irosin, Through The Lgsf-fabdp(ntf-elcac-fy 2024) Intends To Apply The Sum Of Five Million Pesos (p 5,000,000.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Construction Of Municipal Building Brgy. Cawayan, Irosin, Sorsogon, Infr-03-2025. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Construction Of Municipal Building Brgy. Cawayan, Irosin, Sorsogon Brief Description: Construction Of 1 Unit,2-classroom School Building With A Total Of 162.00 Sq.m. Floor Area With Amenities And Grouted Rip-rap/slope Protection Approved Budget For The Contract : P 5,000,000.00 Source Of Fund : Lsgf_fabdp(ntf-elcac-fy 2024) 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Completion Of Works Is Two Hundred Ten (210) Calendar Days. Bidders Should Have Completed At Least One Similar Project For The Last Five(5) Years And Whose Value, Of The Contract, Adjusted To Current Prices Using The Nso Consumer Price Indices Must Be Equal To 50% Of The Abc To Be Bid. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). 4. Interested Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 17, 2025 Until February 10, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of Five Thousand Pesos (p 5,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Hold A Pre-bid Conference On January 24, 2025, 9:00am At The Conference Room, Office Of The Municipal Mayor, Municipal Compound, San Julian, Irosin, Sorsogon, Which Shall Be Open To Prospective Bidders. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before February 10, 2025, 8:59 Am At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On February 10, 2025, 9:00 Am At The Given Address Below Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Benjamin M. Gabionza, Ce Municipal Engineer Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph Email Address: Bengabionza@gmail.com 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Posting: January 17, 2025 _____________________ Noel D. Mercado Ii Bac Chairman Standard Form Number: Sf-infr-07 Revised On: July 29, 2004 Checklist Of Technical And Financial Documents I. Technical Component Envelope Class “a” Documents Legal Documents ⬜ A) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; Or B) Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives C) Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located D) Tax Clearance Per Eo 398 E) Tax Clearance For Collection Purposes Technical Documents ⬜ (b) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And ⬜ (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid Completed Within The Last Five(5) Years, Except Under Conditions Provided Under The Rules; And • The Statement Shall Include The Following: (1)name Of The Contract; (2)date Of The Contract; (3)contract Duration; (4)owner’s Name And Address; (5)nature Of Work; (6)contractor’s Role (whether Sole Contractor, Subcontractor, Or Partner In A Jv) And Percentage Of Participation; (7)total Contract Value At Award; (8)date Of Completion Or Estimated Completion Time; (9)total Contract Value At Completion, If Applicable; (10)percentages Of Planned And Actual Accomplishments, If Applicable; (11)value Of Outstanding Works, If Applicable; (12)the Statement Shall Be Supported By The Notices Of Award And/or Notices To Proceed Issued By The Owners; And (13)the Statement Shall Be Supported By The Constructors Performance Evaluation System (cpes) Rating Sheets, And/or Certificates Of Completion And Owner’s Acceptance, If Applicable; ⬜ (d) Valid Pcab License-category B, Size Range Medium A Or Higher/special Pcab License In Case Of Joint Ventures And Registration For The Type And Cost Of The Contract To Be Bid; And ⬜ (e) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And (f) Project Requirements, Which Shall Include The Following: ⬜ A. Organizational Chart For The Contract To Be Bid; ⬜ B. List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen), To Be Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data; ⬜ C. List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership Or Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be; And ⬜ (g) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. (h) Affidavit Of Site Inspection Financial Documents ⬜ (i) Audited Financial Statement Stamped Received By The Bureau Of Internal Revenue(bir) Or Its Duly Authorized Institutions, For The Immediately Preceding Calendar Year, Which Should Not Be Earlier From Two(2) Years From The Date Of Submission (j) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc). Class “b” Documents ⬜ (k) If Applicable, Duly Signed Joint Venture Agreement (jva) In Accordance With Ra No. 4566 And Its Irr In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (l) Original Of Duly Signed And Accomplished Financial Bid Form; And Other Documentary Requirements Under Ra No. 9184 ⬜ (m) Original Of Duly Signed Bid Prices In The Bill Of Quantities; And ⬜ (n) Duly Accomplished Detailed Estimates Form, Including A Summary Sheet Indicating The Unit Prices Of Construction Materials, Labor Rates, And Equipment Rentals Used In Coming Up With The Bid; And ⬜ (o) Cash Flow By Quarter. Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon, With Project Identification Number Infr-03-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website.] The Procurement Project (referred To Herein As “project”) Is For The Construction Of Works, As Described In Section Vi (specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below For Lgsf-fabdp(ntf-elcac-fy 2024) In The Amount Of Five Million Pesos ( P 5,000,000.00). 2.2. The Source Of Funding Is: Lgsf-fabdp(ntf-elcac-fy 2024) 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Characteristics Of The Contracted Works And The Conditions For This Project, Such As The Location And The Nature Of The Work; (b) Climatic Conditions; (c) Transportation Facilities; (c) Nature And Condition Of The Terrain, Geological Conditions At The Site Communication Facilities, Requirements, Location And Availability Of Construction Aggregates And Other Materials, Labor, Water, Electric Power And Access Roads; And (d) Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Contractors, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. The Bidder Must Have An Experience Of Having Completed A Single Largest Completed Contract (slcc) That Is Similar To This Project, Equivalent To At Least Fifty Percent (50%) Of The Abc Adjusted, If Necessary, By The Bidder To Current Prices Using The Psa’s Cpi, Except Under Conditions Provided For In Section 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184. A Contract Is Considered To Be “similar” To The Contract To Be Bid If It Has The Major Categories Of Work Stated In The Bds. 5.3. For Foreign-funded Procurement, The Procuring Entity And The Foreign Government/foreign Or International Financing Institution May Agree On Another Track Record Requirement, As Specified In The Bidding Document Prepared For This Purpose. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Associated Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Fifty Percent (50%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.1. Subcontracting Is Not Allowed During The Bidding. 7.2. Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.3. Subcontracting Of Any Portion Of The Project Does Not Relieve The Contractor Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Hold A Pre-bid Conference For This Project On January 17 , 2025, 9:00am And Either At Its Physical Address Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon In A Face-to-face Manner As Indicated In Paragraph 6 Of The Ib. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 10.2. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. For Contracting Parties To The Apostille Convention, Only The Translated Documents Shall Be Authenticated Through An Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 10.3. A Valid Special Pcab License In Case Of Joint Ventures, And Registration For The Type And Cost Of The Contract For This Project. Any Additional Type Of Contractor License Or Permit Shall Be Indicated In The Bds. 10.4. A List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen) Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data Shall Be Provided. These Key Personnel Must Meet The Required Minimum Years Of Experience Set In The Bds. 10.5. A List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership, Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be, Must Meet The Minimum Requirements For The Contract Set In The Bds. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 11.2. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.3. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 9184. 12. Alternative Bids Bidders Shall Submit Offers That Comply With The Requirements Of The Bidding Documents, Including The Basic Technical Design As Indicated In The Drawings And Specifications. Unless There Is A Value Engineering Clause In The Bds, Alternative Bids Shall Not Be Accepted. 13. Bid Prices All Bid Prices For The Given Scope Of Work In The Project As Awarded Shall Be Considered As Fixed Prices, And Therefore Not Subject To Price Escalation During Contract Implementation, Except Under Extraordinary Circumstances As Determined By The Neda And Approved By The Gppb Pursuant To The Revised Guidelines For Contract Price Escalation Guidelines. 14. Bid And Payment Currencies 14.1. Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Accepted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreign Currencies Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 15. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 16. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 17. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 18. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, All Bids And Combinations Of Bids As Indicated In The Bds Shall Be Received By The Same Deadline And Opened And Evaluated Simultaneously So As To Determine The Bid Or Combination Of Bids Offering The Lowest Calculated Cost To The Procuring Entity. Bid Security As Required By Itb Clause 15 Shall Be Submitted For Each Contract (lot) Separately. 19.3. In All Cases, The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184 Must Be Sufficient For The Total Of The Abcs For All The Lots Participated In By The Prospective Bidder. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.2 For This Purpose, Contracts Similar To The Project Refer To Contracts Which Have The Same Major Categories Of Work, Which Shall Be: Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon I.earthworks Ii. Rebar Works Iii. Formworks Iv. Concrete Works V. Masonry Works Vi. Trusses & Roofing Works Vii. Ceiling Works Viii. Plumbing Works Ix. Electrical Works X. Painting Works Xi. Doors And Windows Xii. Tile Works Xiii. Steel Works Spl-1 Grouted Rip-rap/slope Protection Spl-2 Amenities Spl-3 Hauling Of Materials To Jobsite Spl-4 Ppe’s Spl-5 Temporary Facilities Spl-6 Project Signage 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 10.3 The Other Contractor’s License Or Permit Required Is Bir Registration. 10.4 The Key Personnel Must Meet The Required Minimum Years Of Experience Set Below: Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon Key Personnel General Experience Relevant Experience 1. Foreman 2. Le Operator 3. Skilled Worker 4.laborer 10.5 Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon The Minimum Major Equipment Requirements Are The Following: Equipment Capacity Number Of Units 1.tampering Machine 2. Water Truck 3. Concrete Mixer 4. Bar Cutter 5. Welding Machine 6. Enough Hand Tools 12 Value Engineering Clause Is Not Allowed. 15.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.2 Partial Bids Are Not Allowed. 20 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21 Additional Contract Documents Relevant To The Project That May Be Required By Existing Laws And/or The Procuring Entity, Such As Construction Schedule And S-curve, Manpower Schedule, Construction Methods, Equipment Utilization Schedule, Construction Safety And Health Program Approved By The Dole, And Other Acceptable Tools Of Project Scheduling. General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. 2. Sectional Completion Of Works If Sectional Completion Is Specified In The Special Conditions Of Contract (scc), References In The Conditions Of Contract To The Works, The Completion Date, And The Intended Completion Date Shall Apply To Any Section Of The Works (other Than References To The Completion Date And Intended Completion Date For The Whole Of The Works). 3. Possession Of Site 3.1 The Procuring Entity Shall Give Possession Of All Or Parts Of The Site To The Contractor Based On The Schedule Of Delivery Indicated In The Scc, Which Corresponds To The Execution Of The Works. If The Contractor Suffers Delay Or Incurs Cost From Failure On The Part Of The Procuring Entity To Give Possession In Accordance With The Terms Of This Clause, The Procuring Entity’s Representative Shall Give The Contractor A Contract Time Extension And Certify Such Sum As Fair To Cover The Cost Incurred, Which Sum Shall Be Paid By Procuring Entity. 3.2 If Possession Of A Portion Is Not Given By The Above Date, The Procuring Entity Will Be Deemed To Have Delayed The Start Of The Relevant Activities. The Resulting Adjustments In Contract Time To Address Such Delay May Be Addressed Through Contract Extension Provided Under Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 4. The Contractor’s Obligations The Contractor Shall Employ The Key Personnel Named In The Schedule Of Key Personnel Indicating Their Designation, In Accordance With Itb Clause 10.3 And Specified In The Bds, To Carry Out The Supervision Of The Works. The Procuring Entity Will Approve Any Proposed Replacement Of Key Personnel Only If Their Relevant Qualifications And Abilities Are Equal To Or Better Than Those Of The Personnel Listed In The Schedule. 5. Performance Security 5.1. Within Ten (10) Calendar Days From Receipt Of The Notice Of Award From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 5.2. The Contractor, By Entering Into The Contract With The Procuring Entity, Acknowledges The Right Of The Procuring Entity To Institute Action Pursuant To Ra No. 3688 Against Any Subcontractor Be They An Individual, Firm, Partnership, Corporation, Or Association Supplying The Contractor With Labor, Materials And/or Equipment For The Performance Of This Contract. 6. Site Investigation Reports The Contractor, In Preparing The Bid, Shall Rely On Any Site Investigation Reports Referred To In The Scc Supplemented By Any Information Obtained By The Contractor. 7. Warranty 7.1. In Case The Contractor Fails To Undertake The Repair Works Under Section 62.2.2 Of The 2016 Revised Irr, The Procuring Entity Shall Forfeit Its Performance Security, Subject Its Property(ies) To Attachment Or Garnishment Proceedings, And Perpetually Disqualify It From Participating In Any Public Bidding. All Payables Of The Gop In His Favor Shall Be Offset To Recover The Costs. 7.2. The Warranty Against Structural Defects/failures, Except That Occasioned-on Force Majeure, Shall Cover The Period From The Date Of Issuance Of The Certificate Of Final Acceptance By The Procuring Entity. Specific Duration Of The Warranty Is Found In The Scc. 8. Liability Of The Contractor Subject To Additional Provisions, If Any, Set Forth In The Scc, The Contractor’s Liability Under This Contract Shall Be As Provided By The Laws Of The Republic Of The Philippines. If The Contractor Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. 9. Termination For Other Causes Contract Termination Shall Be Initiated In Case It Is Determined Prima Facie By The Procuring Entity That The Contractor Has Engaged, Before, Or During The Implementation Of The Contract, In Unlawful Deeds And Behaviors Relative To Contract Acquisition And Implementation, Such As, But Not Limited To Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices As Stated In Itb Clause 4. 10. Dayworks Subject To The Guidelines On Variation Order In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184, And If Applicable As Indicated In The Scc, The Dayworks Rates In The Contractor’s Bid Shall Be Used For Small Additional Amounts Of Work Only When The Procuring Entity’s Representative Has Given Written Instructions In Advance For Additional Work To Be Paid For In That Way. 11. Program Of Work 11.1. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval The Said Program Of Work Showing The General Methods, Arrangements, Order, And Timing For All The Activities In The Works. The Submissions Of The Program Of Work Are Indicated In The Scc. 11.2. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval An Updated Program Of Work At Intervals No Longer Than The Period Stated In The Scc. If The Contractor Does Not Submit An Updated Program Of Work Within This Period, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From The Next Payment Certificate And Continue To Withhold This Amount Until The Next Payment After The Date On Which The Overdue Program Of Work Has Been Submitted. 12. Instructions, Inspections And Audits The Contractor Shall Permit The Gop Or The Procuring Entity To Inspect The Contractor’s Accounts And Records Relating To The Performance Of The Contractor And To Have Them Audited By Auditors Of The Gop Or The Procuring Entity, As May Be Required. 13. Advance Payment The Procuring Entity Shall, Upon A Written Request Of The Contractor Which Shall Be Submitted As A Contract Document, Make An Advance Payment To The Contractor In An Amount Not Exceeding Fifteen Percent (15%) Of The Total Contract Price, To Be Made In Lump Sum, Or At The Most Two Installments According To A Schedule Specified In The Scc, Subject To The Requirements In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 14. Progress Payments The Contractor May Submit A Request For Payment For Work Accomplished. Such Requests For Payment Shall Be Verified And Certified By The Procuring Entity’s Representative/project Engineer. Except As Otherwise Stipulated In The Scc, Materials And Equipment Delivered On The Site But Not Completely Put In Place Shall Not Be Included For Payment. 15. Operating And Maintenance Manuals 15.1. If Required, The Contractor Will Provide “as Built” Drawings And/or Operating And Maintenance Manuals As Specified In The Scc. 15.2. If The Contractor Does Not Provide The Drawings And/or Manuals By The Dates Stated Above, Or They Do Not Receive The Procuring Entity’s Representative’s Approval, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From Payments Due To The Contractor. Section V. Special Conditions Of Contract Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon Gcc Clause 2 Sectional Completion Is Not Applicable Since All Works Must Be Completed Within 210 Calendar Days. 4.1 The Schedule Of Delivery Of The Possession Of The Site To The Contractor, Whether Full Or In Part Is Seven(7) Calendar Days After The Issuance Of The Notice To Proceed(ntp). 6 The Site Investigation Reports Are: Construction Of Two Classroom Building For Cawayan Elementary School. 7.2 In Case Of Permanent Structures, Such As Buildings Of Types 4 And 5 As Classified Under The National Building Code Of The Philippines And Other Structures Made Of Steel, Iron, Or Concrete Which Comply With Relevant Structural Codes (e.g., Dpwh Standard Specifications), Such As, But Not Limited To, Steel/concrete Bridges, Flyovers, Aircraft Movement Areas, Ports, Dams, Tunnels, Filtration And Treatment Plants, Sewerage Systems, Power Plants, Transmission And Communication Towers, Railway System, And Other Similar Permanent Structures: Fifteen (15) Years. In Case Of Semi-permanent Structures, Such As Buildings Of Types 1, 2, And 3 As Classified Under The National Building Code Of The Philippines, Concrete/asphalt Roads, Concrete River Control, Drainage, Irrigation Lined Canals, River Landing, Deep Wells, Rock Causeway, Pedestrian Overpass, And Other Similar Semi-permanent Structures: Five (5) Years. In Case Of Other Structures, Such As Bailey And Wooden Bridges, Shallow Wells, Spring Developments, And Other Similar Structures: Two (2) Years. 10 A. Dayworks Are Applicable At The Rate Shown In The Contractor’s Original Bid. 11.1 The Contractor Shall Submit The Program Of Work To The Procuring Entity’s Representative Within Not Applicable Days Of Delivery Of The Notice Of Award. Not Applicable Since The End-user, Municipal Engineering Office, Was The One Who Made The Program Of Work(pow). 11.2 The Amount To Be Withheld For Late Submission Of An Updated Program Of Work Is Not Applicable. Reason Was Stated In 11.1. 13 The Amount Of The Advance Payment Shall Not Exceed 15% Of The Total Contract Price And Schedule Of Payment. 14 15.1 The Date By Which Operating And Maintenance Manuals Are Required Is 210 Calendar Days After The Commencement Of Works. The Date By Which “as Built” Drawings Are Required Is 210 Calendar Days After The Commencement Of Works. 15.2 The Amount To Be Withheld For Failing To Produce “as Built” Drawings And/or Operating And Maintenance Manuals By The Date Required Is Not Applicable. Section Vi. Specifications Specifications Is Provided In The Program Of Work(pow) And Detailed Estimates Section Vii. Drawings Please Seek The Drawings At The Office Of The Municipal Engineer Of Local Government Unit Of Irosin. Section Viii. Bill Of Quantities Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon Item No. Scope Of Work Quantity Unit 1.direct Cost(dc) I Earthworks 1.00 Lot Ii Rebar Works 4,789.81 Kls Iii Formworks 1.00 Lot Iv Concrete Works 53.14 Cu.m. V Masonry Works 214.96 Sq.m. Vi Trusses & Roofing Works 172.00 Sq.m. Vii Ceiling Works 166.50 Sq.m. Viii Plumbing Works 1.00 Lot Ix Electrical Works 1.00 Lot X Painting Works 1.00 Lot Xi Doors And Windows 1.00 Lot Xii Tile Works 25.64 Sq.m. Xiii Steel Works 1.00 Lot Spl-1 Grouted Rip-rap/slope Protection 61.40 Cu.m. Spl-2 Amenities 1.00 Lot Spl-3 Hauling Of Materials To Jobsite 1.00 Lot Spl-4 Ppe’s 1.00 Lot Spl-5 Temporary Facilities 1.00 Lot Spl-6 Project Signage 1.00 Lot 2 Indirect Cost(ic), Contractor’s Mark-up 2.1 Contractor’s Profit(10% Of Direct Cost) 2.2 Ocm(15% Of Direct Cost) 2.3 Vat Component (5% Of Contractor’s Profit+dc+ocm) 2.4 Mobilization Total Cost Of All Line Item Includes Cost Of Contractor’s Profit, Taxes And Ocm. Attached Detailed Cost Estimates Section Ix. Bidding Forms Table Of Contents Bid Form Form Of Contract Agreement Omnibus Sworn Statement Affidavit Of Site Inspection Bid Securing Declaration Bid Form Date: Project Id No.: Infr-03-2025 To: [name And Address Of Procuring Entity] Having Examine The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers ______, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Declare That: (a) We Have Reservation To The Pbds, Including The Supplemental Or Bid Bulletins, For The Procurement Projects, Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon; (b) We Offer To Execute The Works For This Contract In Accordance With The Pbds; (c) The Total Price Of Our Bid In Words And Figures , Excluding Any Discounts Offered Below Is (insert Information); (d) The Discounts Offered And The Methodology For Their Application Are: [insert Information) (e) The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To: Value Added Tax, Income Tax, Local Taxes And Other Fiscal Levies And Duties Which Are Itemized Herein And Reflected In The Detailed Estimates; (f) Our Bid Shall Be Valid Within A Period Stated In The Pbds, And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period; (g) If Our Bid Is Accepted, We Commit To Obtain A Performance Security In The Amount Of [insert Percentage Amount] Percent Of The Contract Price For The Due Performance Of The Contract, Or A Performance Securing Declaration In Lieu Of The Allowable Forms Of The Performance Security, Subject To The Terms And Conditions Of Issued Gppb Guidelines For This Purpose; (h) We Are Not Participating, As Bidders, In More Than One Bid In This Bidding Process, Other Than Alternative Offers In Accordance With The Bidding Documents; (i) We Understand That This Bid, Together With Your Written Acceptance Thereof Included In Your Notification Of Award, Shall Constitute A Binding Contract Between Us, Until A Formal Contract Is Prepared And Executed; And (j) We Understand That You Are Not Bound To Accept The Lowest Evaluated Bid Or Any Other Bid That You May Receive. (k) We Likewise Certify/confirm That The Undersigned, Is The Duly Authorized Representative Of The Bidder, And Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For The Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon. (l) We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including The Bill Of Quantities, Shall Be Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Infrastructure Projects(revised) __________________________________________________________________________ This Agreement, Made This [insert Date] Day Of [insert Month], [insert Year] Between [name And Address Of Procuring Entity] (hereinafter Called The“entity”) And [name And Address Of Contractor] (hereinafter Called The “contractor”). Whereas, The Entity Is Desirous That The Contractor Execute [name And Identification Number Of Contract] (hereinafter Called “the Works”) And The Entity Has Accepted The Bid For [insert The Amount In Specified Currency In Numbers And Words] By The Contractor For The Execution And Completion Of Such Works And The Remedying Of Any Defects Therein. Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: A. Philippine Bidding Documents(pbds) I.drawings/plans; Ii.specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins B. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The Works For The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Contractor: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Municipal Engineer Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Infr-03-2025 Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon Irosin, Sorsogon Standard Form Number: Sf-infr-51 Revised On: August 11, 2004 Affidavit Of Site Inspection I, ________________________, Of Legal Age, _____________, Filipino And Residing At __________________________, Under Oath, Hereby Depose And Say: 1. That I Am The _________________________ Of The ____________________________________________, With Office Address At ______________________________; 2. That I Have Inspected The Site For Construction Of School Building Brgy. Cawayan, Irosin, Sorsogon; 3. That I Am Making This Statement As Part Of The Requirement For The Technical Proposal Of The _________________________ Of ___________________________. In Faith Whereof, I Hereby Affix My Signature This ______ Day Of ________, 2025 At _________________________, Philippines. ___________________ Affiant Subscribed And Sworn To Before Me This ____ Day Of _________ 2025, Affiant Exhibiting To Me His/her Community Tax Certificate No. _______________ Issued On ________________ At ______________________________, Philippines. _______________________ Notary Public Until ______________ Ptr No. ______________ Date ______________ Place ______________ Tin ______________ Doc No. __________ Page No. _________ Book No. _________ Series Of _________. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. Infr-03-2025 To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025.

Details: Description Republic Of The Philippines Province Of Sorsogon Municipality Of Irosin Bids & Awards Committee Invitation To Bid For Irosin Memorial Park Improvement(phase Iii) 1. The Local Government Unit Of Irosin, Through The 20% Edf 2025 Intends To Apply The Sum Of Three Million Pesos (p 3,000,000.00) Being The Approved Budget For The Contract (abc) To Payments Under The Contract For The Irosin Memorial Park Improvement, Infr-04-2025. Bids Received In Excess Of The Abc Shall Be Automatically Rejected At Bid Opening. Name Of Contract : Irosin Memorial Park Improvement(phase Iii) Brief Description: Excavation/backfilling/construction Of 0.15m X 460.00 Square Meters Pccp And 30.00 Linear Meters Canal/construction Of Additional Burial Apartments And Laying Of 1,400 Linear Meters Distribution Pipes Contract : P 3,000,000.00 Source Of Fund : 20% Edf 2025 2. The Local Government Unit Of Irosin Now Invites Bids For The Above Procurement Project. Completion Of Works Is Ninety (90) Calendar Days. Bidders Should Have Completed At Least One Similar Project For The Last Five(5) Years And Whose Value, Of The Contract, Adjusted To Current Prices Using The Nso Consumer Price Indices Must Be Equal To 50% Of The Abc To Be Bid. The Description Of An Eligible Bidder Is Contained In The Bidding Documents, Particularly, In Section Ii. Instruction To Bidders. 3. Bidding Will Be Conducted Through Open Competitive Bidding Procedures Using Non-discretionary “pass/fail” Criterion As Specified In The 2016 Implementing Rules And Regulations (irr) Of Republic Act 9184 (ra 9184). 4. Interested Bidders May Obtain Further Information From Local Government Unit Of Irosin And Inspect The Bidding Documents At The Address Given Below From 8:00 Am-5:00 Pm. 5. A Complete Set Of Bidding Documents May Be Acquired By Interested Bidders On January 28, 2025 Until February 18, 2025 From The Given Address And Philgeps Website And Lgu-irosin Website And Upon Payment Of The Applicable Fee For The Bidding Documents, Pursuant To The Latest Guidelines Issued By The Gppb, In The Amount Of Five Thousand Pesos (p 5,000.00). The Procuring Entity Shall Allow The Bidder To Present Its Proof Of Payment For The Fees By Presenting In Person The Official Receipt Of Bid Documents To The Bac Office. 6. The Local Government Unit Of Irosin Will Hold A Pre-bid Conference On February 5, 2025, 9:00am At The Conference Room, Office Of The Municipal Mayor, Municipal Compound, San Julian, Irosin, Sorsogon, Which Shall Be Open To Prospective Bidders. 7. Bids Must Be Duly Received By The Bac Secretariat Through Manual Submission At The Office Address As Indicated Below On Or Before February 18, 2025, 8:59 Am At Bac Office, Municipal Compound, San Julian, Irosin, Sorsogon. Late Bids Shall Not Be Accepted. 8. All Bids Must Be Accompanied By A Bid Security In Any Of The Acceptable Forms And In The Amount Stated In Itb Clause 16. 9. Bid Opening Shall Be On February 18, 2025, 9:00 Am At The Given Address Below Conference Room, Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon. Bids Will Be Opened In The Presence Of The Bidders’ Representatives Who Choose To Attend At The Address Below. 10. The Local Government Unit Of Irosin Reserves The Right To Accept Any And All Bids, Declare A Failure Of Bidding Or Not Award A Contract At Any Time Prior To Contract Award In Accordance With Section 35.6 And 41 Of The 2016 Revised Implementing Rules And Regulations(irr) Of Ra No. 9184, Without Thereby Incurring Any Liability To The Affected Bidder Or Bidders. 11.for Further Information, Please Refer To: Benjamin M. Gabionza, Ce Municipal Engineer Municipal Compound, San Julian, Irosin, Sorsogon Url: Www.irosin.gov.ph Email Address: Bengabionza@gmail.com 12. You May Visit The Following Websites: For Downloading Of Bidding Documents: Philgeps Website And Www.irosin.gov.ph Date Of Posting: January 28, 2025 _____________________ Noel D. Mercado Ii Bac Chairman Standard Form Number: Sf-infr-07 Revised On: July 29, 2004 Checklist Of Technical And Financial Documents I. Technical Component Envelope Class “a” Documents Legal Documents ⬜ A) Valid Philgeps Registration Certificate (platinum Membership) (all Pages) In Accordance With Section 8.5.2 Of The Irr; Or B) Registration From Sec, Department Of Trade And Industry(dti) For Sole Proprietorship And Cda For Cooperatives C) Valid Mayor’s Permit By The City Or Municipality Where The Principal Place Of Business Is Located D) Tax Clearance Per Eo 398 E) Tax Clearance For Collection Purposes Technical Documents ⬜ (b) Statement Of The Prospective Bidder Of All Its Ongoing Government And Private Contracts, Including Contracts Awarded But Not Yet Started, If Any, Whether Similar Or Not Similar In Nature And Complexity To The Contract To Be Bid; And ⬜ (c) Statement Of The Bidder’s Single Largest Completed Contract (slcc) Similar To The Contract To Be Bid Completed Within The Last Five(5) Years, Except Under Conditions Provided Under The Rules; And • The Statement Shall Include The Following: (1)name Of The Contract; (2)date Of The Contract; (3)contract Duration; (4)owner’s Name And Address; (5)nature Of Work; (6)contractor’s Role (whether Sole Contractor, Subcontractor, Or Partner In A Jv) And Percentage Of Participation; (7)total Contract Value At Award; (8)date Of Completion Or Estimated Completion Time; (9)total Contract Value At Completion, If Applicable; (10)percentages Of Planned And Actual Accomplishments, If Applicable; (11)value Of Outstanding Works, If Applicable; (12)the Statement Shall Be Supported By The Notices Of Award And/or Notices To Proceed Issued By The Owners; And (13)the Statement Shall Be Supported By The Constructors Performance Evaluation System (cpes) Rating Sheets, And/or Certificates Of Completion And Owner’s Acceptance, If Applicable; ⬜ (d) Valid Pcab License-category B, Size Range Medium A Or Higher/special Pcab License In Case Of Joint Ventures And Registration For The Type And Cost Of The Contract To Be Bid; And ⬜ (e) Original Copy Of Bid Security. If In The Form Of A Surety Bond, Submit Also A Certification Issued By The Insurance Commission Or Original Copy Of Notarized Bid Securing Declaration; And (f) Project Requirements, Which Shall Include The Following: ⬜ A. Organizational Chart For The Contract To Be Bid; ⬜ B. List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen), To Be Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data; ⬜ C. List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership Or Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be; And ⬜ (g) Original Duly Signed Omnibus Sworn Statement (oss) And If Applicable, Original Notarized Secretary’s Certificate In Case Of A Corporation, Partnership, Or Cooperative; Or Original Special Power Of Attorney Of All Members Of The Joint Venture Giving Full Power And Authority To Its Officer To Sign The Oss And Do Acts To Represent The Bidder. (h) Affidavit Of Site Inspection Financial Documents ⬜ (i) Audited Financial Statement Stamped Received By The Bureau Of Internal Revenue(bir) Or Its Duly Authorized Institutions, For The Immediately Preceding Calendar Year, Which Should Not Be Earlier From Two(2) Years From The Date Of Submission (j) The Prospective Bidder’s Computation Of Net Financial Contracting Capacity (nfcc). Class “b” Documents ⬜ (k) If Applicable, Duly Signed Joint Venture Agreement (jva) In Accordance With Ra No. 4566 And Its Irr In Case The Joint Venture Is Already In Existence Or Duly Notarized Statements From All The Potential Joint Venture Partners Stating That They Will Enter Into And Abide By The Provisions Of The Jva In The Instance That The Bid Is Successful. Ii. Financial Component Envelope ⬜ (l) Original Of Duly Signed And Accomplished Financial Bid Form; And Other Documentary Requirements Under Ra No. 9184 ⬜ (m) Original Of Duly Signed Bid Prices In The Bill Of Quantities; And ⬜ (n) Duly Accomplished Detailed Estimates Form, Including A Summary Sheet Indicating The Unit Prices Of Construction Materials, Labor Rates, And Equipment Rentals Used In Coming Up With The Bid; And ⬜ (o) Cash Flow By Quarter. Instruction To Bidders 1. Scope Of Bid The Procuring Entity, Local Government Unit Of Irosin Invites Bids For The Improvement/upgrading Of Super Health Center, With Project Identification Number Infr-04-2025. [note: The Project Identification Number Is Assigned By The Procuring Entity Based On Its Own Coding Scheme And Is Not The Same As The Philgeps Reference Number, Which Is Generated After The Posting Of The Bid Opportunity On The Philgeps Website.] The Procurement Project (referred To Herein As “project”) Is For The Construction Of Works, As Described In Section Vi (specifications). 2. Funding Information 2.1. The Gop Through The Source Of Funding As Indicated Below For 20% Edf 2025 In The Amount Of Three Million Pesos ( P 3,000,000.00). 2.2. The Source Of Funding Is: 20% Edf 2025 3. Bidding Requirements The Bidding For The Project Shall Be Governed By All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including Its Generic Procurement Manual And Associated Policies, Rules And Regulations As The Primary Source Thereof, While The Herein Clauses Shall Serve As The Secondary Source Thereof. Any Amendments Made To The Irr And Other Gppb Issuances Shall Be Applicable Only To The Ongoing Posting, Advertisement, Or Invitation To Bid By The Bac Through The Issuance Of A Supplemental Or Bid Bulletin. The Bidder, By The Act Of Submitting Its Bid, Shall Be Deemed To Have Inspected The Site, Determined The General Characteristics Of The Contracted Works And The Conditions For This Project, Such As The Location And The Nature Of The Work; (b) Climatic Conditions; (c) Transportation Facilities; (c) Nature And Condition Of The Terrain, Geological Conditions At The Site Communication Facilities, Requirements, Location And Availability Of Construction Aggregates And Other Materials, Labor, Water, Electric Power And Access Roads; And (d) Other Factors That May Affect The Cost, Duration And Execution Or Implementation Of The Contract, Project, Or Work And Examine All Instructions, Forms, Terms, And Project Requirements In The Bidding Documents. 4. Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices The Procuring Entity, As Well As The Bidders And Contractors, Shall Observe The Highest Standard Of Ethics During The Procurement And Execution Of The Contract. They Or Through An Agent Shall Not Engage In Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices Defined Under Annex “i” Of The 2016 Revised Irr Of Ra No. 9184 Or Other Integrity Violations In Competing For The Project. 5. Eligible Bidders 5.1. Only Bids Of Bidders Found To Be Legally, Technically, And Financially Capable Will Be Evaluated. 5.2. The Bidder Must Have An Experience Of Having Completed A Single Largest Completed Contract (slcc) That Is Similar To This Project, Equivalent To At Least Fifty Percent (50%) Of The Abc Adjusted, If Necessary, By The Bidder To Current Prices Using The Psa’s Cpi, Except Under Conditions Provided For In Section 23.4.2.4 Of The 2016 Revised Irr Of Ra No. 9184. A Contract Is Considered To Be “similar” To The Contract To Be Bid If It Has The Major Categories Of Work Stated In The Bds. 5.3. For Foreign-funded Procurement, The Procuring Entity And The Foreign Government/foreign Or International Financing Institution May Agree On Another Track Record Requirement, As Specified In The Bidding Document Prepared For This Purpose. 5.4. The Bidders Shall Comply With The Eligibility Criteria Under Section 23.4.2 Of The 2016 Irr Of Ra No. 9184. 6. Origin Of Associated Goods There Is No Restriction On The Origin Of Goods Other Than Those Prohibited By A Decision Of The Un Security Council Taken Under Chapter Vii Of The Charter Of The Un. 7. Subcontracts 7.1. The Bidder May Subcontract Portions Of The Project To The Extent Allowed By The Procuring Entity As Stated Herein, But In No Case More Than Fifty Percent (50%) Of The Project. The Procuring Entity Has Prescribed That: A. Subcontracting Is Not Allowed. 7.1. Subcontracting Is Not Allowed During The Bidding. 7.2. Subcontracting Is Not Allowed During The Contract Implementation Stage. 7.3. Subcontracting Of Any Portion Of The Project Does Not Relieve The Contractor Of Any Liability Or Obligation Under The Contract. The Supplier Will Be Responsible For The Acts, Defaults, And Negligence Of Any Subcontractor, Its Agents, Servants, Or Workmen As Fully As If These Were The Contractor’s Own Acts, Defaults, Or Negligence, Or Those Of Its Agents, Servants, Or Workmen. 8. Pre-bid Conference The Procuring Entity Will Hold A Pre-bid Conference For This Project On February 5, 2025, 9:00am And Either At Its Physical Address Office Of The Mayor, Municipal Compound, San Julian, Irosin, Sorsogon In A Face-to-face Manner As Indicated In Paragraph 6 Of The Ib. 9. Clarification And Amendment Of Bidding Documents Prospective Bidders May Request For Clarification On And/or Interpretation Of Any Part Of The Bidding Documents. Such Requests Must Be In Writing And Received By The Procuring Entity, Either At Its Given Address Or Through Electronic Mail Indicated In The Ib, At Least Ten (10) Calendar Days Before The Deadline Set For The Submission And Receipt Of Bids. 10. Documents Comprising The Bid: Eligibility And Technical Components 10.1. The First Envelope Shall Contain The Eligibility And Technical Documents Of The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 10.2. If The Eligibility Requirements Or Statements, The Bids, And All Other Documents For Submission To The Bac Are In Foreign Language Other Than English, It Must Be Accompanied By A Translation In English, Which Shall Be Authenticated By The Appropriate Philippine Foreign Service Establishment, Post, Or The Equivalent Office Having Jurisdiction Over The Foreign Bidder’s Affairs In The Philippines. For Contracting Parties To The Apostille Convention, Only The Translated Documents Shall Be Authenticated Through An Apostille Pursuant To Gppb Resolution No. 13-2019 Dated 23 May 2019. The English Translation Shall Govern, For Purposes Of Interpretation Of The Bid. 10.3. A Valid Special Pcab License In Case Of Joint Ventures, And Registration For The Type And Cost Of The Contract For This Project. Any Additional Type Of Contractor License Or Permit Shall Be Indicated In The Bds. 10.4. A List Of Contractor’s Key Personnel (e.g., Project Manager, Project Engineers, Materials Engineers, And Foremen) Assigned To The Contract To Be Bid, With Their Complete Qualification And Experience Data Shall Be Provided. These Key Personnel Must Meet The Required Minimum Years Of Experience Set In The Bds. 10.5. A List Of Contractor’s Major Equipment Units, Which Are Owned, Leased, And/or Under Purchase Agreements, Supported By Proof Of Ownership, Certification Of Availability Of Equipment From The Equipment Lessor/vendor For The Duration Of The Project, As The Case May Be, Must Meet The Minimum Requirements For The Contract Set In The Bds. 11. Documents Comprising The Bid: Financial Component 11.1. The Second Bid Envelope Shall Contain The Financial Documents For The Bid As Specified In Section Ix. Checklist Of Technical And Financial Documents. 11.2. Any Bid Exceeding The Abc Indicated In Paragraph 1 Of The Ib Shall Not Be Accepted. 11.3. For Foreign-funded Procurement, A Ceiling May Be Applied To Bid Prices Provided The Conditions Are Met Under Section 31.2 Of The 2016 Revised Irr Of Ra No. 9184. 12. Alternative Bids Bidders Shall Submit Offers That Comply With The Requirements Of The Bidding Documents, Including The Basic Technical Design As Indicated In The Drawings And Specifications. Unless There Is A Value Engineering Clause In The Bds, Alternative Bids Shall Not Be Accepted. 13. Bid Prices All Bid Prices For The Given Scope Of Work In The Project As Awarded Shall Be Considered As Fixed Prices, And Therefore Not Subject To Price Escalation During Contract Implementation, Except Under Extraordinary Circumstances As Determined By The Neda And Approved By The Gppb Pursuant To The Revised Guidelines For Contract Price Escalation Guidelines. 14. Bid And Payment Currencies 14.1. Bid Prices May Be Quoted In The Local Currency Or Tradeable Currency Accepted By The Bsp At The Discretion Of The Bidder. However, For Purposes Of Bid Evaluation, Bids Denominated In Foreign Currencies Shall Be Converted To Philippine Currency Based On The Exchange Rate As Published In The Bsp Reference Rate Bulletin On The Day Of The Bid Opening. 14.2. Payment Of The Contract Price Shall Be Made In: Philippine Pesos 15. Bid Security 15.1. The Bidder Shall Submit A Bid Securing Declaration Or Any Form Of Bid Security In The Amount Indicated In The Bds, Which Shall Be Not Less Than The Percentage Of The Abc In Accordance With The Schedule In The Bds. 15.2. The Bid And Bid Security Shall Be Valid Until One Hundred Twenty(120) Calendar Days. Any Bid Not Accompanied By An Acceptable Bid Security Shall Be Rejected By The Procuring Entity As Non-responsive. 16. Sealing And Marking Of Bids Each Bidder Shall Submit One Copy Of The First And Second Components Of Its Bid. The Procuring Entity May Request Additional Hard Copies And/or Electronic Copies Of The Bid. However, Failure Of The Bidders To Comply With The Said Request Shall Not Be A Ground For Disqualification. If The Procuring Entity Allows The Submission Of Bids Through Online Submission To The Given Website Or Any Other Electronic Means, The Bidder Shall Submit An Electronic Copy Of Its Bid, Which Must Be Digitally Signed. An Electronic Copy That Cannot Be Opened Or Is Corrupted Shall Be Considered Non-responsive And, Thus, Automatically Disqualified. 17. Deadline For Submission Of Bids The Bidders Shall Submit On The Specified Date And Time And Either At Its Physical Address Or Through Online Submission As Indicated In Paragraph 7 Of The Ib. 18. Opening And Preliminary Examination Of Bids 18.1. The Bac Shall Open The Bids In Public At The Time, On The Date, And At The Place Specified In Paragraph 9 Of The Ib. The Bidders’ Representatives Who Are Present Shall Sign A Register Evidencing Their Attendance. In Case Videoconferencing, Webcasting Or Other Similar Technologies Will Be Used, Attendance Of Participants Shall Likewise Be Recorded By The Bac Secretariat. In Case The Bids Cannot Be Opened As Scheduled Due To Justifiable Reasons, The Rescheduling Requirements Under Section 29 Of The 2016 Revised Irr Of Ra No. 9184 Shall Prevail. 18.2. The Preliminary Examination Of Bids Shall Be Governed By Section 30 Of The 2016 Revised Irr Of Ra No. 9184. 19. Detailed Evaluation And Comparison Of Bids 19.1. The Procuring Entity’s Bac Shall Immediately Conduct A Detailed Evaluation Of All Bids Rated “passed” Using Non-discretionary Pass/fail Criteria. The Bac Shall Consider The Conditions In The Evaluation Of Bids Under Section 32.2 Of 2016 Revised Irr Of Ra No. 9184. 19.2. If The Project Allows Partial Bids, All Bids And Combinations Of Bids As Indicated In The Bds Shall Be Received By The Same Deadline And Opened And Evaluated Simultaneously So As To Determine The Bid Or Combination Of Bids Offering The Lowest Calculated Cost To The Procuring Entity. Bid Security As Required By Itb Clause 15 Shall Be Submitted For Each Contract (lot) Separately. 19.3. In All Cases, The Nfcc Computation Pursuant To Section 23.4.2.6 Of The 2016 Revised Irr Of Ra No. 9184 Must Be Sufficient For The Total Of The Abcs For All The Lots Participated In By The Prospective Bidder. 20. Post Qualification Within A Non-extendible Period Of Five (5) Calendar Days From Receipt By The Bidder Of The Notice From The Bac That It Submitted The Lowest Calculated Bid, The Bidder Shall Submit Its Latest Income And Business Tax Returns Filed And Paid Through The Bir Electronic Filing And Payment System (efps), And Other Appropriate Licenses And Permits Required By Law And Stated In The Bds. 21. Signing Of The Contract The Documents Required In Section 37.2 Of The 2016 Revised Irr Of Ra No. 9184 Shall Form Part Of The Contract. Additional Contract Documents Are Indicated In The Bds. Bid Data Sheet Itb Clause 5.2 For This Purpose, Contracts Similar To The Project Refer To Contracts Which Have The Same Major Categories Of Work, Which Shall Be: Irosin Memorial Park Improvement(phase Iii) I.excavation/backfilling Ii. Sub-grade Preparation Iii. Aggregate Base-course Iv. Portland Cement Concrete Pavement V. Line Canal Vi. Covered Line Canal W/ Box Culvert Vii. Burial Apartment Viii. Plumbing Works Spl-1 Ppe’s Spl-2 Temporary Facilities Spl-3 Project Signage 7.1 Not Applicable Since Sub-contracting Is Not Allowed. 10.3 The Other Contractor’s License Or Permit Required Is Bir Registration. 10.4 Irosin Memorial Park Improvement(phase Iii) The Key Personnel Must Meet The Required Minimum Years Of Experience Set Below: Key Personnel General Experience Relevant Experience 1. Foreman 2. He And Le Operator 3. Skilled Worker 4.laborer 10.5 Irosin Memorial Park Improvement(phase Iii) The Minimum Major Equipment Requirements Are The Following: Equipment Capacity Number Of Units 1.road Grader 2. Road Roller 3. Water Truck 4. Concrete Mixer 5. Concrete Cutter 6. Bar Cutter 7. Concrete Vibrator 6. Enough Handtools 12 Value Engineering Clause Is Not Allowed. 15.1 The Bid Security Shall Be In The Form Of A Bid Securing Declaration Or Any Of The Following Forms And Amounts: A. [two Percent (2%) Of Abc], If Bid Security Is In Cash, Cashier’s/manager’s Check, Bank Draft/guarantee Or Irrevocable Letter Of Credit; B. [five Percent (5%) Of Abc] If Bid Security Is In Surety Bond. 19.2 Partial Bids Are Not Allowed. 20 Licenses And Permits Relevant To The Project And The Corresponding Law Requiring It: Bir Registration 21 Additional Contract Documents Relevant To The Project That May Be Required By Existing Laws And/or The Procuring Entity, Such As Construction Schedule And S-curve, Manpower Schedule, Construction Methods, Equipment Utilization Schedule, Construction Safety And Health Program Approved By The Dole, And Other Acceptable Tools Of Project Scheduling. General Conditions Of Contract 1. Scope Of Contract This Contract Shall Include All Such Items, Although Not Specifically Mentioned, That Can Be Reasonably Inferred As Being Required For Its Completion As If Such Items Were Expressly Mentioned Herein. All The Provisions Of Ra No. 9184 And Its 2016 Revised Irr, Including The Generic Procurement Manual, And Associated Issuances, Constitute The Primary Source For The Terms And Conditions Of The Contract, And Thus, Applicable In Contract Implementation. Herein Clauses Shall Serve As The Secondary Source For The Terms And Conditions Of The Contract. This Is Without Prejudice To Sections 74.1 And 74.2 Of The 2016 Revised Irr Of Ra No. 9184 Allowing The Gppb To Amend The Irr, Which Shall Be Applied To All Procurement Activities, The Advertisement, Posting, Or Invitation Of Which Were Issued After The Effectivity Of The Said Amendment. 2. Sectional Completion Of Works If Sectional Completion Is Specified In The Special Conditions Of Contract (scc), References In The Conditions Of Contract To The Works, The Completion Date, And The Intended Completion Date Shall Apply To Any Section Of The Works (other Than References To The Completion Date And Intended Completion Date For The Whole Of The Works). 3. Possession Of Site 3.1 The Procuring Entity Shall Give Possession Of All Or Parts Of The Site To The Contractor Based On The Schedule Of Delivery Indicated In The Scc, Which Corresponds To The Execution Of The Works. If The Contractor Suffers Delay Or Incurs Cost From Failure On The Part Of The Procuring Entity To Give Possession In Accordance With The Terms Of This Clause, The Procuring Entity’s Representative Shall Give The Contractor A Contract Time Extension And Certify Such Sum As Fair To Cover The Cost Incurred, Which Sum Shall Be Paid By Procuring Entity. 3.2 If Possession Of A Portion Is Not Given By The Above Date, The Procuring Entity Will Be Deemed To Have Delayed The Start Of The Relevant Activities. The Resulting Adjustments In Contract Time To Address Such Delay May Be Addressed Through Contract Extension Provided Under Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 4. The Contractor’s Obligations The Contractor Shall Employ The Key Personnel Named In The Schedule Of Key Personnel Indicating Their Designation, In Accordance With Itb Clause 10.3 And Specified In The Bds, To Carry Out The Supervision Of The Works. The Procuring Entity Will Approve Any Proposed Replacement Of Key Personnel Only If Their Relevant Qualifications And Abilities Are Equal To Or Better Than Those Of The Personnel Listed In The Schedule. 5. Performance Security 5.1. Within Ten (10) Calendar Days From Receipt Of The Notice Of Award From The Procuring Entity But In No Case Later Than The Signing Of The Contract By Both Parties, The Successful Bidder Shall Furnish The Performance Security In Any Of The Forms Prescribed In Section 39 Of The 2016 Revised Irr. 5.2. The Contractor, By Entering Into The Contract With The Procuring Entity, Acknowledges The Right Of The Procuring Entity To Institute Action Pursuant To Ra No. 3688 Against Any Subcontractor Be They An Individual, Firm, Partnership, Corporation, Or Association Supplying The Contractor With Labor, Materials And/or Equipment For The Performance Of This Contract. 6. Site Investigation Reports The Contractor, In Preparing The Bid, Shall Rely On Any Site Investigation Reports Referred To In The Scc Supplemented By Any Information Obtained By The Contractor. 7. Warranty 7.1. In Case The Contractor Fails To Undertake The Repair Works Under Section 62.2.2 Of The 2016 Revised Irr, The Procuring Entity Shall Forfeit Its Performance Security, Subject Its Property(ies) To Attachment Or Garnishment Proceedings, And Perpetually Disqualify It From Participating In Any Public Bidding. All Payables Of The Gop In His Favor Shall Be Offset To Recover The Costs. 7.2. The Warranty Against Structural Defects/failures, Except That Occasioned-on Force Majeure, Shall Cover The Period From The Date Of Issuance Of The Certificate Of Final Acceptance By The Procuring Entity. Specific Duration Of The Warranty Is Found In The Scc. 8. Liability Of The Contractor Subject To Additional Provisions, If Any, Set Forth In The Scc, The Contractor’s Liability Under This Contract Shall Be As Provided By The Laws Of The Republic Of The Philippines. If The Contractor Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. 9. Termination For Other Causes Contract Termination Shall Be Initiated In Case It Is Determined Prima Facie By The Procuring Entity That The Contractor Has Engaged, Before, Or During The Implementation Of The Contract, In Unlawful Deeds And Behaviors Relative To Contract Acquisition And Implementation, Such As, But Not Limited To Corrupt, Fraudulent, Collusive, Coercive, And Obstructive Practices As Stated In Itb Clause 4. 10. Dayworks Subject To The Guidelines On Variation Order In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184, And If Applicable As Indicated In The Scc, The Dayworks Rates In The Contractor’s Bid Shall Be Used For Small Additional Amounts Of Work Only When The Procuring Entity’s Representative Has Given Written Instructions In Advance For Additional Work To Be Paid For In That Way. 11. Program Of Work 11.1. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval The Said Program Of Work Showing The General Methods, Arrangements, Order, And Timing For All The Activities In The Works. The Submissions Of The Program Of Work Are Indicated In The Scc. 11.2. The Contractor Shall Submit To The Procuring Entity’s Representative For Approval An Updated Program Of Work At Intervals No Longer Than The Period Stated In The Scc. If The Contractor Does Not Submit An Updated Program Of Work Within This Period, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From The Next Payment Certificate And Continue To Withhold This Amount Until The Next Payment After The Date On Which The Overdue Program Of Work Has Been Submitted. 12. Instructions, Inspections And Audits The Contractor Shall Permit The Gop Or The Procuring Entity To Inspect The Contractor’s Accounts And Records Relating To The Performance Of The Contractor And To Have Them Audited By Auditors Of The Gop Or The Procuring Entity, As May Be Required. 13. Advance Payment The Procuring Entity Shall, Upon A Written Request Of The Contractor Which Shall Be Submitted As A Contract Document, Make An Advance Payment To The Contractor In An Amount Not Exceeding Fifteen Percent (15%) Of The Total Contract Price, To Be Made In Lump Sum, Or At The Most Two Installments According To A Schedule Specified In The Scc, Subject To The Requirements In Annex “e” Of The 2016 Revised Irr Of Ra No. 9184. 14. Progress Payments The Contractor May Submit A Request For Payment For Work Accomplished. Such Requests For Payment Shall Be Verified And Certified By The Procuring Entity’s Representative/project Engineer. Except As Otherwise Stipulated In The Scc, Materials And Equipment Delivered On The Site But Not Completely Put In Place Shall Not Be Included For Payment. 15. Operating And Maintenance Manuals 15.1. If Required, The Contractor Will Provide “as Built” Drawings And/or Operating And Maintenance Manuals As Specified In The Scc. 15.2. If The Contractor Does Not Provide The Drawings And/or Manuals By The Dates Stated Above, Or They Do Not Receive The Procuring Entity’s Representative’s Approval, The Procuring Entity’s Representative May Withhold The Amount Stated In The Scc From Payments Due To The Contractor. Section V. Special Conditions Of Contract Irosin Memorial Park Improvement Gcc Clause 2 Sectional Completion Is Not Applicable Since All Works Must Be Completed Within 90 Calendar Days. 4.1 The Schedule Of Delivery Of The Possession Of The Site To The Contractor, Whether Full Or In Part Is Seven(7) Calendar Days After The Issuance Of The Notice To Proceed(ntp). 6 The Site Investigation Reports Are: Additional Improvement Of Memorial Park. 7.2 In Case Of Permanent Structures, Such As Buildings Of Types 4 And 5 As Classified Under The National Building Code Of The Philippines And Other Structures Made Of Steel, Iron, Or Concrete Which Comply With Relevant Structural Codes (e.g., Dpwh Standard Specifications), Such As, But Not Limited To, Steel/concrete Bridges, Flyovers, Aircraft Movement Areas, Ports, Dams, Tunnels, Filtration And Treatment Plants, Sewerage Systems, Power Plants, Transmission And Communication Towers, Railway System, And Other Similar Permanent Structures: Fifteen (15) Years. In Case Of Semi-permanent Structures, Such As Buildings Of Types 1, 2, And 3 As Classified Under The National Building Code Of The Philippines, Concrete/asphalt Roads, Concrete River Control, Drainage, Irrigation Lined Canals, River Landing, Deep Wells, Rock Causeway, Pedestrian Overpass, And Other Similar Semi-permanent Structures: Five (5) Years. In Case Of Other Structures, Such As Bailey And Wooden Bridges, Shallow Wells, Spring Developments, And Other Similar Structures: Two (2) Years. 10 A. Dayworks Are Applicable At The Rate Shown In The Contractor’s Original Bid. 11.1 The Contractor Shall Submit The Program Of Work To The Procuring Entity’s Representative Within Not Applicable Days Of Delivery Of The Notice Of Award. Not Applicable Since The End-user, Municipal Engineering Office, Was The One Who Made The Program Of Work(pow). 11.2 The Amount To Be Withheld For Late Submission Of An Updated Program Of Work Is Not Applicable. Reason Was Stated In 11.1. 13 The Amount Of The Advance Payment Shall Not Exceed 15% Of The Total Contract Price And Schedule Of Payment. 14 15.1 The Date By Which Operating And Maintenance Manuals Are Required Is 90 Calendar Days After The Commencement Of Works. The Date By Which “as Built” Drawings Are Required Is 90 Calendar Days After The Commencement Of Works. 15.2 The Amount To Be Withheld For Failing To Produce “as Built” Drawings And/or Operating And Maintenance Manuals By The Date Required Is Not Applicable. Section Vi. Specifications Specifications Is Provided In The Program Of Work(pow) And Detailed Estimates Section Vii. Drawings Please Seek The Drawings At The Office Of The Municipal Engineer Of Local Government Unit Of Irosin. Section Viii. Bill Of Quantities Improvement Of Irosin Memorial Park(phase Iii) Item No. Scope Of Work Quantity Unit 1.direct Cost(dc) I Excavation/backfilling 5,256.20 Cu.m. Ii Sub-grade Preparation 456.83 Sq.m. Iii Aggregate Base Course 46.00 Cu.m. Iv Portland Cement Concrete Pavement 69.00 Cu.m. V Line Canal 30.00 L.m. Vi Covered Line Canal W/ Box Culvert 18.88 L.m. Vii Burial Apartment 1.00 Lot Viii Plumbing Works 1.400.00 L.m. Spl-1 Ppe’s 1.00 Lot Spl-2 Temporary Facilities 1.00 Lot Spl-3 Project Signage 1.00 Lot 2 Indirect Cost(ic), Contractor’s Mark-up 2.1 Contractor’s Profit(10% Of Direct Cost) 2.2 Ocm(15% Of Direct Cost) 2.3 Vat Component (5% Of Contractor’s Profit+dc+ocm) 2.4 Mobilization Total Cost Of All Line Item Includes Cost Of Contractor’s Profit, Taxes And Ocm. Attached Detailed Cost Estimates Section Ix. Bidding Forms Table Of Contents Bid Form Form Of Contract Agreement Omnibus Sworn Statement Affidavit Of Site Inspection Bid Securing Declaration Bid Form Date: Project Id No.: Infr-04-2025 To: [name And Address Of Procuring Entity] Having Examine The Philippine Bidding Documents(pbds) Including The Supplemental Or Bid Bulletin Numbers ______, The Receipt Of Which Is Hereby Duly Acknowledged, We, The Undersigned, Declare That: (a) We Have Reservation To The Pbds, Including The Supplemental Or Bid Bulletins, For The Procurement Projects, Irosin Memorial Park Improvement(phase Iii); (b) We Offer To Execute The Works For This Contract In Accordance With The Pbds; (c) The Total Price Of Our Bid In Words And Figures , Excluding Any Discounts Offered Below Is (insert Information); (d) The Discounts Offered And The Methodology For Their Application Are: [insert Information) (e) The Total Bid Price Includes The Cost Of All Taxes, Such As, But Not Limited To: Value Added Tax, Income Tax, Local Taxes And Other Fiscal Levies And Duties Which Are Itemized Herein And Reflected In The Detailed Estimates; (f) Our Bid Shall Be Valid Within A Period Stated In The Pbds, And It Shall Remain Binding Upon Us At Any Time Before The Expiration Of That Period; (g) If Our Bid Is Accepted, We Commit To Obtain A Performance Security In The Amount Of [insert Percentage Amount] Percent Of The Contract Price For The Due Performance Of The Contract, Or A Performance Securing Declaration In Lieu Of The Allowable Forms Of The Performance Security, Subject To The Terms And Conditions Of Issued Gppb Guidelines For This Purpose; (h) We Are Not Participating, As Bidders, In More Than One Bid In This Bidding Process, Other Than Alternative Offers In Accordance With The Bidding Documents; (i) We Understand That This Bid, Together With Your Written Acceptance Thereof Included In Your Notification Of Award, Shall Constitute A Binding Contract Between Us, Until A Formal Contract Is Prepared And Executed; And (j) We Understand That You Are Not Bound To Accept The Lowest Evaluated Bid Or Any Other Bid That You May Receive. (k) We Likewise Certify/confirm That The Undersigned, Is The Duly Authorized Representative Of The Bidder, And Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For The Irosin Memorial Park Improvement(phase Iii). (l) We Acknowledge That Failure To Sign Each And Every Page Of This Bid Form, Including The Bill Of Quantities, Shall Be Ground For The Rejection Of Our Bid. Name: Legal Capacity: Signed: Duly Authorized To Sign The Bid For And On Behalf Of: Date: ___________ Contract Agreement For The Procurement Of Infrastructure Projects(revised) __________________________________________________________________________ This Agreement, Made This [insert Date] Day Of [insert Month], [insert Year] Between [name And Address Of Procuring Entity] (hereinafter Called The“entity”) And [name And Address Of Contractor] (hereinafter Called The “contractor”). Whereas, The Entity Is Desirous That The Contractor Execute [name And Identification Number Of Contract] (hereinafter Called “the Works”) And The Entity Has Accepted The Bid For [insert The Amount In Specified Currency In Numbers And Words] By The Contractor For The Execution And Completion Of Such Works And The Remedying Of Any Defects Therein. Now This Agreement Witnesseth As Follows: 1. In This Agreement, Words And Expressions Shall Have The Same Meanings As Are Respectively Assigned To Them In The Conditions Of Contract Hereinafter Referred To. 2. The Following Documents As Required By The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184 Shall Be Deemed To Form And Be Read And Construed As Part Of This Agreement, Viz.: A. Philippine Bidding Documents(pbds) I.drawings/plans; Ii.specifications; Iii.bill Of Quantities Iv.general And Special Conditions Of Contract; V.supplemental Or Bid Bulletins B. Winning Bidder’s Bid, Including The Eligibility Requirements, Technical And Financial Proposals, And All Other Documents Or Statements Submitted; Bid Form, Including All The Documents/statements Contained In The Bidder’s Bidding Envelopes, As Annexes, And All Other Documents Submitted(e.g., Bidder’s Response To Request For Clarifications On The Bid), Including Corrections To The Bid, If Any, Resulting From The Procuring Entity’s Bid Evaluation; C. Performance Security D. Notice Of Award Of Contract And The Bidder’s Conforme Thereto; And E. Other Contract Documents That May Be Required By Existing Laws And/or The Procuring Entity Concerned In The Pbds. Winning Bidder Agrees That Additional Contract Documents Or Information Prescribed By The Gppb That Are Subsequently Required For Submission After The Contract Execution, Such As The Notice To Proceed, Variation Orders And Warranty Security, Shall Likewise Form Part Of The Contract. 3. In Consideration For The Sum Of [total Contract Price In Words And Figures) Or Such Other Sums As May Be Ascertained, [name Of Bidder] Agrees To Execute The Works For The [state The Object Of The Contract] In Accordance With His/her/its Bid. 4. The [name Of The Procuring Entity] To Pay The Above-mentioned Sum In Accordance With The Terms Of Bidding. In Witness, Whereof The Parties Thereto Have Caused This Agreement To Be Executed The Day And Year First Before Written. Binding Signature Of The Procuring Entity: Binding Signature Of Contractor: Insert Name And Signature] [insert Name And Signature] [insert Signatory’s Legal Capacity] [insert Signatory’s Legal Capacity] Signed In The Presence Of: ______________________ ________________ Municipal Engineer Liaison Officer For: For: [insert Procuring Entity] [insert Name Of Supplier] Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Contract Agreement And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. This Instrument Consists Of ____ Pages Including This Page On Which The Acknowledgement Is Written Duly Signed By The Contracting Parties And Their Witnesses. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Omnibus Sworn Statement(revised) Republic Of The Philippines ) City/municipality Of ______ ) S.s. Affidavit I, [name Of Affiant], Of Legal Age, [civil Status], [nationality], And Residing At [address Of Affiant], After Having Been Duly Sworn In Accordance With Law, Do Hereby Depose And State That: 1. Select One, Delete The Other: If A Sole Proprietorship: I Am The Sole Proprietor Or Authorized Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am The Duly Authorized And Designated Representative Of [name Of Bidder] With Office Address At [address Of Bidder]; 2. Select One, Delete The Other: If A Sole Proprietorship: As The Owner And Sole Proprietor Or Authorized Representative Of [name Of Bidder], I Have Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] As Shown In The Attached Duly Notarized Special Power Of Attorney; If A Partnership, Corporation, Cooperative, Or Joint Venture: I Am Granted Full Power And Authority To Do, Execute And Perform Any And All Acts Necessary To Participate, Submit The Bid, And To Sign And Execute The Ensuing Contract For [name Of The Project] Of The [name Of The Procuring Entity], As Shown In The Attached [state Title Of Attached Document Showing Proof Of Authorization (e.g. Duly Notarized Secretary’s Certificate, Board/partnership Resolution Or Special Power Of Attorney, Whichever Is Applicable]; 3. [name Of Bidder] Is Not “blacklisted” Or Barred From Bidding By The Government Of The Philippines Or Any Of Its Agencies, Offices, Corporations, Or Local Government Units, Foreign Government/foreign Or International Financing Institution Whose Blacklisting Rules Have Been Recognized By The Government Procurement Policy Board, By Itself Or By Relation, Membership, Association, Affiliation Or Controlling Interest With Another Blacklisted Person Or Entity As Defined And Provided For And In The Uniform Guidelines On Blacklisting; 4. Each Of The Documents Submitted In Satisfaction Of The Bidding Requirements Is An Authentic Copy Of The Original, Complete, And All Statements And Information Provided Therein Are True And Correct; 5. [name Of Bidder] Is Authorizing The Head Of The Procuring Entity Or Its Duly Authorized Representative(s) To Verify All The Documents Submitted; 6. Select One, Delete The Rest: If A Sole Proprietorship: The Owner Or Sole Proprietor Is Not Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Partnership Or Cooperative: None Of The Officers And Members Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; If A Corporation Or Joint Venture: None Of The Officers, Directors, And Controlling Stockholders Of [name Of Bidder] Is Related To The Head Of The Procuring Entity, Members Of The Bids And Awards Committee (bac), The Technical Working Group, And The Bac Secretariat, The Head Of The Project Management Office Or The End-user Unit, And The Project Consultants By Consanguinity Or Affinity Up To The Third Civil Degree; 7. [name Of Bidder] Complies With Existing Labor Laws And Standards; And 8. [name Of Bidder] Is Aware Of And Has Undertaken The Following Responsibilities As A Bidder: A) Carefully Examine All Of The Bidding Documents; B) Acknowledging All Conditions, Local Or Otherwise, Affecting The Implementation Of The Contract; C) Making An Estimate Of The Facilities Available And Needed For The Contract To Be Bid, If Any; And D) Inquiring Or Securing Supplemental/bid Bulletin(s) Issued For The [name Of The Project]. 9. [name Of Bidder] Did Not Give Or Pay, Directly Or Indirectly, Any Commission, Amount, Fee, Or Any Form Of Consideration, Pecuniary Or Otherwise, To Any Person Or Official, Personnel Or Representative Of The Government In Relation To Any Procurement Project Or Activity. 10. In Case Of Advance Payment Was Made Or Given, Failure To Perform Or Deliver Any Of The Obligations And Undertakings In The Contract Shall Be Sufficient Grounds To Constitute Criminal Liability For Swindling(estafa) Or The Commission Of Fraud With Unfaithfulness Or Abuse Of Confidence Through Misappropriating Or Converting Any Payment Received By A Person Or Entity Under An Obligation Involving The Duty To Deliver Certain Goods Or Services, To The Prejudice Of The Public And The Government Of The Philippines Pursuant To Article 315 Of Act No. 3815 Series Of 1930, As Amended, Or The Revised Penal Code. In Witness Whereof, I Have Hereunto Set My Hand This ___________ Day Of __________________, 2025 At ____________, Philippines. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. ______________ Page No: ______________ Book No. ______________ Series Of 2025. Infr-04-2025 Irosin Memorial Park Improvement(phase Iii) Irosin, Sorsogon Standard Form Number: Sf-infr-51 Revised On: August 11, 2004 Affidavit Of Site Inspection I, ________________________, Of Legal Age, _____________, Filipino And Residing At __________________________, Under Oath, Hereby Depose And Say: 1. That I Am The _________________________ Of The ____________________________________________, With Office Address At ______________________________; 2. That I Have Inspected The Site For Irosin Memorial Park Improvement(phase Iii); 3. That I Am Making This Statement As Part Of The Requirement For The Technical Proposal Of The _________________________ Of ___________________________. In Faith Whereof, I Hereby Affix My Signature This ______ Day Of ________, 2025 At _________________________, Philippines. ___________________ Affiant Subscribed And Sworn To Before Me This ____ Day Of _________ 2025, Affiant Exhibiting To Me His/her Community Tax Certificate No. _______________ Issued On ________________ At ______________________________, Philippines. _______________________ Notary Public Until ______________ Ptr No. ______________ Date ______________ Place ______________ Tin ______________ Doc No. __________ Page No. _________ Book No. _________ Series Of _________. Republic Of The Philipppines ) City Of Sorsogon ) S.s. X ---------------------------------------------------x Bid Securing Declaration Project Identification No. Infr-04-2025 To: [insert Name And Address Of Procuring Entity] I/we, The Undersigned, Declare That: 1. I/we Understand That, According To Your Conditions, Bids Must Be Supported By A Bid Security, Which May Be In The Form Of A Bid-securing Declaration. 2. I/we Accept That: (a) I Will Be Automatically Disqualified From Bidding For Any Procurement Contract With Any Procuring Entity For A Period Of Two(2) Years Upon Receipt Of Your Blacklisting Order; And, (b) I/we Will Pay The Applicable Fine Provided Under Section 6 Of The Guidelines On The Use Of Bid Securing Declaration, Within Fifteen(15) Days From Receipt Of The Written Demand By The Procuring Entity For The Commission Of Acts Resulting To The Enforcement Of The Bid Securing Declaration Under Sections 23.1(b), 34.2, 40.1 And 69.1(f) Of The Irr Of Ra No. 9184; Without Prejudice To Other Legal Action The Government May Undertake. 3. I/we Understand That This Bid-securing Declaration Shall Cease To Be Valid On The Following Circumstances: (a) Upon Expiration Of The Bid Validity Period, Or Any Extension Thereof Pursuant To Your Request; (b) I Am Declared Ineligible Or Post Disqualified Upon Receipt Of Your Notice To Such Effect, And (i) I/we Failed To Timely File A Request For Reconsideration Or (ii) I/we Filed A Waiver To Avail Of Said Right; And (c) I Am/we Declared As The Bidder With The Lowest Calculated And Responsive Bid And I/we Have Furnished The Performance Security And Signed The Contract. In Witness Whereof, I Have Hereunto Set My Hand This _____ Day Of ________, 2025 At __________________. _____________________________________ Bidder’s Representative/authorized Signatory [insert Signatory’s Legal Capacity] Affiant Acknowledgement Before Me, As The Notary Public For And In The City/municipality Of _____________, Personally Appeared _________________, Representing The ________________________ With _____________ Issued On __________ At __________________ And ___________________, _____________________ Representing ________________________ With ______________________ Issued On _________________ At __________________________, Known To Me The Same Persons Who Executed The Foregoing Document And They Acknowledged To Me That The Same Are Their True Act And Deed For And In Behalf Of The Parties They Represent. In Witness Whereof, I Have Hereunto Affixed My Signature And Seal This _______ Day _____________, Philippines. Doc. No. __________ Page No. __________ Book No. __________ Series Of 2025.