Hvac Tenders

Details: Introduction network Contracting Office 1 (nco 1), Supporting Va New England Healthcare System (visn 1) And The Va Boston Healthcare System (hcs) Is Seeking Potential Sources For An Upcoming Requirement As Described In The Attached Statement Of Work For The Project; Upgrade Visn 1 Laundry Building 45. This Notice Is Not A Request For Proposals. This Notice Is A Market Research Tool And Has Not Been Set-aside For Any Small Business Category, However The Notice Is Issued To Determine Appropriate Set-aside Categories. Responses To This Notice, In Conjunction With Other Government Market Research Resources, Will Be Used By The Contracting Officer To Determine The Applicable Socio-economic Set-aside For The Procurement. the Purpose Of This Notice Is To Determine If There Are Qualified Sdvosbs Or Vosbs, Wosbs, And Small Businesses That Have The Experience With This Type Of Work And If Such Firms Are Interested In This Procurement. Once The Appropriate Set-aside Is Determined, A Separate Public Announcement Requesting Bids Or Proposals Will Be Publicized On Sam.gov Contract Opportunities In Accordance With 40 U.s. Code § 1101 And Far 36.601. The Solicitation Is Estimated To Be Released In January 2025. general Project Description, Magnitude, And Naics the Va Boston Hcs In Brockton, Ma, Requires A Contractor To All Labor, Equipment, Materials And Supervision For The Renovation And Improvements Of The Visn 1 Laundry, Building 45 For Veterans Affairs Medical Center, Brockton, Massachusetts In Accordance With Contract Documents. the Renovation Includes Selective Demolition Of All Existing Mechanical, Electrical And Plumbing (mep) Systems, Selective Demolition Of Existing Finishes, Doors, Structural Slab, And Other Existing Items. The Renovation Also Includes The Construction Of Structural Improvements, Doors, Electrical Systems, Hvac Systems, Plumbing Systems, Start-up Of Previously Installed Elevator By Renovating Associated Electrical And Mechanical Components, And Interior And Exterior Finishes. In Addition To The Renovation, The Improvements To Building 45 Include Ensuring Exterior Envelop Around Doors, Windows, And Stair Towers Along With Any Penetrations Are Sealed Properly. Moreover, Renovation Includes Construction Of A Service Platform And Stairs For Dedicated Emergency Generator System. The Focus Of The Project Is To Provide Structural Slab Repairs And Replacement To Sustain Required Laundry Equipment Loads And Vibrations. this Project Also Requires Specialized Personnel, With Specified Experience, To Assist In The Cqc System Manager For The Following Areas, As Applicable: Electrical, Mechanical, Civil, Structural, Environmental, Architectural, Materials Technician Submittals Clerk, Commissioning Agent/leed Specialist, And Low Voltage Systems. These Individuals Or Specified Technical Companies Are Directly Employed By The General Contractor And Cannot Be Employed By A Supplier Or Subcontractor On This Project; Be Responsible To The Cqc System Manager; Be Physically Present At The Construction Site During Work On The Specialized Personnel S Areas Of Responsibility; Have The Necessary Education Or Experience In Accordance With The Experience Matrix Listed Herein. These Individuals Can Perform Other Duties But Need To Be Allowed Sufficient Time To Perform The Specialized Personnel S Assigned Quality Controls Duties As Described In The Cqc Plan. A Single Person Can Cover More Than One Area Provided That The Single Person Is Qualified To Perform Qc Activities In Each Designated And That Workload Allows. experience Matrix area qualifications civil graduate Civil Engineer Or Construction Manager With 2 Years Experience In The Type Of Work Being Performed On This Project Or Technician With 5 Years Related Experience. mechanical graduate Mechanical Engineer With 2 Years Experience Or Construction Professional With 5 Years Of Experience Supervising Mechanical Features Of Work In The Field With A Construction Company. electrical graduate Electrical Engineer With 2 Years Related Experience Or Construction Professional With 5 Years Of Experience Supervising Electrical Features Of Work In The Field With A Construction Company. structural graduate Civil Engineer (with Structural Track Or Focus), Structural Engineer, Or Construction Manager With 2 Years Experience Or Construction Professional With 5 Years Experience Supervising Structural Features Of Work In The Field With A Construction Company. architectural graduate Architect With 2 Years Experience Or Construction Professional With 5 Years Of Related Experience. environmental graduate Environmental Engineer With 3 Years Experience. submittals submittal Clerk With 1 Year Experience. concrete, Pavement, And Soils materials Technician With 2 Years Experience For The Appropriate Area. testing, Adjusting, And balancing (tab) specialist Must Be A Member Of Aabc Or An Experienced Technician Of The Firm Certified By The Nebb. design Quality Control Manager registered Architect Or Professional Engineer the Estimated Magnitude Of This Construction Project Is Between $5,000,000.00 And $10,000,000.00. This Information Is Provided Per Vaar 836.204. The Naics Code Is 236220 And The Small Business Size Standard Is $45 Million. Interested Parties Should Indicate Their Interest To Kyle Kiepke No Later Than 4:00 Pm Est December 1, 2024, Via Email At Kyle.kiepke@va.gov. information Sought a) Sam Unique Entity Id (uei) b) Bonding Capability; Per Contract And Aggregate. Provide Amount Of Aggregate Bonding Currently Available (i.e., Amount Not Committed). c) Is The Anticipated Period Of Performance Realistic For This Project? d) Experience In Managing Construction Projects Between $5,000,000.00 And $10,000,000.00. Include General Information And Technical Background Describing Your Firm's Experience On Contracts Requiring Similar Efforts To Meet The Program Objectives. e) Experience. Submission Of A Maximum Of Five Examples Of Completed Or Substantially Completed (eighty Percent (80%)) Projects Of Similar Size And Scope To The Upgrade Visn 1 Laundry Building 45 Project. Relevant Experience Shall Include Projects Valued At $5m Or Greater, Shall Be Similar In Scope And Complexity, To Include Structural Concerns, And Quality Control Staffing, As The Proposed Upgrade Visn 1 Laundry Building 45 Project And Shall Be Recent (completed Within The Last Eight (8) Years). f) Average Price Per Square Foot For Each Project Identified Under Paragraph (i) Above, Using The Total Modified Value Of The Contract. g) Are Your Sub-contractors From The Local Area Or Will They Be Coming From Out Of The Area, If So, From Where? submission Instructions interested Firms Shall Hold Active Sam Registration. Visit Www.sam.gov To Register In This Database. sdvosb Or Vosb Firms Shall Be Certified By Veterans Small Business Certification (vetcert) (veterans Small Business Certification (sba.gov). all Information Must Be Submitted In Sufficient Detail For A Decision To Be Made. Failure To Submit All Information Requested In Addition To The Below Form May Result In A Contractor Not Being Considered As An Interested Concern. If Adequate Interest Is Not Received By 4:00 Pm Est On December 1, 2024, This Action May Not Be Set-aside For Sdvosbs, Vosbs, Wosbs, Or Small Business Firms. Interested Firms Must Reply Via E-mail To Kyle.kiepke@va,gov With The Subject Attention: 36c24125r0008 - Upgrade Visn 1 Laundry Building 45 . disclaimer this Sources Sought Is Issued Solely For Information And Planning Purposes Only And Does Not Constitute A Solicitation. All Information Received In Response To This Request That Is Marked As Proprietary Will Be Handled Accordingly. In Accordance With Far 15.201(e), Responses To This Notice Are Not Offers And Cannot Be Accepted By The Government To Form A Binding Contract. Responders Are Solely Responsible For All Expenses Associated With Responding To This Notice.

Details: 8/29/2024: Posting Amendment 0005 And Associated Documents Within Piee/solicitation Module_____8/29/2024: Uploaded Amendment 0004 Within Piee/solicitation Module_____8/29/2024: Posting Solicitation Amendment 0005 And Associated Documents. Due To Technical Difficulties, Amendment 0004 And 0005 Were Not Embedded Within Piee/solicitation Module And Rather Are Directly Uploaded Into Sam.gov For This Contract Opportunity _____8/27/2024: Posting Solicitation Amendment 0004 And Associated Documents_____8/22/2024: Posting Solicitation Amendment 0003 And Associated Documents_____8/15/2024: Posting Solicitation Amendment 0002 And Associated Documents_____8/9/2024: Posting Solicitation Amendment 0001 And Associated Documents.___this Is A Solicitation Notice, Request For Proposal Single Project Rfp Set-aside For Small Businesses Naics Code: 236220 - Commercial And Institutional Building Construction The Hawaii National Guard Intends To Issue A Request For Proposals (rfp) To Award A Single Firm Fixed-price Contract For Services, Non-personal, To Provide All Plant, Labor, Transportation, Materials, Tools, Equipment, Appliances And Supervision Necessary For The Construction Of - Knmd202094 Repair Corrosion Control Facility B3407, Hiang, Jbphh, Hi. Work Covered In This Project Includes But Is Not Limited To: Repair Of Existing Facility F-22 Light Low Observational, Corrosion Control, Wash Rack And Fuel Cell Repair Facility Utilizing Conventional Design And Construction Methods To Accommodate The Mission Of The Facility. Repair Minor Spalls And Crack In Existing Hangar Floors Then Finish With Protective Sealant. Repair The Facility Exterior And Replace Facility Life-cycle Roof To Align With The Current Base Standards. Renovate Functional Maintenance Shop Space, Restrooms Equipped With Shower And Locker Areas, And All Associated Administrative Support And Facility Support Spaces. All Exterior And Interior Renovation Will Include Painting. Replace Existing Facility 2-bay Maintenance Hangars To Accommodate F-22 Operations Including Bringing All Required Power (270 Voltage Direct Current), Hvac (power Panels For Equipment To Provide Cooling Air For Aircraft Avionics), Fire Suppression, Vacuum Equipment, Plumbing And Drainage System, And Electrical To All Covered Parking Spots (2). Maintenance Hangar Doors Are To Be In Compliance With Current Airfield Hanger Wind Design Requirements. Installation Of Airfield Concrete Pavement And Concrete Patching And Sealing. Concrete, Asphalt, And Other Site Improvements. Fire Suppression Upgrades To Incorporate The 2021 Foam Fire Suppression Sundown Directive. Seismic Analysis And Retrofitting Upgrades, To Include Seismic Bracing On Installed Equipment And Augmenting Bracing And Connections, Are Included To Ensure Structural Durability Of The Facility. Seismic Upgrades To Achieve Partial Life Safety Structural Performance Level S-3 And Non-structural Performance Level N-a Operational, At A Minimum. Facility Will Receive A Lightning Protection System Adequate For F-22 Operations. In Addition To A Base Price For The Work Described Above The Solicitation Includes Government Options For This Project: 1. Kalwall; 2. Paving; 3. 5-coat Epoxy; 4. Entry Logo. The Contract Duration Will Be 550 Calendar Days After Notice To Proceed To Include Inspection And Punch List. This Project Is Set Aside 100% For Small Businesses. The North American Industry Classification System (naics) Code Is 236220, With A Small Business Size Standard Of $45,000,000. The Magnitude Of Construction Is Between $10,000,000 And $25,000,000.a Pre-proposal Conference Is Scheduled On 06 August 2024, 08:00 Am Local Time, Location To Be Provided In The Solicitation. Interested Contractors Are Encouraged To Attend And Shall Follow Conference Registration And Base Access Requirements Shown In The Solicitation. A Site Visit Will Follow The Preproposal Conference. All Questions For The Pre-bid Conference Must Be Submitted By 05 August 2024 Via Email To Cezar.y.deveas.mil@army.mil And Copy To Anthony.g.reyes1.civ @army.mil.the Solicitation Closing Date Is 02 Sep 2024. Actual Dates And Times Will Be Identified In The Solicitation. The Source Selection Process Will Be Conducted In Accordance With The Source Selection Procedures Described In Far 15.3, Dfars 215.3, And Afars 5115.3. Evaluation Factors Include Technical Capability, Past Performance And Price. The Government Intends To Award A Contract Without Conducting Discussions. Interested Offerors Must Be Registered In The System For Award Management (sam). To Register Go To Www.sam.gov. Instructions For Registering Are On The Web Page (there Is No Fee For Registration).the Solicitation And Associated Information Will Be Posted Within Procurement Integrated Enterprise Environment (piee) Solicitation Module And Subsequently Uploaded Into The Contract Opportunities Page At Sam.gov. Per The Solicitation Requirements, Offerors Are Required To Submit Their Proposals Through The Vendor Portal For Solicitations Within The Piee Platform. A Proposal Manager Role Is Required To Submit An Offer To A Solicitation Posted In The Piee Solicitation Module. A Piee Solicitation Module Vendor Access Instructions Is Attached. If Your Company Is New To Piee And Has No Account Administrator, The Link Below Provides The General Steps In Getting Started As A Vendor To Use The Piee Solicitation Module And Other Piee Applications:https://pieetraining.eb.mil/wbt/xhtml/wbt/portal/overview/vendorregister.xhtmlthis Solicitation Is Not An Invitation For Bids And There Will Not Be A Formal Public Bid Opening. All Inquiries Must Be In Writing, Preferably Via Email To The Persons Specified In The Solicitation. All Answers Will Be Provided In Writing Via Posting To Sam.gov. If You Have Any Questions Concerning This Procurement You Are Encouraged To Email Your Questions To Cezar.y.deveas.mil@army.mil And Copy To Anthony.g.reyes1.civ @army.mil.your Attention Is Directed To Far Clause 52.219-14(e)(3) (deviation 2021-o0008), Limitations On Subcontracting, Which States -by Submission Of An Offer And Execution Of A Contract, The Offeror/contractor Agrees In Performance Of The Contract For General Construction, It Will Not Pay More Than 85 Percent Of The Amount Paid By The Government For Contract Performance, Excluding The Cost Of Materials, To Subcontractors That Are Not Similarly Situated Entities. Any Work That A Similarly Situated Entity Further Subcontracts Will Count Towards The Prime Contractors 85 Percent Subcontract Amount That Cannot Be Exceeded-.in Accordance With Far 36.211(b), The Following Information Is Provided:(1) the National Guard Has No Agency-specific Policies Or Procedures Applicable To Definitization Of Equitable Adjustments For Change Orders Under Construction Contracts Other Than Those Described At Far 43.204, Dfars 243.204 And Afars 5143.204.(2) data For The Prior 3 Fiscal Years Regarding The Time Required To Definitize Equitable Adjustments For Change Orders Under Construction Contracts For The National Guard Is Currently Not Available, But Will Be Compiled And Provided In Future Announcements. Disclaimer: The Official Plans And Specifications Are Located On The Official Government Webpage And The Government Is Not Liable For Information Furnished By Any Other Source. Amendments, If/when Issued Will Be Posted To Contract Opportunities For Electronic Downloading. This Will Normally Be The Only Method Of Distributing Amendments Prior To Closing; Therefore, It Is The Offerors Responsibility To Check The Website Periodically For Any Amendments To The Solicitation. Websites Are Occasionally Inaccessible For Various Reasons. The Government Is Not Responsible For Any Loss Of Internet Connectivity Or For An Offerors Inability To Access The Documents Posted On The Referenced Web Pages. The Government Will Not Issue Paper Copies.

Details: A Market Survey Is Being Conducted To Determine If There Are A Reasonable Number Of Interested Small Business Concerns To Set This Future Project Aside For Them. If Your Firm Is A Small Business, Certified Hubzone, 8a, Woman-owned Small Business Or Service-disabled Veteran Owned Small Business And You Are Interested In This Project Please Respond Appropriately. project Location: Wright Patterson Air Force Base – Dayton, Ohio project Description: This Project Is For A Design-bid-build Construction To Renovate Materials Analysis Lab F/20071. This Project Consists Of Renovation Of 8,400 Sq Ft Across Multiple Laboratories In Facility 20071 To Expand Interior Space, Upgrade Security, And Modernize Research Space. The Project Includes Construction Of Second Floor Areas In 1, 2, 6, & 7 Stands. Existing Machine Shop Equipment Presently Located In 2-stand Will Be Relocated To 7-stand. Renovation Of 6 & 7 Stands Includes Removal/repair Of Concrete Floors And Installation Of New Vibration-isolated Floor Slabs In 7-stand. the Mechanical Support Space Located Between 6 & 7 Stands Will Be Renovated To Include The Addition Of New Restrooms On The First Floor And Administrative Space On The 2nd Floor. The 2nd Floor Area Will Be Extended To Connect With The Northern Exterior Wall. Upgrades To 6 & 7-stands Includes Installation Of New Hvac And Roof Repairs. renovations Also Include Upgrades To 1 And 2 Stands, And 6 & 7 Stands As Special Access Program (sap) Areas In Compliance With Icd 705 Standards Including Installation Of Intrusion Detection Systems (ids) And Access Control Systems (acs). contract Duration Is Estimated At 836 Calendar Days. The Estimated Cost Range Is Between $10,000,000 And $25,000,000. Naics Code Is 236220. All Interested Small Businesses, Certified Hubzone, 8a, Woman-owned Small Business Or Service-disabled Veteran Owned Small Business Contractors Should Respond To This Survey Via Email By Wednesday, June 26, 2024 By 3:00 Pm Eastern Standard Time. responses Should Include: identification And Verification Of The Company’s Small Business Status. contractor’s Unique Entity Identifier (uei)) And Cage Code(s). documentation From The Firm’s Bonding Company Showing Current Single And Aggregate Performance And Payment Bond Limits. description Of Experience – Provide Descriptions Your Firm’s Past Experience On Up To Three (3) Projects With Greater Than 90% Construction Complete Or Those Projects Completed Within The Last Five Years Which Are Similar To This Project In Size, And Scope. Provide Documentation Demonstrating Experience For Construction Of Similar Type Buildings And Managing Multiple Sub-contractors. Demonstrate Experience Including Self-performing 15% Of The Construction. Provide Documentation Demonstrating Experience For Projects Of Similar Type Projects. Each Project Must Include The Name, Title, Project Role, E-mail Address, And Telephone Number Of At Least One Reference. References May Be Used To Verify Project Size, Scope, Dollar Value, Percentages And Quality Of Performance. projects Similar In Scope To This Project Include: Renovation Of Multi-story Industrial Laboratory Facilities, With Storage Mezzanine, Office/administrative Areas And All Associated Site Work. Note: Following Issuance Of The Solicitation, As Part Of The Proposal Evaluation Phase, Additional Consideration May Be Given To Projects That Demonstrate Experience With Icd-705. projects Similar In Size To This Project Include: Combined Square Footage Of At Least 6,300 Sf. based On Definitions Above, For Each Project Submitted Include: current Percentage Of Construction Complete And The Date When It Was Or Will Be Completed. size Of The Project scope Of The Project the Dollar Value Of The Construction Contract the Percentage Of Work That Was Self-performed As Project And/or Construction Management Services Or Physical Construction Type Work. Must Be At Least 15% Self-performed. whether The Project Was Design Build Or Design/bid/build identify The Number Of Subcontractors By Construction Trade Utilized For Each Project. whether The Project Was Icd-705 Compliant. small Businesses Are Reminded Under Far 52.219-14, Limitations On Subcontracting; They Must Perform At Least 15% Of The Cost Of The Contract, Not Including The Cost Of Materials, With The Firm’s Own Employees For General Construction-type Procurement. Include The Percentage Of Work That Will Be Self-performed On This Project, And How It Will Be Accomplished. note: Total Submittal Package Shall Be No Longer Than 8 Pages. Please Only Include A Narrative Of The Requested Information; Additional Information Will Not Be Reviewed. email Responses And Any Questions To Megan Murphy At Megan.murphy@usace.army.mil. This Is Not A Request For Proposal And Does Not Constitute Any Commitment By The Government. Responses To This Sources Sought Notice Will Be Used By The Government To Make Appropriate Acquisition Decisions. All Interested Sources Must Respond To Future Solicitation Announcements Separately For Responses To This Market Survey. notice: The Following Information Is Provided For Situational Awareness And Is Not Required To Respond To This Sources Sought. all Contractors Must Be Registered In The System For Award Management (www.sam.gov) Prior To Award Of A Contract. All Proposed Contractors Are Highly Encouraged To Review Far Clause 52.232-33 Payments By Electronic Funds Transfer – System For Award Management, Which Indicates “all Payments By The Government Under This Contract Shall Be Made By Electronic Funds Transfer (eft).” Those Not Currently Registered Can Obtain Registration By Going To The Website Http://www.sam.gov. The Process Can Usually Be Completed From 24 To 48 Hours After Submission. Contractors Will Need To Obtain A Unique Entity Identifier (formerly Duns Number) For Processing Their Registration. If You Do Not Already Have A Unique Entity Identifier, One Can Be Obtained From Http://www.sam.gov. Refer To Www.sam.gov For Information Formerly Found In Ccr, Epls, Orca And Fedreg. please Begin The Registration Process Immediately In Order To Avoid Delay Of The Contract Award Should Your Firm Be Selected. alert: You Must Submit A Notarized Letter Appointing The Authorized Entity Administrator Before Your Registration Will Be Activated. This Requirement Now Applies To Both New And Existing Entities. Effective 29 April 2018, The Notarized Letter Process Is Now Mandatory On All Current Registrants At Sam Who Have A Requirement To Update Data On Their Sam Record. The Notarized Letter Is Mandatory And Is Required Before The Gsa Federal Service Desk (fsd) Will Activate The Entity's Registration. effective 29 June 2018, Vendors Creating Or Updating Their Registration Can Have Their Registration Activated Prior To The Approval Of The Required Notarized Letter. However, The Signed Copy Of The Notarized Letter Must Be Sent To The Gsa Federal Service Desk (fsd) Within 30 Days Of Activation Or The Vendor Risks No Longer Being Active In Sam. vendors Can Check Whether An Account Is Active By Performing A Query By Their Cage Or Unique Entity Identifier (known As Duns). The New Registration Process May Now Take Several Weeks, So Vendors Are Highly Encouraged To Begin Registering As Soon As Possible To Avoid Any Possible Delays In Future Contract Awards. Remember, There Is No Cost To Use Sam. to Find Out Additional Information About The Changes Of The Sam Registration Process, Contractors Should Visit The Frequently Asked Questions (faq) Link Located At The Top Of The Sam Homepage (www.sam.gov).

Details: Sources Sought Synopsis For repair B5546 Crisis Action Center, barksdale Afb, Louisiana panswd-24-p-0000 001476 w9126g24r0z5u this Is A Sources Sought Announcement; A Market Survey For Information Only, To Be Used For Preliminary Planning Purposes. This Is Not A Solicitation For Proposals And No Contract Will Be Awarded from This Synopsis. No Reimbursement Will Be Made For Any Costs Associated With Providing Information In Response To This Synopsis Or Any Follow Up Information Requests. the U.s. Army Corps Of Engineers – Fort Worth District Has Been Tasked To Solicit For And Award A Project To Repair Bldg. 5546 Crisis Action Center, At Barksdale Afb, Louisiana. Proposed Project Will Be A Competitive, Firm-fixed Price, Design Bid Build Contract. The Government Intends To Issue A Solicitation; However, The Results And Analysis Of The Market Research Will Finalize The Determination Of Procurement Method. The Type Of Set-aside Decision To Be Issued Will Depend Upon The Capabilities Of The Responses To This Synopsis. the Purpose Of This Synopsis Is To Gain Knowledge Of Interest, Capabilities And Qualifications Of Various Members Of Industry, To Include The Small Business Community: Small Business, Small Disadvantaged Business (sdb) To Include The 8(a) Program, Historically Underutilized Business Zones (hubzone), And Service-disabled Veteran-owned Small Business (sdvosb). The Government Must Ensure There Is Adequate Competition Among The Potential Pool Of Responsible Contractors. Small Business, Section 8(a), Hubzone, Sdvosb And Businesses Are Highly Encouraged To Participate. project Scope: the Government Is Seeking Qualified, Experienced Sources Capable Of Renovating A Portion Of The Second And Third Floor Of Bldg. 5546 At Barksdale Afb, Louisiana To Serve As The Afgsc Headquarters And Housing The Afgsc Crisis Action Center (cac). The Renovation Of This Existing Administrative Facilities Will Serve As The Continuity Of Operations Site For Tier 1 & 2 Relocations For Jgsoc, Aoc, And The 2bw Command Post. the Project Encompasses The Transformation Of A 9,000 Sf Area To Adhere To Icd-705 Compliance Standards. The Proposed Requirements For This Area Include The Establishment Of A Crisis Action Center Capable Of Accommodating 30 Individuals, Incorporating 30 Workstations Interconnected Across Various Networks, And Featuring A Multi-screen Focal Point Potentially Manifested As A Data Wall Or Projection System. This Renovation Will Effectively Utilize The Presently Available Open Space On The 3rd Floor. The Design Incorporates Offices, Cubicle-style Workstations, Following A 6x6 Configuration To Optimize Collaborative Productivity; The Utilization Of Existing Restroom Facilities For Operational Efficiency; The Establishment Of A Breakroom Strategically Accessible From Both The 3rd And 2nd Floors; The Designation Of A Server Room On The 2nd Floor To Centralize Critical Equipment; The Allocation Of Storage Areas On The 2nd Floor To Facilitate Organizational Needs; The Creation Of A 2nd-floor Conference Room Intended For 25 Personnel, Equipped With Secure Video Teleconferencing (svtc) Capabilities; A Counterpart 3rd-floor Conference Room Catering To The Same Capacity And Capabilities; Integration Of Various Equipment Such As Printers, Shredders, Tvs, Secure Video Teleconferencing (svtc) Setups, And Secure Messaging Systems (sms); And Lastly, The Incorporation Of An Entrapment Area Along With Designated Storage Zones To Address Security Considerations. Each Workstation Will Be “wired” For All Networks, Including Sipr, Nipr, Jwics, Gold, And Orange. Access Via Stairs, Eliminating The Need To Traverse Through The Cac Large Display Room, Is Preferred. The Existing Roof Structure And Dormers Serve As The Envelope Due To The Absence Of An Attic. Parts Of This Area Have A Raised Flooring System. Moreover, Placement Of The Staircase Will Be Determined, Taking Into Account Compliance With Icd 705 Regulations Regarding Interior Versus Exterior Envelope Access. Lighting Arrangements Pose A Challenge Within The Double-height Space; Hence, A Drop-down Cable System Will Facilitate Lighting Unit Changes. Integration Of Alarm And Hvac Systems Will Seamlessly Adhere To The Established Barksdale Afb Requirements And Standards. Additionally, The Potential For Expanding The Floor Plate To Enclose Approximately 2,000 Sq. Ft. On The 3rd Floor Will Be Explored, Provided It Does Not Conflict With The Projection/data Wall Requirements. in Accordance With Dfar Part 236, The Construction Magnitude Is Between $10,000,000 And $25,000,000. the Estimated Duration Of The Project Is 550 Calendar Days. the North American Industry Classification System Code For This Procurement Is 236220 Which Has A Small Business Size Standard Of $39.5 Million. the Product Supply Code (psc) Is Y1az. small Businesses Are Reminded Under Far 52.219-14, Limitations On Subcontracting, They Must Perform At Least 15% Of The Cost Of The Contract, Not Including The Cost Of Materials, With Their Own Employees For General Construction-type Procurement. If A Large Business Firm Is Selected For This Announcement, They Must Also Comply With The Far 52.219-9 Clause Regarding The Requirement For An Approved Subcontracting Plan. should The Acquisition Be Set-aside For The 8(a) Program, 8(a) Firms Are Reminded They Need To Have A Bona Fide Office In The Geographical Area Of Consideration Where The Work Is To Be Performed As Determined By Sba. prior Government Contract Work Is Not Required For Submitting A Response Under This Source Sought Synopsis. However, All Construction Performance Must Be In Compliance With The Usace Safety And Health Requirements Manual, (em 385- 1-1, And Must Also Comply With All Federal, State And Local Laws, Ordinances, Codes And/or Regulations. the Type Of Solicitation To Be Issued Will Be A Design Bid Build Rfp. No Reimbursement Will Be Made For Any Costs Associated With Providing Information In Response To This Synopsis Or Any Follow Up Information Requests. Anticipated Solicitation Issuance Date Is On Or About 14 November 2024, And The Estimated Proposal Due Date Will Be On Or About 14 December 2024. The Official Synopsis Citing The Solicitation Number Will Be Issued Via Sam.gov Website At Https://sam.gov And Inviting Firms To Register Electronically To Receive A Copy Of The Solicitation When It Is Issued. firm’s Response To This Synopsis Shall Be Limited To 5 Pages And Shall Include The Following Information: firm's Name, Address, Point Of Contact, Phone Number, And E-mail Address. firm's Interest In Proposing On The Construction Of A Crisis Action Center, Barksdale Afb, Louisiana (as Described In The Project Scope Above). firm's Capability To Perform A Contract Of This Magnitude And Complexity, Including The Firm's Capability To Execute Construction Comparable Work Performed Within The Past Five Years. Incorporate A Brief Description Of The Project, Customer's Name, Timeline Of Performance, Customer Satisfaction And Dollar Value Of The Project - Provide At Least Three Examples. firm's Size: Large, Small Business Category And Business Size, (small Business, Small Business, Small Disadvantaged Business (sdb) To Include The 8(a) Program, Historically Underutilized Business Zones (hubzone), Service- Disabled Veteran-owned Small Business (sdvosb),). firm's Joint Venture Information If Applicable - Existing And Potential. firm's Bonding Capability (bonding Level Per Contract And Aggregate Bonding Level, Both Expressed In Dollars, Via Letter From The Bonding Company). interested Firms Shall Respond To This Sources Sought Synopsis No Later Than 2:00 P.m. Cst, 09 February 2024 Via Email Only. All Interested Firms Must Be Registered In Sam (www.sam.gov) To Be Eligible For Award Of Government Contracts. Please Email Your Response To Both: jesus Floriano, Contract Specialist contracting Division, Usace - Fort Worth District, Fort Worth, Tx 76102 email: Jesus.j.floriano@usace.army.mil terry Hardin, Contracting Officer contracting Division, Usace - Fort Worth District, Fort Worth, Tx 76102 email: Terry.hardin@usace.army.mil

Details: Sources Sought w9126g25r1668 renovate Buildings 10006 And 10008 Hammerhead Renovations, Fort Cavazos, Texas, Bell County us Army Corps Of Engineers fort Worth District disclaimer this Sources-sought Is For Informational Purposes Only. This Is Not A "request For Proposal (rfp)" To Be Submitted. It Does Not Constitute A Solicitation And Shall Not Be Construed As A Commitment By The Government. Responses In Any Form Are Not Offers And The Government Is Under No Obligation To Award A Contract As A Result Of This Announcement. No Funds Are Available To Pay For Preparation Of Responses To This Announcement. Any Information Submitted By Respondents To This Technical Description Is Strictly Voluntary. Responses Will Not Be Returned To The Responder. Not Responding To This Notice Does Not Preclude Participation In Any Future Request For Quote (rfq) Or Invitation For Bid (ifb) Or Request For Proposal (rfp), If Any Issued. If A Solicitation Is Released, It Will Be Synopsized On The Government-wide Point Of Entry (gpe). It Is The Responsibility Of Potential Offerors To Monitor The Gpe For Additional Information Pertaining To This Requirement. introduction the Us Army Corps Of Engineers, Fort Worth District Is Issuing A Sources Sought Synopsis As A Means Of Conducting Market Research To Determine If Small Business Firms Are Available To Support The Requirement For A Firm Fixed-price, Design-bid-build Construction Project For New Construction Located At Fort Cavazos, Texas. based On The Responses To This Sources Sought Notice, The Government Will Assess Small Business Capabilities To Satisfy The Agency’s Requirements And Decide If This Procurement Should Be Set-aside For Small Business. Telephone Inquiries Will Not Be Accepted Or Acknowledged, And No Feedback Or Evaluations Will Be Provided To Companies Regarding Their Submissions. place Of Performance fort Cavazos, Texas Bell County program Background the U.s. Army Corps Of Engineers – Fort Worth District Has Been Tasked To Solicit For An Award Of A Design-build Construction Contract For The Renovations Of Buildings 10006 And 10008 Hammerhead Renovations, On Fort Cavazos, Texas. The Proposed Project Will Be A Competitive, Firm-fixed Price Procurement. The Acquisition Strategy Decision Will Be Based On The Respondent’s Capabilities From This Source Sought And/or Other Market Research Methods. the Purpose Of This Synopsis Is To Gain Knowledge Of Interest, Capabilities, And Qualifications Of Various Members Of The Small Business Community To Determine If There Are Two Or More Capable Small Businesses That Can Perform The Requirements Of The Scope Of Work Outlined Below. The Small Business Community Includes Small Business, Section 8(a), Historically Underutilized Business Zones (hubzone), Service-disabled Veteran-owned Small Business (sdvosb), And Women-owned Small Business (wosb). The Government Must Ensure There Is Adequate Competition Of Capable Firms. Small Business, 8(a), Hubzone, Sdvosb And Wosb Businesses Are Highly Encouraged To Participate. Be Advised That The U.s. Government Will Not Be Able To Set Aside This Requirement If Two Or More Small Businesses Do Not Respond With Information To Support The Set-aside. scope Of Work: in Accordance With Dfars 236.204, The Magnitude Of Construction For This Project Is Estimated Between $25,000,000 And $100,000,000. buildings Were Originally Constructed In The 1950’s And Last Renovated In The Early 2000’s. estimated Duration Of The Project Is 730 Calendar Days. Note: The Project Duration In The Actual Solicitation Could Be Increased Or Decreased. air Leak Test Results Showed Failing Building Envelope And Substandard Building Insulation; The Hvac System Is Inefficient And Failing. This Has Resulted In Substantial Mold Growth Due To Insufficient Humidity Control And Moisture Infiltration. The Electrical Systems Throughout The Buildings Are Old And Undersized And The Lighting Is Outdated. Neither Building Has A Fire Protection/ Mass Notification System. The Roofs Of Both Buildings Are In Need Of Replacement. the First Floor Of Each Building Is Administrative Space – Primarily Company Ops Facility (cof), However The Hammer Portion Of Each Barracks Is Classified As Battalion Hq. From Observation Inside Each Building, The Engineering Team Found That The Units Occupying These Spaces Are Nearly All Headquarters And Headquarter Company (hhc) Units, Which Would Not Be Supported By The Battalion Hq Cat Code. A New Floorplan Was Therefore Developed In The 10000 Block Renovations, Which Would Provide Enough Administrative Space For Three Companies Or 1 Company And 1 Hhc. the New Chiller Motors In The Cep 10017 Cut Out Automatically At 108 Degrees. There Is Currently No Climate Control For This Building, So It Is Difficult To Keep Them Operational In The Summer. Requested Response Information responses To This Synopsis Must Address At A Minimum The Following Items: information In Sufficient Detail Regarding Previous Experience (indicate Whether As A Prime Contractor Or Subcontractor) On Similar Requirements (include Size, Scope, Complexity, Timeframe, Government Or Commercial), Pertinent Certifications, Etc., That Will Facilitate Making A Capability Determination. Include How Your Company Has Successfully Managed Projects Of This Magnitude And Provide Specific Project Details Which Indicate How The Projects Are Similar In Size, Scope, And Complexity. Also Include Specific Technical Skills Your Company Possesses Which Will Ensure Capability To Perform The Project Scope. project Specific Items: can Your Company Manage A Safety Program During The Duration Of The Project? If So, Provide Details. b) Can Your Company Manage And Perform Work In An Occupied Office Building? c) Can Your Company Manage Upgrade Of Systems In An Occupied Building Requiring Systems To Remain Operational? 2) Can Or Has Your Company Managed A Team Of Subcontractors Before? If So, Provide Details. 3) Identify Whether Your Firm Is Interested In Competing For This Requirement As A Prime Contractor Or Not. Identify Subcontracting, Joint Ventures, Or Teaming Arrangement That Will Be Pursued, If Any. 4) Identify How The Army Can Best Structure These Contract Requirements To Facilitate Competition By And Among Small Business Concerns. Provide Any Additional Information Your Company Believes May Assist The Government In Deciding On Whether To Set This Project Aside For Small Business. 5) Identify Any Condition Or Action That May Be Having The Effect Of Unnecessarily Restricting Competition With Respect To This Acquisition. Please Contact Contracting Officer, Mr. Matthew Dickson, At Matthew.s.dickson@usace.army.mil Or 817-886-1110, If You Believe That This Action Is Unreasonably Restricting Competition. Include The Subject Of The Acquisition, This Announcement, And The Point Of Contact Information From The Sam.gov Notice. Provide The Specific Aspects That Unreasonably Restrict Competition And The Rationale For Such Conclusion. respondents To This Notice Must Also Provide A Current Capability Statement And Indicate Whether They Qualify As A Small, Small Disadvantaged, Women-owned, Hubzone, Or Service-disabled Veteran-owned Small Business Concern. the North American Industry Classification System Code For This Procurement Is 236220 Commercial And Institutional Building Construction Which Has A Small Business Size Standard Of $45m. the Product Service Code Is Z2fc. small Businesses Are Required To Comply With Far 52.219-14, Limitations On Subcontracting When Utilizing Subcontractors. Firm Will Not Pay More Than 85% Of The Amount Paid By The Government To The Prime’s Subcontractors That Are Not Similarly Situated. prior Government Contract Work Is Not Required For Submitting A Response To This Synopsis. However, Respondents Are Reminded That All Construction Performance Must Follow The Usace Safety And Health Requirements Manual, (em 385-1-1, And Must Also Comply With All Federal, State, And Local Laws, Ordinances, Codes And/or Regulations. responses To This Synopsis Shall Be Limited To 5 Pages And Shall Include The Contractor’s Capability Statement. interested Firms Shall Respond To This Synopsis No Later Than 29 March 2024, 4pm (central local Time). Email Your Response To Vernon Valigura At: Vernon.n.valigura2@usace.army.mil. email Is The Preferred Method When Receiving Responses To This Synopsis.

Details: Update 09/13/2024:see Attached Amendment 5 Whichincorporates The Most Up To Date Wage Determination Dated Aug 30, 2024, And Also Clarifies Hard Copy Bids Are Required In Addition To A Bid Disk On The Bid Due Date. update 09/10/2024: See Attached Amendment 4 Which Updated The Bid Opening Date (revised From 13 Sept To 17 Sept) And Adds Addendum 3 - Updates To Specificaions:01 14 00 – Work Restrictions, 08 34 16.10 – Horizontal Rolling Steel Doors, 09 06 00 – Schedule Of Finishes, G-002 – Sheet Index, G-201 – Special Inspections, G-202 – Special Inspections, G-203 – Special Inspections, A101 – Floor Plan, A103 – Roof Plan, A104 – Hangar Bay Floor Paint Striping Plan, A201 – Building Elevations, A500 – Details, A501 – Details, S-001 – General Notes, Sb102 – Slab Plan, Sb506 – Foundation Details, Sb507 – Foundation Details, Sb508 – Foundation Details, Eg502 – Grounding And Lightning Protection Details And Adds Two Attachments; Jbsa Soil Management Plan – Jan 22 And Kelly Annex Topographic – May 19. Also Included Are Rfi Responses To Questions 1-230. update 09/5/2024:see Attached Amendment 3 Which Updates The Bid Opening Date (revised From 10 Sept To 13 Sept) And Adds Addendum 2 - Updates To Specification - 08 34 16.10 And Drawing - A-603.many Rfi Responses Are Pending And Will Be Published In The Near Future. update 08/29/2024:see Attached Amendment 2 Which Updates The Bid Delivery Instructions And Add Attachment 11 - Geotechnical Report.also Included Are Rfi Responses To Questions 1-11. update 08/23/2024:see Attached Amendment 1 Which Deletes "attachment 9 - Falcon", And Incorporates Addendum 1, Specifications Volume 1 - Section 08 71 00 Door Hardware. Also Included Are Rfi Responses To Questions 1-5. update 08/15/2024: Attachment 1 (drawings) Was Re-uploaded Due To Rfi's Requesting Higher Fidelity Of Drawings. Attachment 1a And 1b Were Deleted Due To Low Quality During File Compression. the Texas Air National Guard Intends To Issue An Invitation For Bids To Award A Single Firm Fixed-price Contract For Non-personal Construction Services To Provide All Plant, Labor, Transportation, Materials, Tools, Equipment, Appliances And Supervision Necessary For The Construction Of A New 12,200 Square Foot Corrosion Control Facility Located At Joint Base San Antonio – Kelly Field Annex, In Accordance With Applicable Federal, State And Local Codes, Project Specifications, Project Drawings And Structural Interior Design. The Facility Shall Be Compatible With Applicable Dod, Air Force, And Base Design Standards. In Addition, Local Materials And Construction Techniques Shall Be Used Where Cost Effective. This Project Will Comply With Dod Antiterrorism/force Protection Requirements Per Unified Facilities Criteria. special Construction Requirements: Work Will Include An Environmentally Controlled Area To Wash Aircraft, As Well As Hangar Space For Corrosion Treatment, Corrosion Repair, And Limited Paint Removal/repainting. This Facility Also Provides Space For Corrosion Control Shops Which Includes Paint Preparation And Drying Areas, Abrasive Blasting Rooms, And Booth For Mixing And Applying Paint, Tool Storage, Lockers, And Administrative Areas. Furthermore, 1,500 Square Yards Of Airfield Pavements Are Expected For This Project. In Addition To A Base Price For The Work Described Above, The Solicitation Includes Four (4) Options And Brand Name Items Which Are Identified Below. this Facility Is For The Texas Air National Guard (txang), Joint Base San Antonio (jbsa) Lackland Air Force Base (afb) 149th Fighter Wing (fw). the Contract Duration Will Be540calendar Days After Notice To Proceed To Include Inspection And Punch List. This Project Is Set Aside 100% For Small Business. The North American Industry Classification System (naics) Code Is 236220, With A Small Business Size Standard Of $45,000,000. The Magnitude Of Construction Is Between $10,000,000 And $25,000,000. a Site Visit Will Be Held On 20 August At 09:00 Am (cst) Proceeded By A Pre-bid Conference. Access Must Be Requested No Later Than 5 Days Prior To The Pre-bid Conference. All Questions And Rfi's Must Be Submitted By 5:00 Pm Cst On 5 September 2024 Regardless Of Anytime Extensions To The Bid Due Date,via Email To: Msgt Mark Green, At Mark.green.23@us.af.mil, Msgt Joel Yerkey, At Joel.yerkey.1@us.af.mil And Ms. Amanda Bogue, At Amanda.m.bogue.civ@army.mil. actual Dates And Times Will Be Identified In The Solicitation. Interested Offerors Must Be Registered In The System For Award Management (sam). To Register Go To Www.sam.gov. Instructions For Registering Are On The Web Page (there Is No Fee For Registration). the Project Will Include A Base Bid Along With The Following Options: base Bid: Construct Aircraft Corrosion Control Facility option 1: Translucent Fiberglass Panel option 2: Screen Wall option 3: Alternate Roof (ssmr) option 4: Epoxy Flooring the Project Will Include The Following Brand Name Items Are Specific For Compatibility With Existing Installation Systems (noted Justifications Will Be Included With Solicitation): 1. Fire Alarm Control Panel: Monaco Maap-x 2. Heating, Ventilation, And Air Conditioning (hvac) Chiller System: Trane North America 3. Door Locks: Falcon Locksets With Falcon Brand Cores 4. Direct Digital Control: Automated Logic Corporation Webctrl Building Automation System the Solicitation And Associated Information Will Be Available Only From The Contract Opportunities Page At Sam.gov. your Attention Is Directed To Far Clause 52.219-14(e)(3) (deviation 2021-o0008), Limitations On Subcontracting, Which States “by Submission Of An Offer And Execution Of A Contract, The Contractor Agrees That In Performance Of A Contract Assigned A North American Industry Classification System (naics) Code For General Construction, It Will Not Pay More Than 85 Percent Of The Amount Paid By The Government For Contract Performance, Excluding The Cost Of Materials, To Subcontractors That Are Not Similarly Situated Entities. Any Work That A Similarly Situated Entity Further Subcontracts Will Count Towards The Prime Contractor’s 85 Percent Subcontract Amount That Cannot Be Exceeded”. in Accordance With Far 36.211(b), The Following Information Is Provided: the National Guard Has No Agency-specific Policies Or Procedures Applicable To Definitization Of Equitable Adjustments For Change Orders Under Construction Contracts Other Than Those Described At Far 43.204, Dfars 243.204 And Afars 5143.204. data For The Prior 3 Fiscal Years Regarding The Time Required To Definitize Equitable Adjustments For Change Orders Under Construction Contracts For The National Guard Is Currently Not Available But Will Be Compiled And Provided In Future Announcements. disclaimer: The Official Plans And Specifications Are Located On The Official Government Webpage And The Government Is Not Liable For Information Furnished By Any Other Source. Amendments, If/when Issued Will Be Posted To Contract Opportunities For Electronic Downloading. This Will Normally Be The Only Method Of Distributing Amendments Prior To Closing; Therefore, It Is The Offeror’s Responsibility To Check The Website Periodically For Any Amendments To The Solicitation. Websites Are Occasionally Inaccessible For Various Reasons. The Government Is Not Responsible For Any Loss Of Internet Connectivity Or For An Offeror’s Inability To Access The Documents Posted On The Referenced Web Pages. The Government Will Not Issue Paper Copies.

Details: The object of the procurement is the construction of a residential apartment building in Helsinki's Pohjoispasila Postipuisto as a fixed-price turnkey contract, including construction technical work and all HVAC work. The estimated start date is 08-09/2021 and the work must start no later than 10/2021","","the procurement will not be divided into parts, because the multi-supplier model would produce inappropriate schedule management of the entire contract as well as the coordination of the works and could endanger the achievement of an affordable cost level.

Details: The aim of the project is to redevelop the garden level of the Rambouillet Public Finance Center, located in an urban area at 2 Rue Pasteur in Rambouillet (78). The contract is allocated in the following manner: Lot 00: General; Lot 01: Cleaning, Asbestos Removal, Lead Removal; Lot 02: Fitting out - Partitions, False ceilings, Interior carpentry, Painting, Floor covering; Lot 03: Plumbing - HVAC; Lot 04: Electricity - High Current - Low Current;

Details: Work for the Creation of a Zonal Coordination Center for Combating Illegal Immigration on the 4th Floor of the Northern Prefecture Hotel. This Center should accommodate around twenty agents. The Works Are On Occupied Site. The Works Are Divided Into 5 Lots:#x0d; - Lot 01 Cleaning/lead removal; - Lot 02 Major Work / Wooden frame/roof; - Lot 03 Interior Fittings; - Lot 04 HVAC/Plumbing; - Lot 05 Electricity

Details: Contract for reorganization works of the secure post of the main entrance door (pep) at the Privas remand center (07)#x0d; The work consists of removing the bulletproof glass frame, installation of the bulletproof glass frame with document pass, supply and installation of metal grilles, supply and installation of Deny type locks. Other work concerns plastering, painting, false ceilings, wood carpentry, flexible floors, tiling, earthenware, HVAC, plumbing, electricity CFO/CFA