Hvac Tenders

Details: General Services Administration (gsa) Seeks To Lease The Following Space: state:california city:san Diego delineated Area: north: Beginning At Pacific Hwy And Ash St., Continue On Ash St. To Russ Blvd., east: Interstate 5 Freeway south: Hwy 75 To Harbor Dr. west: Pacific Hwy minimum Sq. Ft. (aboa):11,156 maximum Sq. Ft. (aboa):11,379 space Type:office And Related Space parking Spaces (total): 3 Reserved Structured Parking Spaces 16 Secured Fenced-in Structured Parking Spaces With A Minimum Vertical Clearance Of 6 Feet 8 Inches And An Access Path. Parking Must Be Able To Support Vehicles Weighing Up To 12,500 Pounds Per Vehicle. 21 Unreserved Structured Parking Spaces parking Spaces (surface):0 Surface parking Spaces (structured):40 Structured full Term:15 Years firm Term:10 Years option Term:n/a additional Requirements: space Will Be Occupied By Government Law Enforcement Agency With Special Build-out Requirements Including Firearms And Ammunition Storage; Secure Evidence Room, Holding Cell, Digital Science/computer Laboratory (not A Physical Science Lab.), Etc. space Cannot Be Located On The 1st Or Top Floor Of The Building space Cannot Be Located Near A Foreign Country Suite Or Office. space Must Have Access To A Loading Dock And Freight Elevator. 24/7 Hvac Will Be Required For Specific Rooms Within The Leased Space. additional Requirements To Be Stated In The Request For Lease Proposal (rlp). offered Space Must Meet Government Requirements For Fire Safety, Accessibility, Seismic, And Sustainability Standards Per The Terms Of The Lease. A Fully Serviced Lease Is Required. Offered Space Shall Not Be In The 100-year Flood Plain. entities Are Advised To Familiarize Themselves With The Telecommunications Prohibitions Outlined Under Section 889 Of The Fy19 National Defense Authorization Act (ndaa), As Implemented By The Federal Acquisition Regulation (far). ). For More Information, Visit: Https://acquisition.gov/far-case-2019-009/889_part_b. the U.s. Government Currently Occupies Office And Related Space In A Building Under A Lease In San Diego, That Will Be Expiring. The Government Is Considering Alternative Space If Economically Advantageous. In Making This Determination, The Government Will Consider, Among Other Things, The Availability Of Alternative Space That Potentially Can Satisfy The Government’s Requirements, As Well As Costs Likely To Be Incurred Through Relocating, Such As Physical Move Costs, Replication Of Tenant Improvements And Telecommunication Infrastructure, And Non-productive Agency Downtime. expressions Of Interest Due:january 15, 2025 market Survey (estimated):tbd occupancy (estimated):may 1, 2026 send Expressions Of Interest To: name/title: mash Braimah & John Winnek email Address: mash.braimah@gsa.gov; John.winnek@gsa.gov government Contact Information lease Contracting Officer:joseph Yu broker: cushman Wakefield – John Winnek And Mash Braimah – Slate Advisors, Llc (small Business Partner)

Details: Sources Sought Notice Construction Multiple Award Task Order Contract (matoc)this Sources Sought Notice Is Being Issued For Market Research Purposes To Determine The Availability, Capability, And Interest Of Large And Small Business Firms For A Potential Government Requirement. No Solicitation Is Available. Requests For A Solicitation Will Go Unanswered. No Award Will Be Made From This Notice. Responses Will Be Used To Determine Potential Acquisition Strategies, Understand Current Market Capabilities, And To Gain Knowledge Of Potential Sources. General Scope: The United States Army Corps Of Engineers (usace) Transatlantic Middle East District (tam) Anticipates A Potential Requirement For A Seven-year Construction Multiple Award Task Order Contract (matoc) To Provide Repair, Alteration, And Construction Services In Israel, Primarily For The Israeli Ministry Of Defense (imod), But May Be Used For Other Customers With Requirements In Israel. Task Orders May Include, But Are Not Limited To, Maintenance, Repairs, Alterations, Construction, Demolition, Excavation, Site And Infrastructure Improvements (e.g. Fencing, Utilities, Roads, Parking, And Drainage), System Maintenance (e.g. Heat Ventilation Air-conditioning (hvac)), Airfield Aprons And Pavements, Asbestos Abatement, And Any Supporting Work Necessary To Construct Complete And Usable Facilities To Support The Israeli Ministry Of Defense (imod) And Foreign Military Sales (fms) Programs. The Potential Requirement May Result In A Matoc Solicitation In Approximately May 2025. If Solicited, The Government Intends To Award The Anticipated Requirement By Approximately December 2025.in Accordance With Defense Federal Acquisition Regulation Supplement (dfars) 236.204(iii), The Government Currently Estimates The Magnitude Of Construction For The Potential Matoc Is Over $500,000,000. Anticipated Task Orders Are Expected To Range From $5,000,000 To $500,000,000. The North American Industrial Classification System (naics) Code For The Potential Requirement Is Anticipated To Be 236220 Commercial And Institutional Building Construction. Contractors With The Skill, Capabilities, Workload Capacity, And Ability To Obtain Bonding To Complete The Work Described Above (either Through Self-performance And/or Subcontractor Management) Are Invited To Provide Capability Statements To The Primary Point Of Contact Listed Below. Capability Statement: Responses Must Be Limited To 20 - 8.5?x11? Pages With A Minimum Font Size Of Arial Point 10 Or Equivalent. Please Complete The Attached Questionnaire. Please Submit All Capabilities Statements, Information, Brochures, And/or Marketing Material As One .pdf Document, Limited To The Page Maximum Above. Responses Will Not Be Considered An Offer, Proposal, Or Bid For Any Solicitation That May Result From This Notice. Moreover, Responses Will Not Restrict The Government To A Specific Acquisition Approach. This Notice Is For Information And Planning Purposes Only. Respondents Will Not Be Notified Of The Results Of Any Review Conducted Or The Capability Statements Received. Respondents Will Not Be Compensated. Please Provide Responses And/or Questions By E-mail To The Contract Specialist, Tracy Gusukuma At Tracy.m.gusukuma@usace.army.mil And The Contracting Officer, Matt Durbin At Matthew.d.durbin@usace.army.mil By 5:00 Pm (et) January 09, 2025.please Include The Sources Sought Notice Number, ?w912er25r13bb? In The E-mail Subject Line.

Details: Vhapg Part 813.5 Simplified Acquisition Procedures For Certain Commercial Items Attachment 1: Request For Sole Source Justification >sat-$7.5m Under Far13.5 effective Date: 11/15/24 revision: 01 acquisition Id#: 36c249-25-ap-0458 page2of3 department Of Veterans Affairs sole Source Justification Under Simplified Procedures For Certain Commercial Items In Accordance With Far 13.5 acquisition Plan Action Id: 36c249-25-ap-0458 contracting Activity: Department Of Veterans Affairs, Network Contracting Office (nco) 09, 1639 Medical Center Pky, Ste. 204, Murfreesboro, Tn 37129, Visn 09, Lt. Col. Luke Weathers, Jr. Veterans Affairs Medical Center (vamc), 116 N. Pauline St., Memphis, Tn 38105 2237: 614-25-1-5069-0033 Nature And/or Description Of The Action Being Processed: This Procurement Is For The Rental Of A Temporary Water Cooling Tower In Accordance With Far 13.5 Simplified Procedures For Certain Commercial Items And Specifically Far 13.501 Special Documentation Requirements, Where Acquisitions Conducted Under Simplified Acquisition Procedures Are Exempt From The Requirements Of Far Part 6, But Still Require A Justification Using The Format Of Far 6.303-2. The Rental Of A Temporary Water Cooling Tower Is Required And Will Be Awarded As A New Firm-fixed Contract With A Base Year And 1 (one) Option Year To Aggreko, Llc As The Only Responsible Source And No Other Supplies Or Services Will Satisfy Agency Requirements. description Of Supplies/services Required To Meet The Agency's Needs: rental Of Cooling Tower To Include: base Rental Cooling Tower Package one-time Cleaning Fee one-time Teardown Fee option Year Rental Cooling Tower Package Estimated Value: the Period Of Performance Is December 16, 2024 Through December 15, 2026. statutory Authority Permitting Restricted Competition: far 13.5 Simplified Procedures For Certain Commercial Items. The Statutory Authority For Applying The Simplified Procedures For Commercial Items Of Far 13.5 Is 41 U.s.c. § 1901 And Is Implemented By Far 13.106-l(b)(2) For Restricting Competition On This Procurement. Competition Is Restricted On This Procurement For The Reason Below: (x) Only One Responsible Source And No Other Supplies Or Services Will Satisfy Agency Requirements ( ) Unusual And Compelling Urgency ( ) Industrial Mobilization, Engineering, Developmental Or Research Capability Or Expert Services ( ) International Agreement ( ) Authorized Or Required By Statute ( ) National Security ( ) Public Interest demonstration That The Contractor's Unique Qualifications Or Nature Of The Acquisition Requires The Use Of The Authority Cited Above (applicability Of Authority): The Lt. Col. Luke Weathers, Jr. Is Currently Renting The Required Water Cooling Tower From Aggreko, Llc While Design And Construction Is Being Completed For A Permanent Water Cooling Tower. The Previous Contract, 36c24923p0726, Has Expired And Design And Construction Of The Permanent Water Cooling Tower Has Not Been Completed; Therefore, A Follow-on Contract Is Required. The Water Cooling Tower Is A Component Of A Major System: Heating, Ventilation, And Air Conditioning {hvac). To Remove And Install Another Cooling Tower Would Incur Substantial Duplication Of Cost To The Government As Opposed To The Continued Rental Of The Cooling Tower From Aggreko, Llc. Furthermore, To Remove The Current Tower And Install Another Rental Cooling Tower Would Cause Unacceptable Delays As The Hvac Would Be Incapable Of Efficient And Complete Operation. This Would Endanger The Health And Well-being Of Veteran Patients, Their Caregivers, And All Hospital Employees As Air Conditioning Would Not Work Properly. Accordingly, Aggreko, Llc Is The Only Firm Capable Of Providing The Services Described In Paragraph 3 Above Without The Veteran's Health Administration Experiencing Substantial Duplication Of Cost That Could Not Be Expected To Be Recovered Through Competition And Unacceptable Delays In Fulfilling Its Requirements. description Of Efforts Made To Ensure That Offers Are Solicited From As Many Potential Sources As Deemed Practicable: Based On Searches Of Government-wide Databases For The Rental Of Cooling Towers, It Does Not Appear That There Are Two Or More Sdvosbs Or Vosbs Capable Of Providing This Service. A Search Of Contractdirectory.gov Using Keywords "cooling Tower" Yielded No Results. A Search Of Vip Using Naics 238220 And Psc W041 Yielded No Results. A Search Of Sba Using Naics 238220 And Key Words "cooling Tower Rental" Yielded No Results. A Search Of Fpds Using Naics 238220 And Keywords "rental Cooling Tower" Found Only 5 Actions In The Last 18 Months And 3 Of These Were For Contract 36c24923p0726. This Action Will Not Be Competed. determination By The Co That The Anticipated Cost To The Government Will Be Fair And Reasonable: The Contracting Officer (co) Has Determined That The Cost Will Be Fair And Reasonable Based Upon Duplication Of Costs To Remove The Current Rented Cooling Tower And Install A New Rented One That Will Be Removed Once The Permanent Cooling Tower Has Been Installed. description Of The Market Research Conducted And The Results, Or A Statement Of The Reasons Market Research Was Not Conducted: Based On Searches Of Government-wide Databases For The Rental Of Cooling Towers, It Does Not Appear That There Are Two Or More Sdvosbs Or Vosbs Capable Of Providing This Service. Furthermore, The Cost Associated With The Removal The Currently Rented And Installation Of Another Would Be Duplicative And Prohibitive. It Would Also Endanger The Health And Well-being Of Veteran Patients, Their Caregivers, And All Hospital Employees As Air Conditioning Would Be Ceased During This Removal And Re-installation. any Other Facts Supporting The Use Of Other Than Full And Open Competition: None. listing Of Sources That Expressed, In Writing, An Interest In The Acquisition: Aggreko, Llc. A Statement Of The Actions, If Any, The Agency May Take To Remove Or Overcome Any Barriers To Competition Before Making Subsequent Acquisitions For The Supplies Or Services Required: No Subsequent Actions Are Planned As A Permanent Water Cooling Tower Is Being Designed And Constructed. It Will Be Completed Before The Ultimate Completion Date Of This Action. One Option Year Is Sought Due To An Unforeseen Delay In The Design And Construction Of A Permanent Water Cooling Tower. An Option Year Is Proposed Because The Work Required Will Be The Same And It Is Estimated That The Design And Construction Of The Permanent Water Cooling Tower Will Take More Than One Year But Not More Than Two. requirements Certification: I Certify That The Requirement Outlined In This Justification Is A Bona Fide Need Of The Department Of Veterans Affairs And That The Supporting Data Under My Cognizance, Which Are Included In The Justification, Are Accurate And Complete To The Best Of My Knowledge And Belief. keith Hawkins digitally Signed By Keith Hawkins Date: 2024.11.22 08:28:38 -06'00' keith Hawkins, Cor Date ac Equipment Operator lt. Col. Luke Weathers, Jr. Va Medical Center approvals In Accordance With The Vhapm Part 806.3 Ofoc Sop: contracting Officer Or Designee's Certification (required): I Certify That The Foregoing Justification Is Accurate And Complete To The Best Of My Knowledge And Belief. diane Ziegler diane Ziegler Contracting Officer network Contracting Office 9 Digitally Signed By Diane Ziegler Date: 2024.12.10 14:44:35 -06'00' date one Level Above The Contracting Officer (required Over Sat But Not Exceeding $7s0k): I Certify The Justification Meets Requirements For Other Than Full And Open Competition. digitally Signed By Roxie roxie Keese; !\024.12.1016:44:s, -05'00' roxie Keese branch Chief, Facilities Support Network Contracting Office 9 Date

Details: This Is A Sources Sought Notice Only. this Is Not A Solicitation For Bids, Proposals, Proposal Abstracts, Or Quotations. The Purpose Of This Sources Sought Notice Is To Obtain Information Regarding The Availability And Capability Of Qualified Sources To Perform The Potential Requirement. This Sources Sought Notice Is Part Of Market Research Effort And Invites Contractors Capable Of Fulfilling The Requirement In Accordance With The Statement Of Work And Salient Characteristics.â  The Responses Received From Interested Contractors Will Assist The Government In Determining The Appropriate Acquisition Method. the Department Of Veterans Affairs (va), Network Contracting Office (nco) 23, Is Conducting Market Research To Identify Potential Sources Which Can Provide The Following:â  statement Of Work mold Remediation Services introduction/background air Quality Testing In A Va Building, Revealed Levels Of Airborne Microbial Particles That Exceed An Acceptable Level For A Healthcare Facility. Due To This Hazard, The Building Has Been Vacated Of All Patients And Staff And Will Remain So Until It Is Safe To Occupy. project Objective remediation Services To Remove Or Clean All Surfaces And Materials Located Inside Building. Building To Be Placed Under Negative Pressure, With Additional Units To Be Used As Air Filtrations. Hvac System To Be Isolated, All Diffusers Removed, Cleaned, Then Set Aside, All Flex Ducting To Be Removed (to Later Be Replaced), And All Duct Openings To Be Sealed. All Carpet In The Building To Be Removed. All Ceiling Tiles In The Building To Be Removed. All Drywall (including Above The Drop Ceiling) That Has Microbial Growth Or Moisture Damage To Be Removed. All Pipe And Ductwork Insulation Showing Evidence Of Growth Or Moisture Damage To Be Removed. All Building Semi And Non-porous Surfaces - Such As But Not Limited To Cabinetry, Countertops, Metal, Glass, Rubber Baseboards, Lighting And Plumbing Fixtures - Needs To Be Thoroughly Disinfected Via Appropriate Cleaning Methods. specifications mold Remediation Technical Specifications part 1 General scope this Specification Covers The Remediation Of Mold Including Removal, Cleanup And Disposal Of Mold Contaminated Materials From A Va Building. The Methods And Procedures In This Specification Are Based On The Observations And Previously Collected Background Air Samples. an Estimate Of The Amount Of Material To Be Removed Or Cleaned Is Not Given. The Determination Of The Actual Amounts, For Bidding Purposes, Is The Responsibility Of The Contractor. By Submitting A Bid, The Contractor Acknowledges That He Has Investigated And Satisfied Himself As To: the Conditions Affecting The Work, Including, But Not Limited To, Physical Conditions Of The Site Which May Affect Site Access, Handling And Storage Of Tools And Materials, Access To Water, Electricity Or Other Utilities, Or Otherwise Affect Performance Of Required Activities. the Character And Quantity Of All Surface And Subsurface Materials Or Obstacles To Be Encountered As Far As This Information Is Reasonably Ascertainable From An Inspection Of The Site, Including Exploratory Work Done By The Building Owner Or A Designated Consultant, As Well As Information Presented In Drawings And Specifications Included With This Contract. Any Failure By The Contractor To Acquaint Himself With Available Information Will Not Relieve Him From The Responsibility For Estimating Properly The Difficulty Or Cost Of Successfully Performing The Work. The Building Owner Is Not Responsible For Any Conclusions Or Interpretations Made By The Contractor On The Basis Of The Information Made Available By The Building Owner. description the Work Specified Herein Shall Be The Remediation Of Mold By Competent Persons trained, Knowledgeable And Qualified In The Techniques Of Remediation, Handling And Disposal Of Mold Contaminated Materials And The Subsequent Cleaning Of Contaminated Areas, Who Comply With All Applicable Federal, State And Local Regulations And Are Capable Of, And Willing To Perform, The Work Of This Contract. the Contractor Shall Supply All Labor, Materials, Services, Insurance, Permits, licenses, Patents, And Equipment Necessary To Carry Out The Work In Accordance With All Applicable Federal, State And Local Regulations And These Specifications. the Contractor Is Responsible For Restoring The Work Area And Auxiliary Areas Utilized During The Remediation To Conditions At Least Equal To Original Conditions. (this Excludes Any Material Removed As Part Of Scope.) Any Damages Caused During The Performance Of Remediation Activities Shall Be Repaired By The Contractor (e.g., Paint Peeled Off By Barrier Tape, Nail Holes, Water Damage, Broken Glass) At No Additional Expense To The Owner. applicable Standards And Guidelines all Work Under This Contract Shall Be Done In Strict Accordance With All Applicable Federal, State, And Local Regulations, Standards, And Codes Governing Mold Remediation And Any Other Trade Work Done In Conjunction With The Remediation. the Most Recent Edition Of Any Relevant Regulation, Standard, Document Or Code Shall Be In Effect. Where Conflict Among The Requirements Or With These Specifications Exists, The Most Stringent Requirements Shall Be Utilized. specific Requirements: title 29, Code Of Federal Regulations, 1926. Occupational Safety And Health Administration (osha), U.s. Department Of Labor. quality Assurance bidders Must Be Licensed As Required By The Iowa Bureau Of Labor. bidders Shall Demonstrate Prior Experience On Mold Remediation Projects Of Similar Nature And Scope Through The Submission Of Letters Of Reference From The Owners Including The Name, Address, And Telephone Numbers Of Contact Person (someone Specifically Familiar With The Contractor's Work) For At Least Three (3) Previous Users Of Service If Requested By The Owners. the Owner Reserves The Right To Reject Bids For Any Reason That Serves The Best Interests Of The Owner Or Building Occupants. The Owner Also Reserves The Right To Waive Any Technicality Or Irregularity In A Bid. Failure To Submit Requested information/documentation Can Result In Automatic Disqualification Of Bid Package. submittals And Notices pre-remediation: submit The Location Of The Landfill To Be Used For Disposal Of The Mold Contaminated Material. submit A List Of All Personnel Who Will Be Involved In The Remediation Activity Including, Supervisors, Workers, And Any Other Personnel Or Agent Who May Be Responsible For Any Aspect Of The Remediation Activities. submit Documentation From A Physician That All Employees Or Agents Have Been Medically Monitored To Determine Whether They Are Physically Capable Of Working While Wearing The Respirator Required Without Suffering Adverse Health Effects. submit Documentation Of Respirator Fit Testing For All Employees And Agents Who Must Enter The Work Area. Document Niosh Approval Of All Respiratory Protective Devices Utilized On-site. submit A List Of Equipment For This Project. with The Owner Or Owner's Representative, Inspect The Premises Wherein All Remediation And Remediation Related Activities Will Occur And Submit A Statement Signed By Both, Agreeing On Building And Fixture Condition Prior To The Commencement Of The Work. submit Manufacturer's Certification That Hepa Vacuums, Negative Pressure Ventilation Units, And Other Local Exhaust Ventilation Equipment Conform To Ansi 29.2-79. when Rental Equipment Is To Be Used In Remediation Areas Or To Transport Mold Contaminated Waste, A Written Notification Concerning Intended Use Of The Rental Equipment Must Be Provided To The Rental Agency With A Copy Submitted To The Owner. during Remediation Activities: submit Weekly Job Progress Reports Detailing Remediation Activities And Progress. submit Copies Of All Transport Manifests, Trip Tickets And Disposal Receipts For All Mold Waste Materials Removed From The Work Area During The Remediation Process. post In The Clean Room Area Of The Worker Decontamination Enclosure: a List Containing The Names, Addresses, And Telephone Numbers Of The Contractor, The Owner, The Assessment Professional, The Testing Laboratory And Any Other Personnel Who May Be Required To Assist During Remediation Activities. a Logbook To Record Names Of All Personnel Who Enter The Work Area. a Copy Of Emergency Procedures. telephone Numbers Of All Emergency Personnel And Principals For This Remediation Project. the Project Will Not Be Considered Completed Until All Submittals Are Received By The Owner. This Will Affect Payment For The Project. site Security the Work Area Is To Be Restricted Only To Authorized, Trained, And Protected Personnel. These May Include The Contractor's Employees, Employees Of subcontractors, Owner Employees And Representatives, State And Local Inspectors And Any Other Designated Individuals. entry Into The Work Area By Unauthorized Individuals Shall Be Reported Immediately To The Owner By The Contractor. access To The Work Area Shall Be Through A Single Worker Decontamination System. All Other Means Of Access (doors, Windows, Hallways, Etc.) Shall Be Blocked Or Locked So As To Prevent Entry To Or Exit From The Work Area. The Only Exceptions For This Rule Are The Waste Pass Out Airlock Which Shall Be Sealed Except During The Removal Of Containerized Mold Waste From The Work Area, And Emergency Exits In Case Of Fire Or Accident. Emergency Exits Shall Not Be Locked From The Inside; However, They Shall Be Sealed With Polyethylene Sheeting And Tape Until Needed. the Contractor Shall Have Control Of Site Security During Remediation Operations Whenever Possible, In Order To Protect Work Efforts And Equipment. contractor Will Have Owner's Assistance In Notifying Building Occupants Of Impending Activity And Enforcement Of Restricted Access By Owner's Employees. emergency Planning emergency Planning Shall Be Developed Prior To Remediation Initiation And Agreed To By Contractor And Owner. emergency Planning Shall Include Considerations Of Fire, Explosion, Toxic Atmospheres, Electrical Hazards, Slips, Trips And Falls, Confined Spaces, And Heat Related Injury. Written Procedures Shall Be Developed And Employee Training In Procedures Shall Be Provided. employees Shall Be Trained In Evacuation Procedures In The Event Of Work Place Emergencies. part 2 Materials And Equipment materials general: deliver All Materials In The Original Packages, Containers, Or Bundles Bearing The Name Of The Manufacturer And The Brand Name. store All Materials Subject To Damage Off The Ground, Away From Wet Or Damp surfaces, And Under Cover Sufficient Enough To Prevent Damage Or Contamination. polyethylene Sheeting For Walls And Stationary Objects Shall Be A Minimum Of 4 Mil Thick. For Floors And All Other Sheeting Of At Least 6 Mil Thickness Shall Be Used In Widths Selected To Minimize The Frequency Of Joints. tape - Duct, Glass Fiber, Or Other Type Capable Of Sealing Adjacent Sheets Of Polyethylene And Capable Of Sealing Polyethylene To Dissimilar Finished Or Unfinished Surfaces Under Both Wet And Dry Conditions Including The Use Of Amended Water. polyethylene Sheeting Utilized For Worker Decontamination Enclosure Shall Be Opaque White Or Black In Color. disposal Bags Shall Be Of 6 Mil Polyethylene. disposal Drums Shall Be Metal Or Fiberboard With Locking Ring Tops. equipment general: a Sufficient Quantity Of Negative Pressure Ventilation Units Equipped With Hepa Filtration Shall Be Utilized To Provide One Workplace Air Change Every 15 Minutes Or A Static Pressure Within The Work Area Of At Least -0.02 Inches Of Water Column. These Ventilation Units Must Be Commercially Produced Units And Not Self-manufactured. Ventilation Units To Be Exhausted Outside.the Contractor Shall Furnish A Copy Of Their Calculations To Obtain This Air Flow Or Static Pressure If Requested By The Owner. air Purifying Respirators Equipped With Hepa Filters Will Be Required. A Sufficient Supply Of Filters Shall Be Available In The Clean Change Area. This Requirement May be Modified By The Assessment Professional If Air Sampling Results Indicate The Need For More Protection. air Purifying Respirators With Dual High Efficiency (hepa) Filters May Be Utilized During Work Area Preparation Activities. Spectacle Kits And Eyeglasses Must Be Provided For Employees Who Wear Glasses And Who Must Wear Full Face Piece Respirators. Respirators Shall Be Provided That Have Been Tested And Approved By The National institute Of Occupational Safety And Health For Use In Mold Contaminated Atmospheres. full Body Disposable Protective Clothing, Including Head, Body And Foot Coverings (unless Using Footwear As Described In Section 2.02 (a)(6) Consisting Of Material Impenetrable By Mold (tyvek Or Equivalent) Shall Be Provided To All Workers In Sizes Adequate To Accommodate Movement Without Tearing. additional Safety Equipment (e.g., Hard Hats, Eye Protection, Safety Shoes Meeting The Applicable Ansi Standard, Disposable Pvc Gloves) As Necessary, Shall Be Provided To All Workers And Authorized Visitors. nonskid Footwear Shall Be Provided To All Remediation Workers. Disposable Clothing Shall Be Adequately Sealed To The Footwear To Prevent Body Contamination. a Sufficient Supply Of Disposable Mops, Rags And Sponges For Work Area Decontamination Shall Be Available. mobile Radios, Telephones, Etc. As Required By The Project Will Be Provided By The Contractor. removal/cleaning Equipment: sufficient Supply Of Scaffolds, Ladders, Lifts And Hand Tools Shall Be Provided As Needed. sprayers With Pumps Capable Of Providing A Water Stream Or Mist For Dust Control. rubber Dustpans And Rubber Squeegees Shall Be Provided For Cleanup. brushes Utilized For Removing Loose Mold Containing Material Shall Have Nylon Or Fiber Bristles, Not Metal. a Sufficient Supply Of Hepa Filtered Vacuum Systems Shall Be Available During Cleanup. part 3 Execution preparation post Caution Signs At Any Location And Approaches To A Location Where Airborne Concentrations Of Mold May Exceed Ambient Background Levels. Additional Signs May Need To Be Posted Following Construction Of Workplace Enclosure Barriers. shut Down And Lock Out Electric Power To All Work Areas As Necessary If Wet Conditions Warrant. Provide Temporary Power And Lighting. Ensure Safe Installation (including Ground Faulting) Of Temporary Power Sources And Equipment By Compliance With All Applicable Electrical Code Requirements And Osha Requirements For Temporary Electrical Systems. shut Down And Lock Out All Heating, Cooling And Air Conditioning System (hvac) Components That Are In, Supply Or Pass Through The Work Area. Seal All Intake And Exhaust Vents In The Work Area With Tape And 6 Mil Polyethylene. Also Seal Any Seams In System Components That Pass Through The Work Area. Remove All Hvac System Filters And Place In Labeled 6 Mil Polyethylene Bags For Staging And Eventual Disposal As Mold Contaminated Waste. due To Hvac Being Offline During Winter Conditions, Contractor To Provide Temporary Heat To Maintain Indoor Temperature Of 60 Degrees Fahrenheit Throughout Building. the Contractor Shall Provide Sanitary Facilities For Remediation Personnel Outside Of The Enclosed Work Area And Maintain Them In A Clean And Sanitary Condition Throughout The Project. seal Off All Windows, Doorways, Elevator Openings, Corridor Entrances, Drains, Ducts, Grills, Grates, Diffusers, Skylights, And Any Other Openings Between The Work Area And Uncontaminated Areas Outside Of The Work Area With 4 Mil Polyethylene Sheeting And Tape. barrier Walls Will Be Constructed Of 4 Mil Polyethylene Sheeting Extending From The Ceiling To Floor. workplace Exits worker Decontamination Enclosure System: worker Decontamination Enclosure Systems Shall Be Provided At All Locations Where Workers Will Enter Or Exit The Work Area. worker Decontamination Enclosure Systems Constructed At The Work Site Shall Utilize 6 Mil Opaque White Or Black Polyethylene Sheeting Or Other Acceptable Materials For Privacy. Detailed Descriptions Of Portable, Prefabricated Units, If Used, Must Be submitted For The Owner's Approval. Plans Must Include Floor Plan With Dimensions, Materials, Size, Thickness, Plumbing, And Electrical Utilities. the Worker Decontamination Enclosure System Shall Consist Of At Least A Clean Room And An Airlock. entry And Exit From The Decontamination Enclosure System Chamber Shall Be Through Curtained Doorways Consisting Of Two Sheets Of Overlapping Polyethylene Sheeting. One Sheet Shall Be Secured At The Top And Left Side, The Other Sheet At The Top And Right Side. Both Sheets Shall Have Weights Attached To The Bottom To Ensure That They Hang Straight And Maintain A Seal Over The Doorway When Not In Use. the Clean Room Shall Be Sized To Adequately Accommodate The Work Crew. Benches Shall Be Provided As Well As Hooks For Hanging Up Street Clothes. Shelves For Storing Respirators Shall Also Be Provided In This Area. Clean Work Clothes: Clean Disposable Clothing, Replacement Filters For Respirators, Towels, And Other Necessary Items Shall Be Provided In Adequate Supply In The Clean Room. A Location For Postings Shall Also Be Provided In This Area. Whenever Possible, A Lockable Door Shall Be Used To Permit Access Into The Clean Room From Outside The Work Area. Lighting, Heat, And Electricity Shall Be Provided As Necessary For Comfort. This Space Shall Not Be Used For Storage Of Tools, Equipment Or Materials, Or As An Office Space. waste Container Pass Out Airlock: the Waste Container Pass Out Airlock Shall Be The Same As The Exit Entry Airlock. emergency Exits: emergency Exits Shall Be Established And Clearly Marked With Duct Tape Arrows Or Other Effective Designations To Permit Easy Identification From Anywhere Within The Work Area. They Shall Be Secured To Prevent Access From Uncontaminated Areas And Still Permit Emergency Exiting. These Exits Shall Be Properly Sealed With Polyethylene Sheeting Which Can Be Cut To Permit Egress If Needed. These Exits May Be The Worker Decontamination Enclosure, The Waste Pass Out Airlock And/or Other Alternative Exits Satisfactory To Fire Officials. isolation Of The Workplace maintenance Of Enclosure Systems: following Completion Of The Construction Of All Polyethylene Barriers And Decontamination System Enclosures, Allow Overnight Settling To Ensure That Barriers Will Remain Intact And Secured To Walls And Fixtures Before Beginning Actual Remediation Activities. all Polyethylene Barriers Inside The Workplace, In The Worker Decontamination Enclosure System, In The Waste Container Pass Out Airlock And At Partitions constructed To Isolate The Work Area From Occupied Areas Shall Be Inspected At Least Twice Daily, Once Prior To The Start Of Each Day's Remediation Activities. Document Inspections And Observations In The Daily Project Log. damage And Defects In The Enclosure System Are To Be Repaired Immediately Upon Discovery. negative Pressure To Be Monitored With A Continuous Reading Device. A Record Of This Shall Be Furnished To The Owner. Use Smoke Tubes To Test The Effectiveness Of The Barrier System When Directed By The Owner. at Any Time During The Remediation Activities After Barriers Have Been Erected, If Visible Material Is Observed Outside Of The Work Area Or If Damage Occurs To Barriers, Work Shall Immediately Stop, Repairs Be Made To Barriers, And Debris/residue Cleaned Up Using Appropriate Hepa Vacuuming And Wet Mopping Procedures. install And Initiate Operation Of Negative Pressure Ventilation Equipment As Needed To Provide One Air Change In The Work Area Every 15 Minutes Or Produce A Static Pressure Of -0.02 Inches Of Water Column. (see Section 2.02 (a)) Openings Made In The Enclosure System To Accommodate These Units Shall Be Made Airtight With Tape And/or Caulking As Needed. If More Than One Unit Is Installed, They Should Be Turned On One At A Time, Checking The Integrity Of Wall Barriers For Secure Attachment And The Need For Additional Reinforcement. Ensure That Adequate Power Supply Is Available To Satisfy The Requirements Of The Ventilating Units. Negative Pressure Ventilation Units Shall Be Exhausted To The Outside Of The Building Whenever Feasible. Additional Negative Pressure Ventilation Units May Be Exhausted Inside The Work Area To Provide Continuous Air Cleaning. They Shall Not Be Exhausted Into Occupied Areas Of The building. Twelve-inch Extension Ducting Shall Be Used To Reach From The Work Area To The Outside When Required. Careful Installation, Air Monitoring And Daily Inspections Shall Be Done To Ensure That The Ducting Does Not Release Fibers Into Uncontaminated Building Areas. once Constructed And Reinforced As Necessary, With Negative Pressure Ventilation Units In Operation As Required, Test Enclosure For Leakage Utilizing Smoke Tubes. Repair Or Reconstruct As Needed. workplace Entry And Exit Procedures personnel Entry And Exit: all Workers And Authorized Personnel Shall Enter The Work Area Through The Worker Decontamination Enclosure System. Workers Shall Not Eat, Chew, Or Smoke Once They Have Entered The Work Area. Eating May Take Place Just Outside The Clean Room. Smoking, At Any Time During The Project, Is Prohibited On The Campus. all Personnel, Before Entering The Work Area, Shall Read And Be Familiar With All Posted Regulations, Personal Protection Requirements (including Workplace Entry And Exit Procedures) And Emergency Procedures. A Sign Off Sheet Shall Be Used To Acknowledge That These Procedures Have Been Reviewed And Understood By All Personnel Prior To Entry. all Personnel Shall Proceed First To The Clean Room And Appropriately Don Respiratory Protection And Launderable And/or Disposable Coveralls, Head Covering, And Foot Covering. Hard Hats, Eye Protection, And Gloves Shall Also Be Utilized If Required. Clean Respirators And Protective Clothing Shall Be Provided And Utilized By Each Person For Each Separate Entry Into The Work Area. personnel Wearing Designated Personal Protective Equipment Shall Proceed From The Clean Room Through The Airlock Into The Main Work Area. before Leaving The Work Area All Personnel Shall Remove Gross Contamination From The Outside Of Respirators And The Outer Protective Clothing By Brushing And/or Wet Wiping Procedures. Each Person Shall Clean Bottoms Of Protective Footwear Just Prior To Entering The Airlock. personnel Shall Proceed To The Airlock Where They Remove The Outer Protective equipment Except Respirators. Deposit Disposable And/or Launderable Clothing Back Into The Work Area Into Appropriately Labeled Containers For Disposal And/or laundering. reusable, Contaminated Footwear Shall Be Stored In The Airlock When Not In Use In The Work Area. Upon Completion Of Remediation, It Shall Be Disposed Of As Mold Contaminated Waste. Rubber Boots May Be Decontaminated At The Completion Of The Remediation Project For Reuse. still Wearing Respirators, Personnel Shall Proceed To The Clean Room, Clean The Outside Of The Respirators And The Exposed Face Area Under Running Water Prior To Removal Of Respirator. Various Types Of Respirators Will Require Slight Modification Of These Procedures. don Clean Disposable And/or Launderable Clothing If There Will Be Later Reentry Into The Work Area Or Street Clothes If It Is The End Of The Work Shift. these Procedures Shall Be Posted In The Clean Room And Equipment Room. waste Container Pass Out Procedures: mold Contaminated Waste That Has Been Containerized Shall Be Transported Out Of The Work Area Through The Waste Container Pass Out Airlock Or Through The Worker Decontamination Enclosure If A Separate Airlock Has Not Been Construction. waste Pass Out Procedures Shall Utilize Two Teams Of Workers, An "inside" Team And An "outside" Team. the Inside Team Wearing Appropriate Protective Clothing And Respirators For Inside The Work Area Shall Clean The Outside, Including Bottoms, Containers (bags, Drums, Or Wrapped Components) Using Hepa Vacuums And Wet Wiping Techniques And transport Them Into The Waste Container Pass Out Airlock. the Outside Team, Wearing Appropriately Assigned Respirators, Shall Enter The Airlock From The Outside Of The Work Area, Remove Them From The Airlock To The Outside. No Worker From The Outside Team Shall Further Enter The Work Area Through This Airlock. The Exit From This Airlock Shall Be Secured When Not In Use To Prevent Unauthorized Entry. personnel Protection Requirements training: prior To Commencement Of Remediation Activities, The Contractor Shall Have One Person Designated As A Competent Supervisor. This Person Shall Be On-site At All Times. special On-site Training On Equipment And Procedures Unique To This Job Site Shall Be Performed As Required. training In Emergency Response And Evaluation Procedures Shall Be Provided. respiratory Protection: all Respiratory Protection Shall Be Provided To Workers In Accordance With The Written Respiratory Protection Program, Which Includes All Items In osha 29 Cfr 1910.134 (b)(1-11). This Program Shall Be Posted In The Clean Room Of The Worker Decontamination Enclosure System. workers Shall Be Provided With Personally Issued, Individually Identified Respirators. respirator Types Shall Be Utilized According To The Following Schedule: full Face Air Purifying Respirators With Dual Hepa Filters Shall Be Utilized By Workers During Remediation Operations. full Face Powered Air Purifying Respirators Equipped With Hepa Filters May Be Used During Remediation Activities. fit Testing: workers Must Perform Positive And Negative Air Pressure Fit Tests Each Time A Respirator Is Put On, Wherever The Respirator Design So Permits. Powered Air Purifying Respirators Shall Be Tested For Adequate Flow As Specified By The manufacturer. workers Shall Be Given A Qualitative Fit Test In Accordance With Procedures Detailed In The Osha Lead Standard (29 Cfr 1910.1025, Appendix D, Qualitative Fit Test Protocols) For All Respirators To Be Used On This Remediation Project. An Appropriate administered Quantitative Fit Test May Be Substituted For The Qualitative Fit Test. documentation Of Adequate Respirator Fit Must Be Provided To The Owner. no One Wearing A Beard Shall Be Permitted To Don A Respirator And Enter The Work Area. protective Clothing: disposable Clothing Including Head, Foot, And Full Body Protection Shall Be Provided In Sufficient Quantities And Adequate Sizes For All Workers And Authorized Visitors. launderable Clothing, If Required, Shall Be Provided In Sufficient Quantities And Adequate Sizes For All Workers And Authorized Visitors. hard Hats, Protective Eyewear, Gloves, Rubber Boots, And/or Other Footwear Shall Be Provided As Required For Workers And Authorized Visitors. Safety Shoes May Be Required For Some Activities. commencement Of Work enclosure Systems Have Been Constructed And Tested. negative Pressure Ventilation Systems Are Functioning Adequately. all Pre-remediation Submissions, Notifications, Postings, And Permits Have Been Provided And Are Satisfactory To The Owner. all Equipment For Remediation, Cleanup, And Disposal Are On Hand. all Worker Training Is Completed. contractor Receives Written Permission From The Owner To Commence Remediation. removal/cleaning Procedures protection Of Materials Not Being Removed: materials That Are Not Being Removed Are To Be Protected From Any Damage That May Occur During Work. The Acoustic Ceiling Tile Suspension Grid Is To Be Cleaned Yet Remain In Place And Is Not To Be Damaged During The Removal Of The Tiles. level One: clean And Isolate Active Work Areas In Accordance With Section 3.01. wet All Mold Containing Materials With An Approved Biocide Solution Using Equipment Capable Of Providing A Fine Spray Mist, To Reduce Airborne Concentrations When The Material Is Disturbed. Keep All Removed Material Wet Enough To Prevent Release Until It Can Be Containerized For Disposal. removal And Cleaning: all Acoustic Ceiling Tiles, All Carpet Throughout The Entire Building Are To Be Removed And Properly Disposed Of. non-porous Materials - All Non-porous Surfaces Are To Be Cleaned Using A detergent Solution Or Solution Of Contractor's Choice That Will Re Move Mold. Hepa Vacuums May Be Used Along With The Solution For Cleaning. all Materials Need To Be Dried. Examples Of Non-porous Materials Include: metal glass hard Plastics plumbing Fixtures all Hvac Diffusers Are To Be Removed, Thoroughly Cleaned (as Detailed Above) And Set Aside Per Owner S Direction To Be Re-installed Later. semi-porous (e.g. Wood Doors, Unsealed Concrete) All Semi-porous Surfaces Are To Be Cleaned Using A Detergent Solution Or Solution Of Contractor's Choice That Will Remove Mold. This Solution Must Be Approved By Owner. Hepa Vacuums May Be Used Along With The Solution For Cleaning. All Materials Need To Be Dried. Examples Of Semi-porous Materials Include: wood concrete porous Materials - Remove All Porous Materials Where Visible Mold Growth Or Evidence Of Moisture Is Present. The Materials Should Be Removed, Bagged And Discarded. Examples Of Porous Materials Include: drywall insulation Of All Types carpet (all Being Removed, Regardless Of Evidence) acoustic Ceiling Tiles (all Being Removed, Regardless Of Evidence) containers (6 Mil Polyethylene Bags) Shall Be Sealed When Full. Bags Shall Not Be Overfilled. They Should Be Securely Sealed To Prevent Accidental Opening And Leakage By Tying Tops Of Bags In An Overhead Knot Or By Taping In gooseneck Fashion. Do Not Seal Bags With Wire Or Cord. Bags Shall Be Decontaminated On Exterior Surfaces By Wet Cleaning And Hepa Vacuuming. large Components Removed Intact May Be Wrapped In 2 Layers Of 6 Mil Polyethylene Sheeting Secured With Tape For Transport To The Landfill. mold Containing Waste With Sharp Edged Components (e.g., Nails, Screws, Metal Lath, Tin Sheeting) Will Tear The Polyethylene Bags And Sheet And Shall Be Reinforces With Extra Bags Or Wrapping. cleanup Procedure remove And Containerize All Visible Accumulations Of Mold Containing Material And Mold Contaminated Debris Utilizing Rubber Dust Pans, Rubber Squeegees, Hepa vacuums, Etc. remove All Containerized Waste From The Work Area And Waste Container Pass Out Airlock. decontaminate All Tools And Equipment And Remove At The Appropriate Time In The Cleaning Sequence. inspect The Work Area For Visible Residue. If Any Accumulation Of Residue Is Observed, It Will Be Assumed To Be Mold And The Work Area Must Be Re-cleaned. the Work Area Shall Be Cleaned Until It In Compliance With Criteria Agreed Upon By The Contractor And Owner Prior To Initiation Of Remediation Activities. following The Satisfactory Completion Of Clearance Criteria Remaining Barriers May Be Removed And Properly Disposed Of. A Final Visual Inspection By The Owner Shall Ensure That No Contamination Remains In The Work Area. Unsatisfactory Conditions May Require Additional Cleaning And Air Monitoring (see Section 3.11, Reestablishment Of The Work Area). clearance Testing following The Completion Of Cleanup Operations, The Remediation Contractor Shall Notify The Owner (or Industrial Hygiene Consultant Selected By Owner) When The Building Area Is Ready For Clearance Testing. Remediation Contractor Will Not Be Responsible For Performing Clearance Testing. The Owner (via Contracted Industrial Hygienist) Shall Arrange For Collecting Samples. 3.10 Disposal Procedures general: as The Work Progresses, To Prevent Exceeding Available Storage Capacity Onsite, Sealed And Labeled Containers Of Mold Containing Waste Shall Be Removed And Stored In The Dumpster On-site Until It Is Transported To The Prearranged Disposal Location. all Waste Shipment Records Shall Be Delivered To The Owner. A Recommended Record Keeping Format Utilizes The Waste Shipment Record (wsr) Which Includes The Names And Addresses Of The Generator (owner), Contractor, Transporter, And Disposal Site, The Estimated Quantity Of The Mold Waste And The Type Of Containers Used. transportation To The Landfill: once Drums, Bags And Wrapped Components Have Been Removed From The Work Area, They Shall Be Loaded Into An Enclosed Truck Or Dumpster For Transportation. any Debris Or Residue Observed On Containers Or Surfaces Outside Of The Work Area Resulting From Cleanup Or Disposal Activities Shall Be Immediately Cleaned Up Using Hepa Filtered Vacuum Equipment And/or Wet Methods As Appropriate. large Metal Dumpsters Are Sometimes Used For Mold Waste Disposal. These Should Have Doors Or Tops That Can Be Closed And Locked To Prevent Vandalism Or Other Disturbance Of The Bagged Mold Debris And Wind Dispersion Of Mold Fibers. Bags Shall Be Placed, Not Thrown, Into These Containers To Avoid Splitting. disposal At The Landfill: upon Reaching The Landfill, Trucks Are To Approach The Dump Location As Closely As Possible For Unloading Of The Mold Containing Waste. bags, Drums, And Components Shall Be Inspected As They Are Off Loaded At The Disposal Site. Waste Containers Shall Be Placed On The Ground At The Disposal Site, Not Pushed Or Thrown Out Of The Trucks. following The Removal Of All Containerized Waste, The Truck Cargo Area Shall Be Decontaminated Using Hepa Vacuums And/or Wet Methods To Meet The No Visible Residue Criteria. 3.11 Re-establishment Of The Work Area And Systems re-establishment Of The Work Area Shall Only Occur Following The Completion Of Cleanup Procedures And After Clearance Criteria Have Been Met And Documented To The Satisfaction Of The Owner. the Contractor And Owner Shall Visually Inspect The Work Area For Any Remaining Visible Residue. Evidence Of Contamination Will Necessitate Additional Cleaning Requirements In Accordance With Section 3.07. following Satisfactory Clearance Of The Work Area, Remaining Polyethylene Barriers May Be Removed And Disposed Of As Mold Contaminated Waste. at The Discretion Of The Contractor, Mandatory Requirements For Personal Protective Equipment May Be Waived Following The Removal Of All Barriers. re-secure Mounted Objects Removed From Their Former Positions During Area Preparation Activities. relocate Objects That Were Removed To Temporary Locations Back To Their Original Positions. reestablish Hvac, Mechanical And Electrical Systems In Proper Working Order. Remove Contaminated Hvac System Filters And Dispose Of As Mold Contaminated Waste. Decontaminate Filter Assembly Using Hepa Vacuums And Wet Cleaning Techniques. Install New Filters In Hvac Systems. Dispose Of Old Filters. repair All Areas Of Damage That Occurred Because Of Remediation Activities. period Of Performance upon Notice To Proceed, Contractor Shall Have 30 Calendar Days To Complete The Scope Detailed In This Document.

Details: Synopsis: introduction: in Accordance With Federal Acquisition Regulation (far) 10.002(b)(2), This Sources Sought Notice Is For Market Research And Information Purposes Only At This Time And Shall Not Be Construed As A Solicitation Or As An Obligation On The Part Of The Department Of Veterans Affairs (va). the Department Of Veterans Affairs, Veterans Health Administration (vha), Program Contracting Activity Central (pcac) Is Conducting A Market Survey And Is Seeking Potential Sources For Project 562-22-700, Construct Ehrm Infrastructure Upgrades At The Erie Va Medical Center (vamc) Located In Erie, Pennsylvania. project Description: the Erie Vamc Is Seeking A General Contractor To Provide All Necessary Tools, Labor, Materials, Equipment, Permits, License, Supervision, And Quality Control For Ehrm Infrastructure Upgrades Erie, Pa At The Erie Va Medical Center, In Accordance With The Drawings And Specifications. Work Includes General Construction, Alterations, Grading, And The Following Infrastructure Improvements: Electrical Power (normal And Emergency); Bonding; Ups; Building Management System (bms) Interfaces; New And Upgrades Of Existing Hvac; Reconfiguration, Expansion, And Renovation Of Existing Spaces; Communication Infrastructure; Physical Security Upgrades; Upgrade Of Fiber Infrastructure Backbone Campus-wide, Within Buildings And Between Buildings; Construct New Data Center; Hazardous Material Abatement And All Necessary Removal Of Existing Structures And Construction Of Certain Other Items. the Upgrade To The Infrastructure Will Include Campus Wide New Campus Wide Fiber Backbone Underground Routing And Will Require Excavation, Trenching, Reinforced Concrete Duct Bank With Associated Access Points. Campus Buildings Impacted By The Upgrades Include Buildings 1, 6, 7, 8, 11, 14, And 18. Upgrades In These Buildings Will Include Existing Rooms And Telecommunications Closets And Include Relocation, Reconfiguration, Expansion, And Renovation Involving New Walls, Doors And Finishes, Etc. Throughout Each Space. construction Shall Comply With Va Infrastructure Standard For Telecommunications Spaces (ists) V4.0, June 1, 2023. New Data Center To Include Electrical Distribution, Cable Management, Data Cabinets, Finishes And Hvac. The Data Center Is Designed For And Meeting The Requirements Of A Small/medium Campus Support Center. The Data Center Shall Be Constructed To Withstand Blast Protection Requirements Per The Va Psrdm. procurement Information: the Proposed Project Will Be A Competitive, Firm-fixed-price Contract Utilizing The Design-bid-build Approach (final Specifications And Drawings Will Be Provided). The Anticipated Solicitation Will Be Issued Either As A Request For Proposal (rfp) In Accordance With Far Part 15, Considering Technical And Price Factors Or As An Invitation For Bid (ifb) In Accordance With Far Part 14, Considering Price Only. The Results And Analysis Of The Market Research Will Finalize The Determination Of The Procurement Method. The Type Of Socio-economic Set-aside, If Any, Will Depend Upon The Responses To This Notice And Any Other Information Gathered During The Market Research Process. this Project Is Planned For Advertising In March, 2025. In Accordance With Vaar 836.204, The Magnitude Of Construction Is Between $20,000,000.00 And $50,000,000.00. The North American Industry Classification System (naics) Code 236220 (size Standard $45.0 Million) Applies To This Procurement. The Duration Of The Project Is Currently Estimated At 540 Calendar Days From The Issuance Of A Notice To Proceed. The Services For This Project Will Include Providing All Construction Related Services Such As: Providing Tools, Labor, Materials, Equipment, Permits, Licenses, Supervision, And Quality Control Required To Complete The Project As Per Contract Documents Prepared By An Independent Architect-engineer Firm. capability Statement: respondents Shall Provide A General Capabilities Statement To Include The Following Information: section 1: Provide Company Name, Duns Number And Unique Entity Identifier (uei), Company Address, Point-of-contact Name, Phone Number And Email. section 2: Provide Company Business Size Based On Naics Code 236220. Also, Provide Business Type (i.e., Large Business, Small Business, Service-disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-owned Small Business, Hub Zone Small Business, Etc.). section 3: Provide A Statement Of Interest In The Project. Please State Your Intent To Submit A Bid On This Project If The Only Evaluation Factor Is Price (far Part 14). Please Also State Your Intent To Submit A Proposal If The Solicitation Contains Both Price And Non-price Evaluation Factor (far 15). section 4: Provide The Prime Contractor S Available Bonding Capacity In The Form Of A Letter Of Intent From Your Bonding Company With This Submission. *please Ensure That The Individual Bonding Capacity Is In Line With The Vaar Magnitude Of Construction Listed Above. Letter Should Include Single Award Limit, Aggregate Limit And Available Bonding Capacity. section 5: Provide The Type Of Work Your Company Has Performed In The Past In Support Of The Same Or Similar Requirement. This Section Is Important As It Will Help To Determine The Type Of Socio-economic Set-aside, If Any. Please Provide The Following In Your Response: no More Than Three (3) Contracts That Your Company Has Performed Within The Last Six (6) Years That Are Of Comparable Size, Complexity, And Scope To This Requirement. Include The Project Name, Project Owner And Contact Information As This Person May Be Contacted For Further Information, Project Scope, Project Size (example: Square Footage), Building Use (example: Medical Facility, Office Building, Etc.), Project Dollar Value, Start And Completion Dates. provide Specific Examples That Relate Aspects Of Previous Projects To The Proposed Project. Describe Specific Technical Skills And Key Personnel Your Company Possess To Perform The Requirements Described Under Description Of Work. describe Your Self-performed** Effort (as Either A Prime Or Subcontractor). Describe Self-performed Work In Terms Of Dollar Value And Description. **self-performed Means Work Performed By The Offeror Themselves, Not Work Performed By Another Company For Them For Any Of The Project Examples Provided. it Is Requested That Interested Contractors Submit A Response (electronic Submission) Of No More Than Eight (8) Single Sided Pages, Single-spaced, 12-point Font Minimum That Addresses The Above Information. This Response Must Be Submitted As A Single Application-generated (not Scanned) Pdf Document That Is Less Than Or Equal To 4mb In Size. Please Note That Hard Copies Will Not Be Accepted. Please Also Include A Cover Page, Which Includes, At A Minimum: The Company S Name, Address, Unique Entity Identifier (if Available), Socio-economic Status, Point-of-contact Name, Phone Number, And E-mail Address. Responses Must Include The Sources Sought Number And Project Title In The Subject Line Of Their E-mail Response. Submissions (responses) Shall Be Submitted Via Email To The Primary And Secondary Points Of Contact Listed Below By January 15, 2025 At 1:00 Pm Et. No Phone Calls Will Be Accepted. the Capabilities Statement Submitted In Response To This Sources Sought Shall Not Be Considered To Be A Bid Or Proposal. This Notice Is For Information And Planning Purposes Only And Is Neither To Be Construed As A Commitment By The Government Nor Will The Government Pay For Information Solicited. No Evaluation Letters And/or Results Will Be Issued To The Respondents. After Completing Its Analyses, The Government Will Determine Whether To Limit Competition Among The Small Business Categories Listed Above Or Proceed With Full And Open Competition As Other Than Small Business. at This Time No Solicitation Exists; Therefore, Please Do Not Request A Copy Of The Solicitation. If A Solicitation Is Released It Will Be Synopsized In Contract Opportunities At Https://sam.gov/. It Is The Potential Offeror's Responsibility To Monitor This Site For The Release Of Any Solicitation Or Synopsis. contracting Office Address: vha Program Contracting Activity Central (vha-pcac) 6100 Oak Tree Blvd. Suite 490 independence, Oh 44131 primary Point Of Contact: leslie Prather contract Specialist leslie.prather@va.gov secondary Point Of Contact: samantha Mihaila contracting Officer samantha.mihaila@va.gov

Details: Title: Proiectare Si Executie Lucrari Pentru Obiectivul „extinderea Aripilor A1 Si A4 Ale Spitalulului Universitar De Urgenta Bucuresti Cu Regim De Inaltime Sth+p+3e/sth+p+6e, Amenajare Parcari Exterioare” description: Obiectul Contractului Il Reprezinta Proiectarea Si Executia Lucrarilor Pentru Obiectivul „extinderea Aripilor A1 Si A4 Ale Spitalulului Universitar De Urgenta Bucuresti Cu Regim De Inaltime Sth+p+3e/sth+p+6e, Amenajare Parcari Exterioare”. Prin Intermediul Contractului Incheiat Vor Fi Asigurate Urmatoarele: - Servicii De Proiectare – Elaborare Proiect Tehnic De Executie (pte) – Conform Prevederilor Hg 907/2016, Cu Modificarile Si Completarile Ulterioare, Elaborarea Documentatiilor Si Obtinerea Avizelor/acordurilor Solicitate Prin Certificatul De Urbanism Nr. 560/21338 Din Data De 01.07.2022 (valabil Pana La Data De 30.06.2025) Emis De Primaria Municipiului Bucuresti, Precum Si A Documentatiilor Dtac Si Dtoe Si Obtinerea Autorizatiei De Construire; - Asistenta Tehnica Acordata De Proiectant Pe Perioada Executiei A Lucrarilor Si In Perioada De Garantie A Lucrarilor; - Execuție Lucrări În Vederea Construirii Extinderii Aripilor A1 Si A4 Ale Spitalului Universitar Bucuresti (având În Vedere Faptul Că Extinderea Aripilor A1 Si A4 Constituie O Construcție Nouă, Obiectul Contractului Include Executia Tuturor Tipurilor De Lucrari La Obiectivul De Investitii, Respectiv: Lucrari De Structura/rezistenta, Lucrari De Arhitectura, Lucrari De Instalatii Sanitare, Electrice, Termice, Hvac, Gaze Medicale, Gaze Naturale, Etc.). - Executie Parcari Exterioare În Acest Sens A Fost Elaborat Un Studiu De Fezabilitate Prin Intermediul Căruia Este Identificată Soluția Tehnico-economică De Principiu Ce Va Sta La Baza Realizării Obiectivului De Investiții. Obiectul Contractului Supus Prezentei Proceduri Constă În Achiziționarea Serviciilor De Proiectare, A Documentațiilor Pentru Obținerea De Acorduri Și Avize Care Nu Sunt Obtinute, A Proiectelor Tehnice, A Detaliilor De Execuție Și A Oricăror Documente/studii Necesare Elaborării Acestora, Inclusiv Verificarea Tehnică De Specialitate A Proiectului Și Asistența Tehnică Din Partea Proiectantului Și Execuția De Lucrări (cum Ar Fi Amenajarea Terenului, Relocarea/protecția/asigurarea Utilităților, Structură, Arhitectură, Instalații Electrice, Instalații De Curenți Slabi, Instalații De Gaze Naturale, Sisteme De Disribuire A Gazelor Medicale Și Instalații Medicale, Instalții Termice Și De Ventilare, Instalații Sanitare, Montaj Lifturi Și Platforme Ridicătoare Pentru Persoane Cu Dizabilități, Sisteme De Limitare Și Stingere A Incendiilor, Rețele Exterioare, Inclusiv Furnizarea, Montarea Și Punerea În Funcțiune A Utilajelor Și Echipamentelor Tehnologice). Plecând De La Propunerile Tehnice Și Arhitecturale Formulate În Cuprinsul Studiului De Fezabilitate Este Necesară Elaborarea Unei Documentații Tehnice Complete Și Coerente Care Să Expliciteze Și Să Detalieze Cele Mai Potrivite Soluții Tehnice Si Constructive Privind Realizarea Unei Noi Construcții. În Etapa Următoare Finalizării Proiectului Tehnic Și A Obținerii Tuturor Avizelor Necesare Și A Autorizației De Construire Aferente Se Va Proceda La Realizarea Pe Baza Acestui Proiect Tehnic A Lucrărilor De Execuție. Orice Operator Economic Interesat Are Dreptul De A Solicita Clarificări Sau Informații Suplimentare În Legătură Cu Documentația De Atribuire. În Măsura În Care Solicitările De Clarificare Sunt Primite Cu Cel Puțin 25 Zile Înainte De Termenul Limită Stabilit Pentru Depunerea Ofertelor, Autoritatea Contractantă Va Răspunde În Mod Clar Și Complet Tuturor Acestor Solicitări De Clarificare Cu Cel Putin 15 Zile Inainte De Termenul Stabilit Pentru Depunerea Ofertelor.

Details: Title: Proiectare Si Executie: Modernizarea Serviciilor Spitalicești În Cadrul Spitalului Orășenesc Baraolt Din Județul Covasna Prin Construirea Unei Noi Aripi description: Într-un Contract Mixt, Urmând Scopul Şi Obiectul Proiectului, Se Va Realiza Atât Proiectarea Tehnică, Detalii De Execuție, Asistența Tehnică Din Partea Proiectantului, Activitate Ssm Faza De Proiectare Și Pe Șantier, Cât Şi Executia De Lucrări De Constructii Privind Realizarea Investiției Modernizarea Serviciilor Spitalicești În Cadrul Spitalului Orășenesc Baraolt Din Județul Covasna Prin Construirea Unei Noi Aripi. Obiect 1. Construcție Noua Spital Obiect 2 - Amenajari Exterioare Contract Cu Clauza Suspensivă: Contractul Intră În Vigoare Strict După Și Cu Condiția Semnării Contractului De Finanțare Între Uat Or. Baraolt Și Finanțatorul. Atenție: Dotare Nu Face Obiectul Contractului De Lucrări, Dar -elaborarea Formularelor F4, F5 Conform Hg 907/2016 Intră În Sarcina Proiectantului -echipamente, Utilaje Cu Și Fără Montaj, Necesare Pentru Funcționarea Unității Sunt Cuprinse În Obiectul Contractului De Lucrări, Cum Ar Fi, De Ex. Pompă De Căldură, Sistem Hvac, Etc. Atenție: În Cazul În Care, Ulterior Publicării Anunțului De Participare, Sunt Anumite Avize, Acorduri Condiționate, Cum Ar Fi De Ex. Avizul De La Igsu Pentru Scenariu De Incendiu, Etc., Detalierea, Conformarea Și Proiectarea În Faza Pth-dtac Intra În Sarcina Proiectantului, Fără Cost Suplimentar, Dar Eventuale Costuri Suplimentare Justificate Poate Fi Adăugate La Capitolul De Lucrări, Respectând Art. 221 Din L98/2016. Se Va Executa Și Proiecta Racordurile Și Branșamente Electrice Necesare. Plata Se Va Face Direct Către Operatorul Sistemului De Distribuție Energiei Electrice. Atenție! Contract Cu Preț Forfetar! Conform Codului Civil: ” Art. 1.867 Preţul Forfetar (1) Atunci Când Contractul Este Încheiat Pentru Un Preţ Global, Beneficiarul Trebuie Să Plătească Preţul Convenit Şi Nu Poate Cere O Diminuare A Acestuia, Motivând Că Lucrarea Sau Serviciul A Necesitat Mai Puţină Muncă Ori A Costat Mai Puţin Decât S-a Prevăzut. (2) Tot Astfel, Antreprenorul Nu Poate Pretinde O Creştere A Preţului Pentru Motive Opuse Celor Menţionate La Alin. (1). (3) Preţul Forfetar Rămâne Neschimbat, Cu Toate Că S-au Adus Modificări Cu Privire La Condiţiile De Executare Iniţial Prevăzute, Dacă Părţile Nu Au Convenit Altfel.” Se Va Elabora Pth Și Se Va Utiliza Sume Din Cap. 7.1 Strict Numai Respectând Art. 221 Din Legea 98/2016, Coroborat Cu Art. 1867 Din Codul Civil, Adică Numai În Cazul În Care - Sunt Noi Prevederi Necunoscute În Faza De Ofertare Cum Ar Fi Norme Tehnice Noi, Prevederi Din Raport Nzeb, Prevederi Prevăzute Prin Adrese Transmise De Organe Abilitate Pentru Emiterea Avizelor - Sunt Acoperite Prin Renunțări La Cantități Care Nu Sunt Necesare Pentru Atingerea Obiectivelor - Sunt Prevăzute Ulterior De Către Finanțator În Faza De Evaluare A Proiectului Depus În Cadrul Programului De Sănătate, Coordonat De Mipe Dg Programe De Sănătate, - Sunt Mai Eficiente D.p.d.v. Financiar Pe Termen De 15 Ani, Utilizând Rata De Discontare De 7,6% Pe An, Având În Vedere Costuri De Operare Mai Scăzute Din Cauza Tehnologiei Propuse – Necesită O Comparare Utilizând Metoda De Analiza Cost-beneficiu. Termen De Valabilitate A Contractului: 108 Luni. Durata Maximă De: - Proiectare: 12 Luni, - Execuție A Lucrărilor De Construire Este De 36 Luni. Termene: - Durata De Execuției: 48 Luni, Inclusiv Proiectare, Emiterea Ac Si Lucrări, Perioade De Timp Friguros, - Durata De Garanție: 60 Luni.

Details: Title: Proiectare Si Executie: Modernizarea Serviciilor Spitalicești În Cadrul Spitalului Orășenesc Baraolt Din Județul Covasna Prin Construirea Unei Noi Aripi description: Într-un Contract Mixt, Urmând Scopul Şi Obiectul Proiectului, Se Va Realiza Atât Proiectarea Tehnică, Detalii De Execuție, Asistența Tehnică Din Partea Proiectantului, Activitate Ssm Faza De Proiectare Și Pe Șantier, Cât Şi Executia De Lucrări De Constructii Privind Realizarea Investiției Modernizarea Serviciilor Spitalicești În Cadrul Spitalului Orășenesc Baraolt Din Județul Covasna Prin Construirea Unei Noi Aripi. Obiect 1. Construcție Noua Spital Obiect 2 - Amenajari Exterioare Contract Cu Clauza Suspensivă: Contractul Intră În Vigoare Strict După Și Cu Condiția Semnării Contractului De Finanțare Între Uat Or. Baraolt Și Finanțatorul. Atenție: Dotare Nu Face Obiectul Contractului De Lucrări, Dar -elaborarea Formularelor F4, F5 Conform Hg 907/2016 Intră În Sarcina Proiectantului -echipamente, Utilaje Cu Și Fără Montaj, Necesare Pentru Funcționarea Unității Sunt Cuprinse În Obiectul Contractului De Lucrări, Cum Ar Fi, De Ex. Pompă De Căldură, Sistem Hvac, Etc. Atenție: În Cazul În Care, Ulterior Publicării Anunțului De Participare, Sunt Anumite Avize, Acorduri Condiționate, Cum Ar Fi De Ex. Avizul De La Igsu Pentru Scenariu De Incendiu, Etc., Detalierea, Conformarea Și Proiectarea În Faza Pth-dtac Intra În Sarcina Proiectantului, Fără Cost Suplimentar, Dar Eventuale Costuri Suplimentare Justificate Poate Fi Adăugate La Capitolul De Lucrări, Respectând Art. 221 Din L98/2016. Se Va Executa Și Proiecta Racordurile Și Branșamente Electrice Necesare. Plata Se Va Face Direct Către Operatorul Sistemului De Distribuție Energiei Electrice. Atenție! Contract Cu Preț Forfetar! Conform Codului Civil: ” Art. 1.867 Preţul Forfetar (1) Atunci Când Contractul Este Încheiat Pentru Un Preţ Global, Beneficiarul Trebuie Să Plătească Preţul Convenit Şi Nu Poate Cere O Diminuare A Acestuia, Motivând Că Lucrarea Sau Serviciul A Necesitat Mai Puţină Muncă Ori A Costat Mai Puţin Decât S-a Prevăzut. (2) Tot Astfel, Antreprenorul Nu Poate Pretinde O Creştere A Preţului Pentru Motive Opuse Celor Menţionate La Alin. (1). (3) Preţul Forfetar Rămâne Neschimbat, Cu Toate Că S-au Adus Modificări Cu Privire La Condiţiile De Executare Iniţial Prevăzute, Dacă Părţile Nu Au Convenit Altfel.” Se Va Elabora Pth Și Se Va Utiliza Sume Din Cap. 7.1 Strict Numai Respectând Art. 221 Din Legea 98/2016, Coroborat Cu Art. 1867 Din Codul Civil, Adică Numai În Cazul În Care - Sunt Noi Prevederi Necunoscute În Faza De Ofertare Cum Ar Fi Norme Tehnice Noi, Prevederi Din Raport Nzeb, Prevederi Prevăzute Prin Adrese Transmise De Organe Abilitate Pentru Emiterea Avizelor - Sunt Acoperite Prin Renunțări La Cantități Care Nu Sunt Necesare Pentru Atingerea Obiectivelor - Sunt Prevăzute Ulterior De Către Finanțator În Faza De Evaluare A Proiectului Depus În Cadrul Programului De Sănătate, Coordonat De Mipe Dg Programe De Sănătate, - Sunt Mai Eficiente D.p.d.v. Financiar Pe Termen De 15 Ani, Utilizând Rata De Discontare De 7,6% Pe An, Având În Vedere Costuri De Operare Mai Scăzute Din Cauza Tehnologiei Propuse – Necesită O Comparare Utilizând Metoda De Analiza Cost-beneficiu. Termen De Valabilitate A Contractului: 108 Luni. Durata Maximă De: - Proiectare: 12 Luni, - Execuție A Lucrărilor De Construire Este De 36 Luni. Termene: - Durata De Execuției: 48 Luni, Inclusiv Proiectare, Emiterea Ac Si Lucrări, Perioade De Timp Friguros, - Durata De Garanție: 60 Luni.

Details: Document Type: Sources Sought Notice – Renovate B.1816 Warehouse For Kc-46a Base Supply, Mcguire Afb, Joint-base-mdl, New Jersey solicitation Number: W912ds25s0008 naics Title:236220 For Commercial & Institutional Building Construction (size Standard $45 Million) sic Code:1542 General Contractors-nonresidential Buildings, Other Than Industrial Buildings & Warehouses contracting Office Address: u.s. Army Engineer District, New York, Cenan-ct, 26 Federal Plaza, New York, N.y. 10278-0090 project Description: the U.s. Army Corps Of Engineers, New York District Is Issuing This Market Research Or Sources Sought Notice Is To Determine If There Is An Adequate Number Of Interested And Qualified Small Businesses Having The Capability And Bonding Capacity For The Following Effort. The Procurement Method For This Solicitation Will Be Competitive Sealed Bidding Also Known As An Invitation For Bids. this Market Research Is For The Construction/renovation Mcguire Afb Within Joint Base-mcguire-dix-lakehurst, New Jersey. The Project Magnitude Is Estimated Between $10- $25 Million. the Construction Includes Renovations, Alterations, Reconfigurations, And Some Addition To The Existing Facility. There Will Be Interior Concrete Floor Stab Thickening Required. Alteration Work Will Include Hvac Systems, Fire Suppression, Carpet/tile, Wall Finishes, Ceiling Material, Interior Electrical Systems, Office Entry Doors, Latrine Fixtures, Main Entrance Canopies & The Reconfiguration Of Interior Walls. A Loading Dock Area Will Be Added/installed Through The Modernization Of One Side Of The Facility To Meet Truck Delivery Needs Of The Facility. Two Water Tanks That Feed The Facility Will Be Identified To Be Demolished And Replaced. The Project Includes Utilities, Site Improvements, Pavements, Communications Infrastructure, And All Other Support Work Necessary To Make A Complete And Useable Facility. responses: responses To This Sources Sought Will Be Used By The Government For Market Research Analysis Only, As An Aid In Its Making Of The Appropriate Acquisition Decision(s); Such As; Use Of A Small Business Set Aside; Or A Small Business Set-aside Within A Specific Socio-economic Category Or Full And Open Competition. this Project Is Planned For Advertisement Starting In Late February 2025 With An Award Approximately By April 2025. The Contract Duration Will Be 540 Calendar Days. The North American Industry Classification System (naics) Code Is For General Construction; 236220 For Commercial & Institutional Facilities. all Interested Businesses Should Notify Brian.h.winters@usace.army.mil By E-mail And Provide A Response To The Questions Below – (1) Prior Construction Performance – Submit / Provide A Brief Description Of Two (2) Past Performed Projects, Completed In The Last Seven (7) Years (defined As Turned Over To The Customer By This Response Due Date), For A Same Or Similar Scope. A. Similar Scope Includes Commercial Or Institutional Construction Projects Requiring The Use & Management Of Multiple Trade-work. Indicate In The Description If The Project Was Completed On Time Or If Delays Were Incurred State Why; (2) Provide A Statement Verifying The Prime Contractor Is Capable And Will Perform Twenty Fifteen (20%) Of The Physical Work And Indicate The Type Of Work (trade) To Be Self-performed By The Prime Contractor. This Doesn’t Include Contract Supervision And Administration Duties; (3) Provide Identification And Verification Of The Company As Small Business For Naics Code 236220. Please Also Include If You Fall Within Any Socio-economic Categories; (4) Provide Cage Code And System For Award Management (sam) Unique Entity Identifier (uei); And (5) The Interested Contractor Must Indicate Their Capability Of Obtaining Performance And Payment Bonds For A Project In The Dollar Amount (price Or Range) Listed Previously, Above In The Description. all Interested Businesses Should Submit Their Responses In Writing By E-mail. The Due Date For Responses Is Approx. 14 Days From This Announcement. email Responses To: Brian.h.winters@usace.army.mil this Is Not A Commitment On The Part Of The Government To Award A Contract As A Result Of This Notice Or To Pay For Any Information Received. This Synopsis Neither Constitutes A Request For Proposal Or Invitation For Bid, Nor Does It Restrict The Government To An Ultimate Acquisition Approach. This Sources Sought Synopsis Should Not Be Construed As A Commitment By The Government For Any Purpose. The Government Does Not Intend To Rank Submittals Or Provide Any Reply To Interested Firms. Submittals Will Be Used For Market Survey Information Only. point Of Contact: e-mail Questions To Us Army Engineer District, New York At Brian.h.winters@usace.army.mil place Of Performance mcguire Afb At Jb-mdl, New Jersey

Details: This Is A Sources Sought Notice Only. This Is Not A Request For Proposals Or Invitation For Bid. There Is Not A Solicitation, Specifications, Or Drawings Available At This Time.the National Park Service (nps), Contracting Operations (conops) West Is Seeking Qualified Small Business Firms Capable Of Performing Construction Services At Golden Gate National Recreation Area, Stinson Beach, California. The Contract Resulting From The Solicitation Will Require That Contractors Manage Multiple Construction Fields And Components. Description: Replace Stinson Beach Lifeguard Tower And Visitor Snack Bar.this Project Will Encompass Multiple Construction Components And Will Require A Contractor To Be Knowledgeable Of Both State And Federal Regulations As Well As Natural Resource Protection, Specifically Dunes, While Working In Marine/coastal Conditions. The Projected Scope Of Work Will Include Complete Facility Demolition, Materials Testing, Potential Hazardous Material Abatement, And The Proper Disposal Of All Materials. Construction Will Include Wood And Deep Concrete Pile Driving, Concrete Foundation Construction, Site Utilities Work (gas, Electric, Communications), Water & Wastewater , Hvac, Commercial Kitchen Installation, Structural Steel Construction, Tower Observation Platform/lantern Installation, Finish Quality Exterior And Interior Carpentry, And Asphalt/concrete Paving. The Selected Contractor Will Be Responsible For All Labor, Supervision, Engineering, Permitting, Materials, Equipment, Tools, Parts, Supplies, And Transportation To Perform The Services Described In The Specifications And Drawings For The Project. Pmis #¿s: 318662, 326935, 342029 The North American Industry Classification System (naics) Code For This Requirement Is 236220, Commercial And Institutional Building Construction. The Small Business Size Standard Is $45,000,000.project Magnitude: Between $1,000,000 And $5,000,000.if You Are Interested, Please Submit Your Response Electronically Via Email To Juan_roman@nps.gov By The Response Date Of January 10, 2025, At 4:00pm Pst. If You Chose To Submit A Package, Clearly Identify The Notice Number 140p8525r0003 In The Title Of The Email And On All Documents. It Is Requested That Interested Small Businesses Submit A Response That Demonstrates The Ability To Perform The Services Described.all Responses Should Include: (1) The Attached Contractor Information Form.(2) Capabilities Statement For Your Company. The Capabilities Submitted Should Demonstrate Same Or Similar Experience. (3) Information On Past Projects. All Past Projects Must Have Been Completed Within The Last 5 Years From The Response Date Of This Notice. Projects Should Demonstrate Experience That Encompasses A Variety Of Construction Services In The Cost Range Described Above. A Maximum Of 10 Detailed Project Descriptions May Be Submitted. A List Of Other Projects Completed Within The 5-year Time Span May Also Be Submitted. Project Information Should Contain A Project Description, Contract Number, Dollar Amount Including % Over / Under Project Budget, Change Orders Total Cost And % Of Final Costs, Duration Including % Over / Under Initial Schedule, Project Tracking And Communications Tools Used, Location, Customer Point Of Contact Information Including Email And Telephone, And Any Other Pertinent Information.(4) Under Far 52.219-14, Limitations On Subcontracting, The Employees Of Each Small Business Must Perform At Least 15% Of The Work As Measured By The Dollar Value Of Their Task Order Contract. The 15% Shall Not Include The Costs For Materials. Responses Must Include A Description As To How Your Small Business Would Meet This Far Requirement.response To This Announcement Is Strictly Voluntary; No Reimbursement Will Be Made For Any Costs Associated With Providing Information In Response To This Sources Sought Announcement Or Any Follow-up Information Requests. Analysis Of The Quantity And Quality Of Responses To This Sources Sought Announcement Will Be Considered In The Market Research Being Conducted, And In The Making Of Any Small Business Set-aside Determination For This Requirement.the Government Anticipates Conducting A Competitive Acquisition For This Requirement. The Amount Of Interest Or Lack Thereof Will Determine The Possibility Of A Competitive Set-aside Or Full And Open Competition (the Size Of A Small Business Firm Includes All Parents, Subsidiaries, Affiliates, Etc.-see 13 Cfr 121.108.) Misrepresentation Of Size Status Can Result In Penalties. Please Refer To The Current Sba Rules Regarding Hubzone Firms, Effective October 1, 2011.the Information Provided In This Notice Is Subject To Change And In No Way Binds Nps To Solicit For Or Award A Contract. Nps Will Not Provide Debriefs On The Results Of This Research, But Feedback Regarding The Decision To Set Aside Or Not Aside The Procurement Will Be Accomplished Via Pre-solicitation Synopsis Or Solicitation For These Services As Applicable. All Information Submitted Will Be Held In A Confidential Manner And Will Only Be Used For The Purpose Intended. Points Of Contact Listed May Be Contacted For The Purpose Of Verifying Performance.