Fire Tenders

Details: Description 1. About The Procuring Entity The Board Of Investments (boi) Is An Attached Agency Of The Department Of Trade And Industry (dti) That Is The National Government Entity Responsible For The Promotion Of Investments For Both Foreign And Domestic, In Accordance With Executive Order No. 226, Also Known As The Omnibus Investments Code Of 1987, And The Recently Approved R.a. 11534 Or The Create Law. The Boi Seeks To Attract Quality Investments That Will Encourage Technological Innovations And Provide Support For Industries To Seize The Opportunities And Challenges Of Global Competition And Demands. The Agency Envisions Itself As A Global Industry Promotion Agency By 2022 Guided By The Core Values Of Integrity, Excellence, Teamwork And Passion For Knowledge. Its Mission Is To Provide Investors With Opportunities For Investments, Comprehensive Business Support Services And Fair Predictable And Consistent Industry Policies. The Current State Of The Economy Due To The On-going Pandemic Makes It More Imperative For Boi To Continuously Aim For Work Excellence, As It Is An Agency, Which Is At The Forefront Of Enticing Investments Into The Country. 2. Project Overview/objectives In Order To Effectively Fulfill The Mandate And Facilitate The Delivery Of Boi’s Core And Support Functions, A 24/7 Maintenance Operations Of The Boi Server Room At The 5th Floor That Hosts Various Application Servers And Other Communication And Network Equipment Is Needed. The Boi Server Room Caters To The Boi Local Area Network (lan). To Upgrade And Have An Existing Boi Server Room With A Fully Functional Data Center, The Boi Is Requesting To Transfer Or Create A Data Center At The Fourth Floor (4/f) Of Industry And Investments Building, 385 Sen. Gil J. Puyat Ave, Makati City. This Is To Ensure Compliance With Industry Standards For It Infrastructure And Data Protection. It Will Also Serve As The Host Of Voice, Video, And Data Requirements Of Boi. Generally, The Data Center Will Include The Following Infrastructure Components: Electrical And Civil Works Component • Site Preparation (civil, Mechanical, And Electrical Works) • Supply And Installation Of New Data Center Build-ups Such As New Static Flooring, Drywall, It Monitoring Room, Electrical Power And Lighting, Temperature, Humidity Monitoring Solution, Acoustic Ceiling, And Drip Pan For Potential Water Leak. • Provisioning Of A Monitoring Room Inside The Proposed Data Center • Installation Of New Server Rack Cabinets Complete With Their Accessories. • Transferring Of Existing Servers, Ups, And Other Data Center Components From The 5th Floor To The New Data Center, Including Mounting, Harnessing, Terminating, And End-to-end Tagging. • Transfer And Installation Of Electrical Works Of Existing 2x 20kva Ups Including Panel Boards And Electrical Wires For Its Distribution • Supply And Installation Of Electrical Works For Precision Air Conditioning Unit (pacu) • Supply And Installation Of A Stand-alone Door Access System Including Biometric Device, And Door Lock Accessories For Physical Security Of A New Data Center. • Supply And Installation Of A New 50kva Powered Diesel Generator Set Including An Isolated Dry Type Of Step-up Transformer • Supply And Installation Of New Automatic Transfer Switch (ats) And Other Components • Supply And Installation Of Temperature, Humidity Control System, And Water Leak Detection System • Supply And Installation Of Communication Grounding And Bonding System. • Supply And Installation Of Roughing-in Materials • Submission Of Test Results, As-built Plan, And Documentation • Cleaning And Retouching Of All Affected Areas Including Necessary Rectifications Network Component • Supply, Installation, And Configuration Of Core Switches • Supply, Installation, And Configuration Of Server Farm Switches • Supply, Installation, And Configuration Of Access Switches • Supply, Installation, And Configuration Of Wireless Access Points • Structured Cabling (horizontal And Vertical) • Provisioning Of Intermediate Distribution Frames (idfs) Cabinets And Other Network Components (2nd, 3rd, 4th Floors) • Supply, Installation, And Configuration Of Servers And Server Rack And Accessories • Transfer Of Network Backbone Connection From 5th Floor To 4th Floor • End-to-end Tagging And Labeling Of All Utp Copper And Fiber Cables • Documentation O Cabling Plan For Structured Cabling And Data Center O Final Cabling Plan As-built Plan With Line Diagram O Final Network/structured Cabling Diagram O Network Vlan Configuration O Softcopy And Hardcopy Of Core, Server Farm, Access Switch, Wlc Running Configuration • Certification Training On Installed Network Switches, Aps, And Other Components. Objectives Of The Project: • To Protect And Secure The Agency's Existing Ict Investments (firewalls, Routers Switches, Servers, Etc.); • To Ensure A Dependable, Secured, And Efficient Ict Support Services (internet, Intranet, Database And Printer Sharing, Etc.); And • To Create An Industry-standard Datacenter For Effective Management Of Network Resources. 3. Deliverables No Particulars Qty Unit 1 Datacenter Civil And Architectural Works 1 Lot 2 Electrical Works, Segregated Power Source Dedicated To Data Center Equipment’s, And Idf Deployed At 1st Floor, 3rd Floor, And 5th Floor 1 Lot 3 Transfer 2x 20kva Ups And Other It Components From The Old Data Center To The New Data Center (servers, Isp, Etc.) 1 Lot 4 Generator Set, 50kva 1 Unit 5 Automatic Transfer System (ats) 1 Unit 6 Precision Air-conditioning Units 2 Units 7 Data Rack 42u (mdf) 2 Units 8 Data Rack 24u (idf) 3 Units 9 Temperature And Humidity Monitoring System 1 Lot 10 Water Leak Detection System 1 Lot 11 Datacenter Access Control System (biometrics, Magnetic Door Lock, Etc.) 1 Lot 12 Structured Cabling 1 Lot 13 Fiber Optic Backbone 1 Lot 14 Core Switch 2 Units 15 Server Farm Switch 2 Units 16 Access Switch 4 Units 17 Access Points 63 Units 18 Transceivers (for Inter-network Link Of Devices) 32 Units 19 End-to-end Tagging And Labeling Of All Utp Copper And Fiber Cables 1 Lot 20 Softcopy And Hardcopy (hardbound) Documentation (as-built, Test Plan, Ip Address Assignment, Vlan Assignment, User’s Manual, Administrators Manual, Etc.) 1 Lot 4. Technical Requirements 4.1 The Bidder Shall Comply With The Following Minimum Specifications For The Physical Data Center And Network Components Of The Project: Item Description Bidder’s Statement Of Compliance Item No 1 Site Preparation (civil, Mechanical, And Electrical Works) • Electrical Wirings With Grounding • Service Entrances For Utilities • Ceiling Installation • Installation Of Industry-grade Data Center Main Door • Installation Of Datacenter Cooling System Item No 2 Laying Of New Electrical Power Lines Distributions/ups Transfer • Provision Of Main Distribution Panel Board (mdp) Main 125a/3p/400vac • Provisioning, Installation, And Configuration Of Dedicated Ats • Provisioning, Installation, And Configuration Of Dedicated Generator Set (at Least 50kva, 129 Amp, Three Phase Dual Voltage, 220-240v Output, At Least 60hz Frequency) • Excavation/backfilling From The Building To The Powerhouse For The Encasement Of The Feeder Line For Power, Ats, And Genset • Transfer And Re-termination Of Electrical Requirements For 2 Units 20kva Ups • Transfer Of Other It Assets From The Old Data Center To The New Data Center • Provisioning Of Electrical Distribution From Data Center Power To Mdfs Located Per Floor • Lighting Fixtures For Datacenter • Testing Of Electrical Equipment Item No 3 Tracing, Tagging, Relocation, And Transfer Of Boi Fas-itd It Equipment (servers, Switches, Routers, Etc.) From 5th Floor To 4th Floor • Tracing Of Backbone To Core Switch Connection • Tracing Of Connection Between Devices Inside The Datacenter • Tagging Of Copper And Fiber Optics Wire Inside The Datacenter • Cable Management • Vertical And Horizontal Cabling From Datacenter To Mdfs And Mdfs To End-nodes Item No 4 Provisioning Of Two (2) 42u Regular Server Racks • 42u With Roof, Side Panel, Castors, Feet, And Brackets • Adjustable Shelf • Vertical Cable Manager • At Least 1 Rack Mountable Kvm (keyboard, Video, Monitor) • Power Rail/strip Options Item No 5 Provisioning Of Three (3) 24u Server Racks To Be Deployed At Mdfs • 24u With Roof, Side Panel, Castors, Feet, And Brackets • Heavy-duty Steel Construction • Door Locks • Anti-tamper Sensors • Network Management Card, Remote Monitoring Capabilities, Snmp Support • With Power Distribution Units (pdu), And Ups Compatibility • Cable Manager Item No 6 Physical Security (door Access, Biometrics, Temperature Monitoring) • Provisioning Of A Solid Door And Tempered Glass Around The Proposed Data Center (1/2, Frameless Door) • Door Access Control Should Conform To Iso-27001 Standards • Magnetic Lock • Biometrics Based Access Control • Access Logs Should Be Maintained For A Minimum Of One Year Or Longer As Specified By The Site Security Policy. • Secured Doors Must Fail Open In A Fire Emergency. Item No 7 Transfer Of Network Backbone Connection From 5th Floor To 4th Floor • Tracing And Tagging Of Backbone Connection From Mdf To Idf • Looping Of Excess Fiber Cable • Re-termination Of Fiber Cable If Necessary Item No 8 Monitoring Room Inside The Proposed Data Center • Provisioning Of Additional Room Inside The Data Center To Serve As A Monitoring Room Item No 9 Anti-static Flooring • Not Generate Static • Groundable After Installation • Have Permanent Static-resistant Properties That Can Provide Protection Amidst Changing Temperatures, Humidity Levels, And Foot Traffic Item No 10 Precision Air Conditioning Unit (pacu) - 2 Units • Shall Have A Nominal Capacity Of Up To Ten (10) Kw • Shall Be Free Blow Type With Plenum And Directional Air Flow Louver Grille • Panels Shall Have A Solid And Rigid Double Skin Insulated • Shall Have A Minimum Net Sensible Capacity Of Ten (10) Kw • Shall Have A Minimum Net Total Capacity Of Eleven (11) Kw • Shall Have A Built-in Touch Screen Display That Provides Informative And User-friendly Interface For Easy Navigation • Shall Have A Built-in Auto Sequencing (1unit Operational And 1unit Back-up, Every 3 Days Sequence Of Operation) • Shall Be Single Circuit Dx Type, Freon R410a • Shall Have Electronic Expansion Valve • Shall Be 380vac,3ph, 6ohz • Shall Recommend Placement Of Air Conditioner Units And Limitations To Be Observed Item No 11 Temperature And Humidity Sensor, And Water Leak Detection System • Base Unit: Sensor Gateway For Up To 4 External Probes • Poe Switch 8 Ports • Sensor Hub • Temperature And Humidity Sensor • Water Leak Sensor Probe • Extension Cable For Water & Flooding Sensor Item No 12 General Requirements Mobilization And Demobilization Labor, Installation, Engineering, And Project Supervision Testing And Commissioning As-built Plans And Documentation (inclusive Of Signed And Sealed) 4.2 Supply, Delivery, Installation, Configuration, And Commissioning Of Network Equipment. Qty Specifications Bidder’s Statement Of Compliance 2 Layer 3 Data Switch To Act As Enterprise Core Layer Switch Features 1. High Performance And Throughput • High Port Density (24-48 Ports) • At Least 960 Gbps Switching Capacity • High Forwarding Rate • Line-rate Packet Processing With Minimal Latency • Non-blocking Architecture With Wire-speed Performance Across All Ports 2. Advanced Switching Capabilities • Layer 2 And Layer 3 Switching Capabilities • Support For Multiple Switching Fabrics • Advanced Qos (quality Of Service) Mechanisms • Support For Vlan Segmentation And Routing 5 High Redundancy And Reliability • Dual Power Supplies • Hot-swappable Components • Redundant Supervisor Engines • Support For Virtual Chassis Technologies • Comprehensive Fault Tolerance Mechanisms 6 Security Characteristics • Advanced Access Control Lists (acls) • Port Security Features • Dhcp Snooping • Dynamic Arp Inspection • Ieee 802.1x Authentication • Integrated Threat Management 7 Routing Protocol Support • Bgp • Ospf • Is-is • Mpls • Multi-protocol Routing Capabilities 8 Management And Monitoring • Snmp Support • Comprehensive Network Monitoring Tools • Remote Management Interfaces • Detailed Logging And Diagnostic Capabilities • Advanced Technological Support 9 Hardware-based Packet Forwarding • Support For Software-defined Networking (sdn) • Ipv6 Compatibility • Mpls And Vpn Support 10 Supports Cloud Management With Wired Assurance: • Provides Operational Visibility Into The Wired Experience With Service-level Expectations (sles) For The Proposed Switch. • Simplified Onboarding And Provisioning With Single-click Activation Which Adds True Plug-and-play Capabilities To The Cloud-ready, Zero-touch Provisioning (ztp)-enabled Switch. • Configuration Models Use Global Templates For Bulk Rollouts While Retaining The Flexibility To Apply Custom Site- Or Switch Specific Attributes. • Device, Port, And Interface Profiles Allows For The Manual Provisioning Of Colored Ports Or Auto-provisioning Of Colorless Ports. • Open Apis Support Third-party Integrations Such As Servicenow And Splunk To Automate Troubleshooting, Ticketing, And More. • Wired Service Level Expectation (sles) Allow To Set, Monitor, And Measure Wired User Experiences Such As Throughput, Successful Connections, And Switch Health With Pre- And Post-connection Performance Metrics. • Ai-driven Switch Insights Reveal Switch Performance, Including Detailed Device-level Metrics Such As Cpu And Memory Utilization. • Features Virtual Network Assistant. 2 Layer 3 Data Switch To Act As Server Farm Switch Features: 1. High-performance Specifications • High Port Density (24-48 Ports) • Wire-speed Performance • Low Latency Switching • Gigabit Ethernet Support • At Least 960 Gbps Switching Capacity 2. Advanced Connectivity Features • Support For Multiple Interface Types • Layer 2/layer 3 Capabilities • Fabric Connection Technologies • Vm-aware Networking 3. Redundancy And Reliability • Hot-swappable Components • Dual Power Supplies • Redundant Supervisor Engines • Non-stop Forwarding (nsf) • Stateful Failover Capabilities 4. Performance Security Features • Hardware-based Acls • Port Security • Advanced Threat Protection • Ieee 802.1x Authentication • Micro-segmentation Support 5. Management Capabilities • Advanced Monitoring Tools • Snmp Support • Comprehensive Logging • Remote Management Interfaces • Network Telemetry 6. Supports Cloud Management With Wired Assurance: • Provides Operational Visibility Into The Wired Experience With Service-level Expectations (sles) For The Proposed Switch. • Simplified Onboarding And Provisioning With Single-click Activation Which Adds True Plug-and-play Capabilities To The Cloud-ready, Zero-touch Provisioning (ztp)-enabled Switch. • Configuration Models Use Global Templates For Bulk Rollouts While Retaining The Flexibility To Apply Custom Site- Or Switch Specific Attributes. • Device, Port, And Interface Profiles Allows For The Manual Provisioning Of Colored Ports Or Auto-provisioning Of Colorless Ports. • Open Apis Support Third-party Integrations Such As Servicenow And Splunk To Automate Troubleshooting, Ticketing, And More. • Wired Service Level Expectation (sles) Allow To Set, Monitor, And Measure Wired User Experiences Such As Throughput, Successful Connections, And Switch Health With Pre- And Post-connection Performance Metrics. • Ai-driven Switch Insights Reveal Switch Performance, Including Detailed Device-level Metrics Such As Cpu And Memory Utilization. • Features Virtual Network Assistant. 4 Layer 3 Data Switch To Act As Access Layer Switch 1. Port Density And Connectivity • Minimum Of 48 Ports • Support For 1g/10g Interfaces • Rj45 And Sfp/sfp+ Port Options • High-density Connectivity • Poe/poe+ Support (up To 30/60 Watts) 2. Performance Characteristics • Low Latency Switching • Wire-speed Performance • Minimum 80-160 Gbps Switching Capacity • Packet Forwarding Rate: 100-240 Mpps 3. Advanced Switching Capabilities • Layer 2/layer 3 Functionality • Vlan Segmentation • Spanning Tree Protocol (stp/rstp) • Link Aggregation (lacp) • Quality Of Service (qos) Support 4. Security Features • Port Security • 802.1x Authentication • Dynamic Arp Inspection • Dhcp Snooping • Mac Address Filtering • Private Vlans • Storm Control 5. Management Capabilities • Snmp Support • Cli Access • Web-based Management • Remote Monitoring • Syslog Integration • Fast Convergence Protocols • Redundant Power Supplies 6. Supports Cloud Management With Wired Assurance: • Provides Operational Visibility Into The Wired Experience With Service-level Expectations (sles) For The Proposed Switch. • Simplified Onboarding And Provisioning With Single-click Activation Which Adds True Plug-and-play Capabilities To The Cloud-ready, Zero-touch Provisioning (ztp)-enabled Switch. • Configuration Models Use Global Templates For Bulk Rollouts While Retaining The Flexibility To Apply Custom Site- Or Switch Specific Attributes. • Device, Port, And Interface Profiles Allows For The Manual Provisioning Of Colored Ports Or Auto-provisioning Of Colorless Ports. • Open Apis Support Third-party Integrations Such As Servicenow And Splunk To Automate Troubleshooting, Ticketing, And More. • Wired Service Level Expectation (sles) Allow To Set, Monitor, And Measure Wired User Experiences Such As Throughput, Successful Connections, And Switch Health With Pre- And Post-connection Performance Metrics. • Ai-driven Switch Insights Reveal Switch Performance, Including Detailed Device-level Metrics Such As Cpu And Memory Utilization. • Features Virtual Network Assistant. 63 Wireless Access Points 1. Performance Characteristics • Dual-band (2.4 Ghz And 5 Ghz) • Wi-fi 6 (802.11ax) Support • Maximum Theoretical Throughput: 5.4 Gbps • Concurrent Dual-band Operation 2. Coverage And Capacity • Recommended Coverage: 150-200 Users Per Ap • Indoor Enterprise-grade Performance • Suitable For Open Offices, Conference Rooms, And Collaborative Spaces 3. Technical Specifications • 4x4:4 Mu-mimo Technology • Beamforming Support • Maximum Concurrent Clients: 512 • Transmit Power: Up To 25 Dbm 4. Advanced Features • Ai-driven Wireless Optimization • Automated Channel And Power Management • Location Services • Cloud-managed Platform 5. Security Capabilities • Wpa3 Support • 802.1x Authentication • Rogue Ap Detection • Integrated Security Fabric • Advanced Threat Protection 6. Artificial Intelligence • The Wireless Solution Must Include Virtual Network Assistant That Supports Natural Language Processing (nlp) Capabilities For Daily Operation. • Api Integration With Generic Ai Such As Google, Alexa And Siri Is Not Considered As Virtual Network Assistant Feature. • The Virtual Network Assistant Must Provide A Conversational Interactive Interface. • The Virtual Network Assistant Must Provide A Single-page Event And Data Correlation View To Eliminate The Need To Pull Up Multiple Dashboards Or Memorize Cli Commands. The Virtual Network Assistant Must Support Multi-vendor Switch Insights: • Switch-ap Affinity To Show How Many Aps Are Connected To A Switch, Reducing Impact Outages • Poe Compliance To Help Manage And Balance The Power Draw Of Connected Devices • Inactive Or Missing Wired Vlans That Are Misconfigured On Switch Ports Where Aps Are Connected But Clients Are Getting Blocked • Version Compliance For Switches Running Dissimilar Hardware • Switch Uptime To Monitor When Switches Are Online Or Offline • The Virtual Network Assistant Must Be Able To Provide Corrective Action Suggestions To Resolve Failures. • The Virtual Network Assistant Must Support Proactive Rma For Unhealthy Access Points. • The Virtual Network Assistant Must Support External Event Triggers Such As Automatic Creation Of A Ticket To External Support Systems With Email Alerts And Webhooks 1 Web-based Controller And Cloud Platform Management 1. Management Capabilities • Identity And Access Management • Centralized Cloud-based Management • Single-pane-of-glass Dashboard • Automatic Firmware Updates • Zero-touch Provisioning • Global Configuration Management 2. Ai-powered Analytics • Proactive Client Experience Monitoring • Automated Troubleshooting • Machine Learning-based Insights • Performance Prediction • Anomaly Detection 3. Security Features • Integrated Security Management • Automatic Threat Detection • Rogue Ap Identification • Compliance Reporting • Role-based Access Control 4. Key Functionalities • Network Configuration • Client Location Services • Performance Analytics • Detailed Reporting And Visualization 5. Access Methods • Web Browser Interface • Mobile Application • Continuous Monitoring And Optimization 1 Lot Structured Cabling • Cat6 Utp Cable • Information Outlet • Faceplate • Patch Panel 5. Scope Of Work Bidders Shall Comply With The Following: • Bidders Shall Be Allowed To Visit The Actual Site For The Preparation Of The Plans Prior To The Submission Of Their Proposal. Bidder Shall Submit An Architectural And Electrical Layout/design Based On User Requirements Together With Their Technical Bid Proposal. • Supply, Delivery, And Installation Of Complete Site Preparation Labor And Materials Including Other Peripherals Needed To Complete The Site Without Additional Cost To Procuring Entity. Bidder Shall Submit A Complete Bill Of Materials For The Site Preparation Component. • Transfer Of Existing Network Components, Servers, And Other It Peripherals From Current Location To New Data Centers • Supply And Installation Of Data Centers Power Distribution And Pacu Power Supply. • Supply, Delivery, And Installation Of Complete Fire Suppression System Including Hangers, Support, And Other Peripherals That May Be Needed To Complete System Without Additional Cost To Procuring Entity. • Supply, Delivery, And Installation Of Complete Security Door Access Input And Output Cables Including Rough-ins, Hangers, Supports, And Other Peripherals That May Be Needed To Complete The System Without Additional Cost To Procuring Entity. Registration Of Personnel To The Door Access System Shall Be Scheduled To Avoid Disruption Of Work. • Provisioning Of Vertical And Horizontal Cabling • Testing Of Each System Shall Be Done Accordingly And Will Be Certified As Completed After Performing And Passing The Functionality Test And The User Acceptance Test. 6. Product Support Requirement 6.1 24x7 Remote Support Through Phone And Email; And Services Assistance Thru Email, Phone, And Web-chat With A Response Time Of Not More Than An Hour Upon Receipt Of The Request From Boi. 6.2 Provision Of 24x7 On-site And On-call Services. 6.3 Provide Comprehensive Service Level Agreement 7. Bidders Eligibility And Project Team Requirements 7.1 A Philippine Contractor Accreditation Board License. At Least With Category A Level; With Classifications In Communication Facilities, Mechanical Works, Electrical Works, And Air-conditioning Works 7.2 The Contractor Must Have At Least One (1) Employed Electronics/electrical Engineer Fully Certified. A Copy Of The Certification Shall Be Provided. A Certified Engineer Must Be Employed By The Bidder For At Least Three (3) Years. 7.3 An Employed Certified Data Center Specialist Personnel; The Personnel Should Have Been Employed For A Minimum Of Three (3) Years 7.4 An Employed Safety Officer With A Construction Occupational Safety And Health Certificate; The Personnel Should Have Been Employed For A Minimum Of Three (3) Years. 7.5 An Employed Certified Associate In Project Management; The Personnel Should Have Been Employed For A Minimum Of Three (3) Years 7.6 The Bidder Must Have Completed At Least One (1) Similar Project In The Supply, Delivery, Installation, Testing, And Commissioning Of A Datacenter Within The Last 10 Years. This Should Be Supported By A Certificate Of Completion And Acceptance By The Client. 7.7 Bidder Should Provide A Certificate That Has 24x7 Technical Support Capabilities. Bidder Should Identify The Person Responsible For Restoring Service Due To Outages And Provide His Contact Details I.e. Contact Person, Position, Contact Numbers, And Email Address. 7.8 Contractors Must Have Philippine Contractors Accreditation Board (pcab) Licenses Required By Republic Act 4566 To Perform Telecommunications /communications Installations. 7.9 A Member Of The Safety Organization Of The Philippines 7.10 A Certificate To Show The Company Is Registered With The National Privacy Commission 7.11 All Prospective Bidders Must Be Authorized Resellers Of All Equipment To Be Supported By A Certificate Issued By The Manufacturer/distributor Of Equipment/materials. 7.12 All Prospective Bidders Shall Submit The Original Copy Of The Design Proposal, Brochures, And Other Publications That Support Compliance To The Requirements. 7.13 Proposed Work Plan And Detailed Implementation Schedule For The Project Covering The Whole Period. Prospective Bidders Are Required To Conduct Site Inspections. This Is To Ensure The Reliability, Security, And Efficiency Of The Required Services That The Contractor Shall Perform. The Timeframe Should Be Specified For Each Activity To Be Done And Shall Include Gantt Chart Summary. 7.14 The Contractor Shall Be Held Solely Responsible For Any Property Or Personal Damages Or Claims, Including Damage To Existing Structures, Systems, Equipment, And/or Site Caused By The Contractor Shall Repair Or Replace It To Its Original Condition At No Additional Cost To The Office. 7.15 The Contractor Shall Be Responsible And Accountable For The Removal And Proper Disposal Of Material And Waste Generated By This Project. Debris, Surplus Materials, Equipment, Etc. Shall Be Removed Daily. 7.16 All Prospective Bidders Shall Submit Original Copy Of Design Proposal, Brochures And Other Publications That Supports Compliance To The Requirements. 8. Project Team Requirements/composition Team Composition And Qualifications The Winning Bidder Shall Assemble A Comprehensive Project Team With The Following Mandatory Positions And Qualifications: Project Management Team 8.1 Project Manager O Minimum Of 10 Years Of Experience In Large-scale It Infrastructure Projects O Proven Track Record In Data Center And Network Refresh Initiatives O Relevant Pmp (project Management Professional) Or Equivalent Certification O Demonstrated Experience In Managing Complex Technological Transformations 8.2 Deputy Project Manager O Minimum Of 7 Years Of Experience In It Infrastructure Projects O Strong Technical Background In Data Center And Network Technologies 8.3 Network Infrastructure Lead O Minimum Of 8 Years Of Specialized Experience In Enterprise Network Design O Advanced Certifications (ccie, Ccnp, Or Equivalent) O Expertise In Modern Network Technologies, Including Sdn, Cloud Integration, And Cybersecurity 8.4 Data Center Infrastructure Specialist O Minimum Of 8 Years Of Experience In Data Center Infrastructure Design And Implementation O Expert In Cooling, Power Management, And Physical Infrastructure Design O Certifications In Data Center Design And Management Support And Implementation Team 1. Senior Systems Engineers (minimum 2) O Each With At Least 6 Years Of Experience In Enterprise System Integration O Comprehensive Knowledge Of Server, Storage, And Virtualization Technologies 2. Network Engineers (minimum 2) O Each With At Least 5 Years Of Experience In Enterprise Network Implementation O Expertise In Network Configuration, Optimization, And Security Additional Team Requirements • The Winning Bidder Must Provide Detailed Cvs And Certifications For Each Key Team Member • Any Changes To The Proposed Team Composition Must Be Pre-approved By The Board Of Investments • The Team Must Demonstrate Collective Experience In Similar Large-scale Infrastructure Projects • All Team Members Must Be Available For The Full Duration Of The Project • The Bidder Must Have A Clear Succession And Backup Plan For Critical Roles The Board Of Investments Reserves The Right To Request Changes To The Team Composition If It Does Not Meet The Project's Critical Requirements. 9. Inspection And Tests The Procuring Entity Or Its Representative Shall Have The Right To Inspect And/or To Test The All Equipment To Ensure Their Conformity To The Project Specifications At No Extra Cost To The Procuring Entity In Accordance With The Generic Procurement Manual. In Addition To Tests In The Scc, Section Vii (technical Specifications) Shall Specify What Inspections And/or Tests The Procuring Entity Requires, And Where They Are To Be Conducted. The Procuring Entity Shall Notify The Supplier In Writing, In A Timely Manner, Of The Identity Of Any Representatives Retained For These Purposes. All Reasonable Facilities And Assistance For The Inspection And Testing Of Goods, Including Access To Drawings And Production Data, Shall Be Provided By The Bidder To The Authorized Inspectors At No Charge To The Procuring Entity. 10. Warranty 10.1 The Bidder Shall Provide A Preventive Maintenance Program During The Warranty Period For All The Delivered Equipment And System. 10.2 The Bidder Shall Provide Quarterly Preventive Maintenance On The Pacu, Fire Suppression, Power Distribution Units, And Door Access System During The Warranty Period. 10.3 The Bidder Shall Provide Not Less Than 4 Hours Of Response Time After Receiving Calls From The Client During The Warranty Period. 10.3 The Procuring Entity Shall Promptly Notify The Supplier In Writing Of Any Claims Arising Under This Warranty. Upon Receipt Of Such Notice, The Supplier Shall, Repair Or Replace The Defective Goods Or Parts Thereof Without Cost To The Procuring Entity, Pursuant To The Generic Procurement Manual. 11. License And Subscription Renewal Provision The Board Of Investments Maintains Absolute And Unconditional Rights To Renew Or Extend All Software Subscriptions, Licenses, And Service Entitlements Beyond The Initial Warranty Or Contract Period. Upon The Expiration Of Any Initial Warranty Or Support Period, We Reserve The Comprehensive Right To Renew Existing Software Licenses, Extend Service Subscriptions, Continue Maintenance And Support Contracts, And Maintain Full Access To All Software And Platform Entitlements. The Successful Bidder Must Provide Comprehensive Documentation Of All Existing Licenses And Subscriptions. This Includes Delivering Complete Credentials, Access Keys, And Licensing Information To Facilitate Seamless Transitions And Ensure Our Continued Operational Effectiveness. We Require Full Disclosure Of Licensing Terms, Clear Renewal Pathways, And Complete Transparency In All Licensing Models. 12. Delivery The Delivery And Commissioning Of All Items For The Data Center Shall Not Exceed 120 Calendar Days Upon Issuance Of The Corresponding Notice To Proceed (ntp). The Commissioning And Initial Testing Shall Be Conducted Within 2-3 Calendar Days After Each Component Is Completed And Witnessed By The End User. After Completion Of The Data Centers, The Bac-twg Together With End User Shall Conduct Functionality Tests. These Will Ensure That All Of The Project's Specifications And Requirements Are Met Must Provide In Hard And Soft Copies Detailed Project Documentation Of The Following: A. Project Implementation Plan With Timetable, B. Installation And Configuration Manual, C. Incident And Problem Escalation Procedure With A List Of Designated Technical Support Engineers, D. Sla (service Level Agreement) E. User Acceptance Test Plan, 13. Training And Technology Transfer A. The Contractor Must Provide Training For At Least Five (5) It Personnel For The Network Equipment/switches, And Troubleshooting For The Structured Cabling And Management Of The Data Center For At Least Three (3) Days Per Module. B. To Ensure That Proper Maintenance And Sustainment Appropriate Training Shall Be Conducted By The Contractor As Essential Part Of Technology Transfer To Prepare And Equip Boi And Its Personnel In The Overall Operations And Maintenance Of Its Network Infrastructure And It Facility. C. The Contractor Shall Submit A Program Of Instruction (poi) Detailing All The Training Activities To Be Conducted For Review, Evaluation, And Approval Of Boi. Hands-on Training Shall Form Part Of The Training Program. D. Operation And Training Manuals Shall Be Provided To Each Participant. E. The Training Shall Be Conducted And Completed Before The Issuance Of The Certificate Of Project Completion And Acceptance. F. All Expenses Related To Training (e.g. Venue, Meals, Equipment, Certificate.) Shall Be Borne By The Contractor. G. Certificate Of Training/s Shall Be Given By The Contractor To All Participants. 14. Liability Of The Bidder The Bidder’s Liability Under This Contract Shall Be As Provided By The Laws Of The Republic Of The Philippines. If The Supplier Is A Joint Venture, All Partners To The Joint Venture Shall Be Jointly And Severally Liable To The Procuring Entity. 15. Incidental Services 1. Spare Parts The Supplier Is Required To Provide All Of The Following Materials, Notifications, And Information Pertaining To Spare Parts Manufactured Or Distributed By The Supplier: A. In The Event Of Termination Of Production Of The Spare Parts/expiration Of Software Licenses O Advance Notification To The Procuring Entity Of The Pending Termination, In Sufficient Time To Permit The Procuring Entity To Procure Needed Requirements; O Following Such Termination Of Production, Furnishing At No Cost To The Procuring Entity, The Blueprints, Drawings, And Specifications Of The Spare Parts, If Requested; O The Bidder Shall Carry Provide The List Of Vendor Of Consumable Spare Parts Or Components For The Equipment. 16. Institutional Requirements Equipment And Asset Ownership All Equipment, Hardware, Software, Infrastructure Components, And Other Tangible And Intangible Assets Procured, Installed, Or Developed During The Data Center Rehabilitation And Network Refresh Project Shall Become The Sole And Exclusive Property Of The Board Of Investments (boi). The Contractor Is Prohibited From Removing Any Delivered Items From The Project Site After Installation Or Project Completion. Specific Provisions Include: • Full Ownership To All Project-related Assets Shall Immediately Transfer To Boi Upon Delivery Or Installation • The Contractor Shall Provide All Necessary Documentation To Formally Transfer Ownership, Including But Not Limited To Equipment Lists, Serial Numbers, Warranty Information, And Certificates Of Ownership • Any Attempt To Remove Or Retain Project-related Items Without Authorization Will Be Considered A Material Breach Of Contract The Contractor Shall Submit Project Implementation And Management Plan (pimp) Within Ten (10) Calendar Days Upon Receipt Of Notice To Proceed For The Implementation Of The Proposed Solution, Which Is Subject To Review And Approval By The Boi. The Pimp Shall Include But Not Be Limited To The Following: • Scope Of Work • Project Organization • Implementation Methodology • Project Timeline • Communication And Deployment Strategy The Contractor Shall Provide Complete Documentation, One (1) Soft Copy And Three (3) Printed Copies, For Every Deliverable And At Every End Of Each Development Stage And Milestone Which Must Be Submitted To The Boi For Approval. Boi Shall Own Any And All Documents And Shall Reserve The Right To Reproduce At No Additional Cost. The Documentation Must Be Written In English With Concise And High-quality Presentation To Include But Not Limited To The Following: 1. Technical Manuals: • As Built Document • Infrastructure Diagrams And Topology • Troubleshooting And Installation Guides • Single Line Diagram • System/operation Manual 2. Operations And Maintenance Manuals 17. Intellectual Property Rights The Bidder Shall Indemnify The Procuring Entity Against All Third-party Claims Of Infringement Of Patent, Trademark, Or Industrial Design Rights Arising From Use Of The Goods Or Any Part Thereof. 18. Approved Budget Cost The Board Of Investments Intends To Apply The Sum Of Thirty-one Million Pesos (31,000,000.00) Being The Approved Budget For The Contract (abc) For The Completion Of The Relocation And Transfer Of The Board Of Investments’ Datacenter And It Related Infrastructure From 5th Floor To 4th Floor To Be A High-performing And Scalable It Infrastructure. Bids Received In Excess Of The Abc Shall Be Automatically Disqualified At The Opening Of The Financial Proposals. Prices Are In Php And Are Vat-inclusive. 19. Source Of Funds The Budget Authorized For Procurement Of Service For The Relocation And Transfer Of Boi Datacenter From 5th Floor To 4th Floor Shall Be Sourced From The 2025 Capital Outlay (co) And Maintenance And Other Operating. Expenses (mooe), Pursuant To The Philippine General Appropriation Act Of 2025. 20. Payment 10% Project Mobilization: Covers Initial Costs, Including Project Planning And Resource Allocation, And To Submit The Project Implementation Plan 25% Network And Datacenter Infrastructure Facility Civil Works All Materials, Equipment, And Labor Necessary For The Construction Of The It Infrastructure Facility Including All Civil Works, Walls, Doors, Partitions, Flooring, Security Access Pass, Air-conditioning Unit And Other Accessories/appurtenances As Specified And As Shown In The Drawings. 25% Delivery Of Equipment And Materials, Structured Cabling, Fixing, Installation Of Cables, Conduit, Outlets Racks Ladders, And Other Components (active Components) All Materials Are To Be Used In The Installation And Cabling. Installed Cables, Conduit, And Components And Tested And Working Cable Lines. 30% Upon Submission Of Certification Of 100% Completion Of Project And Passing Of The Functionality Test To Be Administered By The Bac-twg And Witnessed By The Bac 5% Training Of Personnel For The Completed Network And It Infrastructure Facility. 5% Retention Fee 100% 21. Penalty In Case There Is A Delay In The Delivery And Installation Of The Software Where Boi Is Not At Fault, The Contracted Service Provider Shall Be Subject To Sanctions As Specified In The Contract To Be Signed By Both Parties Based On The Applicable Provisions Of The Procurement Law.

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Reports (combo)|n/a|tbd|n00104|tbd|tbd|see Schedule|tbd|n/a|n/a|n/a|||||| transportation Of Supplies By Sea (oct 2024)|2||| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| notice Of Total Small Business Set-aside (oct 2020)(deviation 2020-o0008)|1|| annual Representations And Certifications (may 2024)|13|332510|750|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Days After The Closing Date As Indicated On The Quotation. Please Specify (if Otherthan 60 Days) _________ Days. if You Are Submitting Your Quote Via Email Or Neco, Please Specify The Number Of Days Pricing Is Valid. all Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders, Delivery Orders And Modifications) Related To The Instant Procurement Are Considered To Be 'issued' By The Government When Copies Are Either Deposited In The Mail, Transmitted By Facsimile, or Sent By Other Electronic Commerce Methods, Such As Email. The Government's Acceptance Of The Contractor's Proposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Not Releasable To Foreign Nationals (noforn) Distribution Statement - ;dwg 803-5959324; Is Subject To Special Export Controls And Each Transmittal To Foreign Governments Or Foreign Nationals May Be Made Only With Prior Approval Of The Naval Sea Systems Command. 2.2 Applicable Documents. technical Documents Associated To This Solicitation Or Award Such As; Drawings,technical Data, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At the Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To The Award. This Website Requires A Password And pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Manufacture And Design - The Clamp,loop Furnished Under This Contract/purchase Order Shall Meet The Requirements As Specified In The Ordering Data Listed Herein And Throughout The Contract/purchase Order. (1). Design, Material And Dimensions To Be In Accordance With: a. Manufacturer: ;naval Ship Systems Command (53711); . b. Drawing: ;803-5959324; . c. Piece Number: ;13; . Revision: ; ; . d. Part Number: ;803-5959324item-13; . e. Catalog Number ;.; . (2). The Following Requirements Apply: a. Exclusion Of Mercury Requirements Are Cited In The Additional Technical Documentation Located Within Section "c" Of The Contract/purchase Order. b. ;.; . 3.2 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 Quality Assurance Requirements- The Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. mark Packaging Label With Nomenclature: clamp Assy1/4ips in Lieu Of: clamp,loop \ date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|mil-i-45208| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Report (combo)|n/a|tbd|n00104|tbd|tbd|see Schedule|tbd|n/a|n/a|n/a|||||| inspection System Program Plans, Or Premanufacturing Or Test Procedures|1|45| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| notice Of Total Small Business Set-aside (oct 2020)(deviation 2020-o0008)|1|| alternate A, Annual Representations And Certifications (oct 2024)|13|||||||||||||| small Business Program Representations (feb 2024)|4||||| annual Representations And Certifications (may 2024)|13|314999|550|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| a Material Irpod Is Available At The Bpmi Site. Vendor Review Of The Irpod Is Mandatory. unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Daysafter The Closing Date As Indicated On The Quotation. Please Specify (if Otherthan 60 Days) ______________ Days. If You Are Submitting Your Quote Via Emailor Neco, Please Specify The Number Of Days Pricing Is Valid. all Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders, Delivery Orders And Modifications) Related To The Instant Procurement Are Considered To Be 'issued' By The Government When Copies Are Either Deposited In The Mail, Transmitted By Facsimile, or Sent By Other Electronic Commerce Methods, Such As Email. The Government's Acceptance Of The Contractor's Proposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. the Recommended Method For Roti Submittals Is Via Wawf Or An Alternative High Quality Electronic Means. (i.e. Fax Or E-mail Your Post Award P.o.c Listed Above) A Dedicated Roti Fax Has Been Added For Your Submittal Convenience. Fax Number (717) 605-8054. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Not Releasable To Foreign Nationals (noforn) Distribution Statement - Drawings, Specification, Or Related Technical Documents As Cited In The Irpod Are Subject To Special Export Controls And Each Transmittal To Foreign Govern Ments Or Foreign Nationals May be Made Only With Prior Approval Of The Naval Sea Systems Command. 2.2 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. mark The Packaging Label With The Nomenclature Identified On The Irpod. date Of First Submission=045 Dac submit For Approval One Package (iaw Di-qcic-8871) Of All Applicable Procedure, Drawing And Other Pre-manufacturing Submittals, Listed On The Individual Repair Part Ordering Data (irpod) Document(s) And Detailed In The Cited Specification, Within 45 Days After contract Award To The Contracting Officer (navsup-wss Code N9433). See Irpod For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8871 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Procedure Package To Be Iaw Did Di-qcic-8871(latest Rev). date Of First Submission=eoc a. Submit To Navsup-wss Code N9433 For Review, A Complete Package (iaw Di-qcic-8872a(latest Rev) Of All Applicable Vendor Certified Test Reports Covered In Mil-dtl-24244. See Individual Repair Part Ordering Data (irpod) For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number And Item Nomenclature Specified In The Schedule Of Supplies/services. the Package Will Be Submitted Per The Contract Delivery Schedule And Authorization To Ship Material Must Be Obtained From The Pco. b. Pack One Copy Of The Applicable Test Report With Each Individual Piece, Roll Or Sheet Furnished. di-qcic-a8872b Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Roti Package To Be Iaw Did Di-qcic-8872a(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|iso9001| inspection Of Supplies--fixed-price (aug 1996)|2||| time Of Delivery (june 1997)|20|0001aa|5|455|||||||||||||||||| stop-work Order (aug 1989)|1|| wide Area Workflow Payment Instructions (jan 2023)|16|tbd|tbd|tbd|n00104|tbd|tbd|w25g1u|tbd|||tbd|||||| navy Use Of Abilityone Support Contractor - Release Of Offeror Information (3-18))|1|| value Engineering (jun 2020)|3|||| equal Opportunity (sep 2016)|2||| integrity Of Unit Prices (nov 2021)|1|| equal Opportunity For Veterans (jun 2020)|4||||| warranty Of Data--basic (mar 2014)|2||| equal Opportunity For Workers With Disabilities (jun 2020)|2||| transportation Of Supplies By Sea (oct 2024)|2||| list Of Award Attachments|5||||x|| list Of Solicitation Attachments|5|||||| alternate A, Annual Representations And Certifications (oct 2024)|13|x|x|x|||x|x||||||| buy American-balance Of Payments Program Certificate-basic (feb 2024)|1|| annual Representations And Certifications (may 2024)|13|332991|1,250 Employees|||||||||||| type Of Contract (apr 1984)|1|firm Fixed Price| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| the Complete Rfp Package Must Be Signed And Returned Prior To The Closing Date. Emailed Proposals Are Acceptable. Neco Quotes Will Not Be Accepted And Will Be Determined Non-responsive. see Attached Irpod Revision 20230927144530, Dated 03/19/2024, For Technical Data Requirements. Notwithstanding The Inspection Terms In The Irpod, Government Source Inspection (gsi) Is Required. 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 ;the Subject Item Must Be Manufactured In Accordance With The Procurement irpod. Procurement Irpod Can Be Obtained From Contracting Officer.; 3.2 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. the Packaging Label Shall Be Marked With The Nomenclature As Cited On Irpod. date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev). date Of First Submission=045 Dac submit For Approval One Package (iaw Di-qcic-8871) Of All Applicable Procedure, Drawing And Other Pre-manufacturing Submittals, Listed On The Individual Repair Part Ordering Data (irpod) Document(s) And Detailed In The Cited Specification, Within 45 Days After contract Award To The Contracting Officer (navsup-wss Code N9433). See Irpod For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8871 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Procedure Package To Be Iaw Did Di-qcic-8871(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|iso9001| inspection Of Supplies--fixed-price (aug 1996)|2||| wide Area Workflow Payment Instructions (jan 2023)|16|tbd|tbd|tbd|n00104|tbd|tbd|23 Units To W25g1u & 24 Units To W62g2t|tbd|||tbd|||||| navy Use Of Abilityone Support Contractor - Release Of Offeror Information (3-18))|1|| equal Opportunity (sep 2016)|2||| warranty Of Data--basic (mar 2014)|2||| option For Increased Quantity--separately Priced Line Item (mar 1989)|1|365 Days After Receipt Of Order| notice Of Total Small Business Set-aside (oct 2020)(deviation 2020-o0008)|1|| list Of Solicitation Attachments|5||||x|| alternate A, Annual Representations And Certifications (oct 2024)|13|x|x|x|||x|x||||||| buy American-balance Of Payments Program Certificate-basic (feb 2024)|1|| annual Representations And Certifications (may 2024)|13|334513|750 Employees|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| amendment To Extend Solicitation Through 15 January 2025. Accelerated Delivery Is Encouraged And Accepted Before The Delivery Date(s) Listed In The Schedule. ^^ all Freight Is Fob Origin. this Rfq Is For A Buy. The Resultant Award Of This Solicitation Will Be Issued Bilaterally, Requiring The Contrctor's Written Acceptance Prior To Execution. Verify Nomenclature, Part Number, And Nsn Prior To Responding. -unit Price: __________ Firm -total Price: __________ Firm -procurement Turnaround Time (ptat): __________ -awardee Cage: __________ -inspection & Acceptance Cage, If Not At Source: __________ important Traceability Notice: If You Are Not The Manufacturer Of The Material You Are Offering, You Must Provide A Letter/official Email From The Oem Confirming Your Company Is An Authorized Distributor Of Their Items. see Attached Irpod Revision 20240222112329 Dated 03/27/2024 For Technical Data Requirements. Notwithstanding The Inspection Terms In The Irpod, Government Source Inspection (gsi) Is Required. the Government Intends To Add An Option Quantity To The Resultant Contract. In Reference To The Option Quantity, The Government May Increase The Quantity Of Supplies Called For In The Schedule At The Unit Price Specified. The Contracting Officer May Exercise The option By Written Notice To The Contractor Within The Number Of Days In Far 52.217-7 Herein. Delivery Of The Added Items Shall Continue At The Same Rate As The Like Items Called For Under The Contract, Unless The Parties Otherwise Agree. 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Manufacturing And Design - The Gage, Pressure Furnished Under This Contract/purchase Order Shall Meet The Material And Physical Requirements As Specified ;049x3 G27-351; . 3.2 ;distributors Must Obtain Item Directly From The Oem.; 3.3 ;the Subject Item Must Be Manufactured In Accordance With The Procurement irpod. Procurement Irpod Can Be Obtained From Contracting Officer.; 3.4 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|mil-i-45208, As Modified By Isr-1| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Reports (combo)|n/a|tbd|n00104|tbd|tbd|see Schedule|tbd|n/a|n/a|n/a|||||| inspection System Program Plans, Or Premanufacturing Or Test Procedures|1|45| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| alternate A, Annual Representations And Certifications (oct 2024)|13|||||||||||||| small Business Program Representations (feb 2024)|4|||x|| buy American-balance Of Payments Program Certificate-basic (feb 2024)|1|| annual Representations And Certifications (may 2024)|13|332919|750|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| a Material Irpod Is Available At The Bpmi Site. Vendor Review Of The Irpod Is Mandatory. Unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Days After The Closing Date As Indicated On The Quotation. Please Specify (if Other Than 60 Days) ______________ days. If You Are Submitting Your Quote Via Email Or Neco, Please Specify The Number Of Days Pricing Is Valid. All Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders, Delivery Orders And Modifications) Related To The Instant Procurement Are Considered To Be 'issued' By The Government When Copies Are Either Deposited In The Mail, Transmitted By Facsimile, or Sent By Other Electronic Commerce Methods, Such As Email. The Government's Acceptance Of The Contractor's Proposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 2.2 Not Releasable To Foreign Nationals (noforn) Distribution Statement - Drawings, Specification, Or Related Technical Documents As Cited In The Irpod Are Subject To Special Export Controls And Each Transmittal To Foreign Govern Ments Or Foreign Nationals May be Made Only With Prior Approval Of The Naval Sea Systems Command. 3. Requirements 3.1 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. 6.3 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. the Packaging Label Shall Be Marked With The Nomenclature Cited On The Irpod. date Of First Submission=eoc submit To Navsup-wss, Code N9433 For Review, A Complete Package Of All Applicable Vendor Certified Reports Of Test And Inspection Per Di-qcic-8872(latest Rev) See (individual Repair Parts Ordering Data) Irpod For Individual Documentsrequired. the Package Will Be Submitted Per The Contract Delivery Schedule, And Authorization To Ship Material Must Be Obtained From The Pco. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8872s Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Roti Package To Be Iaw Did Di-qcic-8872(latest Rev). date Of First Submission=045 Dac submit For Approval One Package (iaw Di-qcic-8871) Of All Applicable Procedure, Drawing And Other Pre-manufacturing Submittals, Listed On The Individual Repair Part Ordering Data (irpod) Document(s) And Detailed In The Cited Specification, Within 45 Days After contract Award To The Contracting Officer (navsup-wss Code N9433). See Irpod For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8871 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Procedure Package To Be Iaw Did Di-qcic-8871(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|iso9001| inspection Of Supplies--fixed-price (aug 1996)|2||| wide Area Workflow Payment Instructions (jan 2023)|16|tbd|tbd|tbd|n00104|tbd|tbd|8 Units To W25g1u & 7 Units To W62g2t|tbd|||tbd|tbd||||| navy Use Of Abilityone Support Contractor - Release Of Offeror Information (3-18))|1|| value Engineering (jun 2020)|3|||| equal Opportunity (sep 2016)|2||| integrity Of Unit Prices (nov 2021)|1|| equal Opportunity For Veterans (jun 2020)|4||||| warranty Of Data--basic (mar 2014)|2||| equal Opportunity For Workers With Disabilities (jun 2020)|2||| transportation Of Supplies By Sea (oct 2024)|2||| option For Increased Quantity--separately Priced Line Item (mar 1989)|1|365 Days After Receipt Of Award| list Of Solicitation Attachments|5||||x|| alternate A, Annual Representations And Certifications (oct 2024)|13|x|x|x|||x|x||||||| buy American-balance Of Payments Program Certificate-basic (feb 2024)|1|| annual Representations And Certifications (may 2024)|13|333413|500 Employees|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| this Solicitation Is Issued Pursuant To Emergency Acquisition Flexibilities (eaf). Accelerated Delivery Is Encouraged And Accepted Before The Delivery Date(s) Listed In The Schedule. ^^ all Freight Is Fob Origin. this Rfq Is For A Buy. The Resultant Award Of This Solicitation Will Be Issued Bilaterally, Requiring The Contractor's Written Acceptance Prior To Execution. Verify Nomenclature, Part Number, And Nsn Prior To Responding. o Unit Price:__________ Firm o Total Price:__________ Firm o Procurement Turnaround Time (ptat) :__________ o Awardee Cage: __________ o Inspection & Acceptance Cage, If Not At Source:__________ o Delivery Vehicle (if Delivery Order Requested) (if Your Company Has A Current Boa/idiq, For Example) :__________ important Traceability Notice: If You Are Not The Manufacturer Of The Material You Are Offering, You Must Provide A Letter/official Email From The Oem Confirming Your Company Is Authorized An Authorized Distributor Of Their Items. see Attached Irpod Revision 20231020040743, Dated 06/18/2024, For Technical Data Requirements. Notwithstanding The Inspection Terms In The Irpod, Government Source Inspection (gsi) Is Required. the Government Intends To Add An Option Quantity To The Resultant Contract. In Reference To The Option Quantity, The Government May Increase The Quantity Of Supplies Called For In The Schedule At The Unit Price Specified. The Contracting Officer May Exercise the Option By Written Notice To The Contractor Within The Number Of Days In Far 52.217-6 Herein. Delivery Of The Added Items Shall Continue At The Same Rate As The Like Items Called For Under The Contract, Unless The Parties Otherwise Agree. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 ;the Subject Item Must Be Manufactured In Accordance With The Procurement irpod. Procurement Irpod Can Be Obtained From Contracting Officer.; 3.2 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Reports (combo)|n/a|tbd|n00104|tbd|tbd|see Schedule|tbd|n/a|n/a|n/a|||||| transportation Of Supplies By Sea (jan 2023)|2||| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| notice Of Total Small Business Set-aside (oct 2020)(deviation 2020-o0008)|1|| annual Representations And Certifications (may 2024)|13|339991|600|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| there Is No Irpod Available Through Bpmi/e-commerce - Just A Drawing That Needs To Be Reviewed. All Other Terms And Conditions Remain The Same. due Date Is Extended To 08 Jan 2024. All Other Terms And Conditions Remain The Same. the Due Date Is Extended Until 07 November 2024. All Other Terms And Conditions Remain The Same. A Material Irpod Is Available At The Bpmi Site. Vendor Review Of The Irpod Is Mandatory. Unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Days After The Closing Date As Indicated On The Quotation. Please Specify (if Other Than 60 Days) ______________ Days. If You Are Submitting Your Quote Via Email Or Neco, Please Specify The number Of Days Pricing Is Valid. All Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders, Delivery Orders And Modifications) Related To The Instant Procurement Are Considered To Be 'issued' By The Government When Copies Are Either Deposited In The Mail, Transmitted By Facsimile, or Sent By Other Electronic Commerce Methods, Such As Email. The Government's Acceptance Of The Contractor's Proposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Not Releasable To Foreign Nationals (noforn) Distribution Statement - ;803-4384539; Is Subject To Special Export Controls And Each Transmittal To Foreign Governments Or Foreign Nationals May Be Made Only With Prior Approval Of The Naval Sea Systems Command. 2.2 Applicable Documents. technical Documents Associated To This Solicitation Or Award Such As; Drawings,technical Data, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At the Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To The Award. This Website Requires A Password And pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Manufacture And Design- The Gasket Furnished Under This Contract/purchase Order Shall Meet The Requirements As Specified In The Procurement Specification. The Requirements For This Contract/purchase Order Are As Follows: 1. Design, Material And Dimensions Are To Be In Accordance With a. Manufacture: ;navsea (80064); . b. Drawings: ;803-4384539; . piece: ;pc108; . revision: ;; c. Part Number: ;803-4384539pc108; . d. Catalog Number: ;; . E. Marking Requirements - Marking And Labeling Shall Be In Accordance With Mil-std-129. In Addition To The Standard Marking Requirements Of Mil-std-129, The Seller Shall Include The Manufacturer's Federal Supply Code For Manufacturers (fscm/cage Code) And The item's Part Number On Intermediate And Unit Packs. Special Marking Which Includes Both Type I And Type Ii Shelf Life Items, Cure Date And Expiration Date In Accordance With Mil-std-129 Also Apply. items Shall Be Supplied With At Least 85% Of The Shelf Life Remaining At The Time Of Shipment. Shelf-life Is ;36; Months. f. Additional Ordering Data: ;; . 3.2 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 Quality Assurance Requirements- The Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev). date Of First Submission=eoc submit At Time Of Material Delivery, A Cure Date Certificate Iaw Di-misc-81318 To Navsup-wss Code N9433. a Separate Certificate Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-misc-a81318 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Certification Package To Be Iaw Did Di-misc-81318(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|mil-i-45208| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Reports (combo) |n/a|tbd|n00104|tbd|tbd|see Schedule |tbd|n/a|n/a|n/a|||||| inspection System Program Plans, Or Premanufacturing Or Test Procedures|1|45| contractor Purchasing System Administration-basic (may 2014)|1|| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| alternate A, Annual Representations And Certifications (oct 2024)|13|||||||||||||| small Business Program Representations (feb 2024)|4|||x|| buy American-balance Of Payments Program Certificate-basic (feb 2024)|1|| annual Representations And Certifications (may 2024)|13|334513|750|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Days After The Closing Date As Indicated On The Quotation. please Specify (if Other Than 60 Days) ______________ Days.if You Are Submitting Your Quote Via Email Or Neco,please Specify The Number Of Days Pricing Is Valid. a Material Irpod Is Available At The Bpmi Website. all Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders,delivery Orders And Modifications) Related To The Instant Procurement Areconsidered To Be 'issued' By The Government When Copies Are Either Deposited In The Mail, Transmitted By Facsimile, Or sent By Other Electronic Commercemethods, Such As Email. The Government's Acceptance Of The Contractor's Proposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. 6.3 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. the Packaging Label Shall Be Marked With The Nomenclature Cited On The Irpod. date Of First Submission=eoc submit At The Time Of Material Delivery A Certificate Of Compliance Per Di-misc-81356 To Navsup-wss Code N9433. A Separate Certificate Of Compliance Shall Be Prepared And Submitted For Each Unique Combination Of Contract/purchase Order Number, National Stock number And Item Nomenclature Specified In The Schedule Of Supply/services. di-misc-a81356 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control number - Certification Package To Be Iaw Did Di-misc-81356(latest Rev). date Of First Submission=045 Dac submit For Approval One Package (iaw Di-qcic-8871) Of All Applicable Procedure, Drawing And Other Pre-manufacturing Submittals, Listed On The Individual Repair Part Ordering Data (irpod) Document(s) And Detailed In The Cited Specification, Within 45 Days After contract Award To The Contracting Officer (navsup-wss Code N9433). See Irpod For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8871 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Procedure Package To Be Iaw Did Di-qcic-8871(latest Rev).

Description: Item Unique Identification And Valuation (jan 2023)|19|||||||||||||||||||| higher-level Contract Quality Requirement (navicp Review Feb 1991)(feb 1999)|1|mil-i-45208| inspection Of Supplies--fixed-price (aug 1996)|2||| inspection And Acceptance - Short Version|8|x||x|||||| stop-work Order (aug 1989)|1|| general Information-fob-destination|1|b| wide Area Workflow Payment Instructions (jan 2023)|16|invoice And Receiving Report (combo)|n/a|tbd|n00104|tbd|tbd|see Schedule|tbd|n/a|n/a|n/a|n/a||||| inspection System Program Plans, Or Premanufacturing Or Test Procedures|1|45 Days| federal Acquisition Supply Chain Security Act Orders-prohibition (dec 2023)|12||||||||||||| notice Of Total Small Business Set-aside (oct 2020)(deviation 2020-o0008)|1|| alternate A, Annual Representations And Certifications (oct 2024)|13|||||||||||||| small Business Program Representations (feb 2024)|4||||| annual Representations And Certifications (may 2024)|13|333914|750|||||||||||| notice Of Priority Rating For National Defense, Emergency Perpardeness, And Enrgy Progam Use (april 2008))|2||x| unless Otherwise Specified, Pricing For This Quotation Is Valid For 60 Days After Theclosing Date As Indicated On The Quotation. a Material Irpod Is Available At The Bpmi Site. Vendor Review Of The Irpod Ismandatory. please Specify (if Other Than 60 Days) ______________ Days.if You Are Submitting Your Quote Via Email Or Neco,please Specify The Number Of Days Pricing Is Valid. all Contractual Documents (i.e. Contracts, Purchase Orders, Task Orders,delivery Orders And Modifications) Related To The Instant Procurement Areconsidered To Be 'issued' By The Government When Copies Are Either Depositedin The Mail, Transmitted By Facsimile, Or sent By Other Electronic Commercemethods, Such As Email. The Government's Acceptance Of The Contractor'sproposal Constitutes Bilateral Agreement To 'issue' Contractual Documents As Detailed Herein. \ 1. Scope 1.1 In The Event Of A Conflict Between Section "c" And Section "d" Of The Contract/purchase Order, Section "c" Will Take Precedence. 2. Applicable Documents 2.1 Applicable Documents; technical Documents Associated To This Solicitation Or Award Such As; Irpod, Drawings,technical Data, Strs, As Well As Certain Military Specifications, And Commercial Item Descriptions (cid) Etc. May Be Obtained At (https://logistics.unnpp.gov/ecommerce) These Documents, At The Required Revision Levels That Are Associated To Either This Solicitation Or Award, Become A Part Of This Solicitation Or Award Unless Changed By An Admendment To The Solicitation Or Modification To the Award. this Website Requires A Password And Pre-registration. To Obtain Instruction On How To Register And Obtain A Password Contact The Bpmi Website Administrator. 3. Requirements 3.1 Navsup Wss-mech Code N94 Additional Technical Documentation order Of Precedence And Effective Issues Of Cited Documentation Dated: July 2004 a. Order Of Precedence For Document Conflict Resolution: The Technical And Quality Requirements Applicable To Manufacture Of The Material Being Purchased Under This Order Are Contained Or Invoked In One Or More Of The Documents Listed Below. In The Event Of any Inconsistencies Between Any Provisions Of This Order, The Order Or Precedence Shall Be As Follows: 1. Amendments To The Purchase Order/contract 2. Schedule Of Supplies Of The Purchase Order/contract. 3. Terms And Conditions Of The Purchase Order/contract. 4. Individual Repair Part Ordering Data (irpod); Or Master Procurement Specification, As Applicable. 5. Any Invoked Standard Technical Requirements (strs). 6. Drawings Referenced In The Irpod, Or Master Procurement Specification , As Applicable. 7. Specifications Referenced In The Irpod, Master Procurement Specifications Or Drawing(s), As Applicable. b. Effective Issues Of Cited Drawings, Specifications, Standards And Other Documents: 1. The Contractor Shall Comply With The Specified Revisions Of The Documents (i.e. Drawings,specifications,standards And Other Documents) Cited In The Irpod And/or Procurement Specification Contained Herein. The Contractor Shall Obtain Written Approval for The Contracting Officer To Use Document Revisions Other Than Those Specified. When A Later Drawing Revision Is Submitted For Approval, Two Full Size Clear Legible Prints Shall Be Provided. 2. Where Documents Are Referred To Only By The Basic Identification Name Or Number And No Specific Revision Thereto, The Contractor Use Of Any Issue Of The Document Except All Such Revisions Shall Be Dated 1 November 1969 Or Later. c. Use Of Document Revisions In Their Entirety: 1. Contractors Shall Use Revisions To Each Cited Or Referenced Document In Its Entirety Unless The Contractor Obtains Contracting Officer Approval To Do Otherwise (i.e. The Contractor Shall Not Use Portions Of Different Revisions Of A Document). d. Vendor Waiver/deviations On Critical Contracts. 1. Compliance With The Delivery Date And Technical Requirements Of Navsup Wss Critical Repair Part Material Contracts Is Expected. 2. As The Cautionary Note Contained In The Contract States, Seller Intended Use Of Any Material Which Is Not In Full Compliance With The Specified Contract Technical Requirements, Should Be Identified As An Exception In Advance Either At The Time The Quotation is Submitted Or Prior To Manufacture. 3. Requests For Delivery Date Extensions And Waivers/deviations Should Be Accompanied By An Explanation Of The Cause For The Delay, Or The Reason For The Requested Non-conformance With An Offer Of Consideration In The Event The Contracting Officer Concurs With your Request. 4. Requests For Waivers/deviations Should Provide Justification For The Requested Change Including An Evaluation Which Demonstrates That Proposed Non-conformance Will Not Affect The Quality, Form, Fit, Or Function Of The Part. Where A Proposed Alternate Or replacement Item Is Offered, Supporting Technical Data (catalog Page, Drawing (s), Etc.) That Fully Describe The Proposed Item Shall Be Provided For Technical Evaluation. 5. Requests Which Do Not Contain The Above Information Will Be Returned And Will Not Be Submitted To Technical/engineering Review Until Sufficient Justification Is Provided. 6. Requests For Waivers/deviations Shall Be Presented To The Government Quality Assurance Representative (qar) For Comment. The Qar Shall Forward The Request, With Their Comments, Directly To The Post Award Pco Identified In The Contract/purchase Order Within five Working Days After Receipt. e. Exclusion Of Mercury 1. Mercury Or Mercury Containing Compounds Shall Not Be Intentionally Added To Or Come In Direct Contact With Hardware Or Supplies Under This Contract. 4. Quality Assurance 4.1 The Quality Assurance Requirements Are Located In The Individual Repair Part Ordering Data (irpod). the Contractor Shall Provide And Maintain An Inspection System Acceptable To The Government Covering The Supplies Herein. records Of All Inspection Work By The Contractor Shall Be Kept Complete And Available To The Government During The Performance Of This Contract And For Such Longer Periods As May Be Specified Elsewhere In The Contract. 5. Packaging 5.1 When The Cleanliness Control Requirements Of One Or More Of The Following Documents Are Invoked: Mil-std-767, Mil-std-2041, Refueling Clean, Or Reactor Plant Clean, The Following Clarification Of Requirements For Mil-prf-23199 Packaging Of Repair Parts applies. (1). The Following Summary Clarifies The Packaging Requirements Of Mil-prf-23199 Pertaining To The Use Of Mil-dtl-24466 Green Poly Bags. The Supplier Remains Responsible For Meeting All Contract Requirements. Suppliers Who Are Unsure Of The Packaging, Packing, and Marking. requirements For A Particular Part Should Request Clarification By Contacting The Navsup-wss Contracting Poc. (a). Paragraph 3.4.2 Of Mil-prf-23199 Discusses Level B Packaging And Refers To Paragraph 3.3.1 For The Method Of Packaging. Paragraph 3.3.1 Provides Several Methods Of Packaging. Packaging In Heat Sealed Envelopes Is Covered In Paragraph 3.3.1.1 Which States, "components Which Are Subject To Cleanliness Controls (see 6.2) Or As Specified (see 6.1) Shall Be Packaged In Heat Sealed Envelopes (see 3.2.2.5 And 3.2.2.5.1)". (2). The Following Conditions Must Be Satisfied In Order For Mil-dtl-24466 Bags To Apply: (a). Paragraph 6.2 Of Mil-prf-23199 Defines Cleanliness Controls As Any Reference To (or Application Of) The Cleanliness Control Requirements Of One Or More Of The Following Documents: Mil-std-767, Mil-std-2041, Refueling Clean, Reactor Plant Clean, Or Other requirements Identified Within The Irpod. the Repair Part Must Have Cleaning Requirements Of One Of The Aformentioned Methods. (b). Paragraph 6.1 Contains Ordering Data Options. Paragraph 6.1(k)2. Provides An Option To Specify The Method Of Packaging To Be Used When Packaging Is Other Than In Accordance With Paragraph 3.3.1.1 Only. If A Contract Specifies Any Additional Requirements for The Use Of Green Poly Bags, Then They Are Required And Take Precedence. (4). The Use Of Fire Retardant Packaging Material Is No Longer Required In Any Navsup-wss N94 Contract. mil-std 2073 Packaging Applies As Found Elsewhere In The Schedule 6. Notes 6.1 1. Nuclear Reactor Publications Assigned Navsea Document And Identification Numbers That Are Not Available From Bpmi E-commerce Web Site Must Be Requested From: contracting Officer navsup Wss-mech code N943 5450 Carlisle Pike p.o. Box 2020 mechanicsburg, Pa. 17055-0788 requests For "official Use Only" And "noforn" (not Releasable To Foreign Natio Nals) Documents Must Identify The Quotation Number On Pre-award Procurement Actions. Requests Must Be Submitted To The Pco For Certification Of "need-to-know" For The Document. On post-award Actions, The Request Must Identify The Government Contract Number, And Be Submitted Via The Defense Contract Management Agency (dcma) For Certification Of "need-to-know" For The Document. 2. Commercial Specifications, Standards And Descriptions - These Specifications, Standards And Descriptions Are Not Available From Government Sources. They May Be Obtained From The Publishers Or Societies Of The Applicable Documents. 6.2 Information Regarding Abbreviations, Symbols And Codes Appearing On Dd Form 1423 - The Following Information Is Provided To Assist In Understanding The Intent Of The Requirement To Provide A Deliverable Item To The Government. The Explanation Of abbreviation, Symbols And Codes Found In A Block Follows The Block Number As They Appear On The Dd Form 1423. block A: Is The Actual Contract Line Item No. block B: Is The Actual Collective Physical List Of The Deliverable Item(s) Which Are Part Of The Total Requirement Of The Contract/purchase Order. block C: Is The Category Of Data Required, Tdp Is Defined In Mil-t-31000. Tm Is Defined In Part 1x, Section B Of Dodi 5000.2. Navsup-wss Has Reasoned That Most Dd Form 1423's Included In Our Solicitations Meet The Requirement Of Tdp As Navsup-wss Does Not Regularly Purchase Only Technical Manuals Without Purchasing Hardware And Related Tdp Software. Therefore, Most Navsup-wss Dd Form 1423 Category Code Will Be Tdp. block D: Is The Name Of The Parent System, Next Higher Assembly, Or The Item Being Purchased. block E: Is The Purchase Request Number, Request For Proposal Number, Invitation For Bid Number Or Another Number For Tracking And Monitoring Purposes. block F: Is The Successful Offerors Name And Or Cage Code. block G: Is The Name Of The Individual And Or The Code/activity Of The Individual Who Prepared The Dd Form 1423 And Included The Requirement In The Technical Data Package (tdp). block H: Self Explanatory. block I: Is The Name And Signature Of The Individual Who Approved The Content And The Need For Inclusion Of The Dd Form 1423 In The Tdp. block J: Self Explanatory. block 1: Is The Exhibit Line Item Number (elin). block 2: Is The Title Of The Data Item Cited In Block 4. block 3: Is The Subtitle Of The Data Item Cited In Block 4 And Is Used If The Title Requires Clarification. block 4: Is The Actual Data Item Description (did) Number Or The Actual Technical Manual Contract Requirements Number. In The Event The Dd Form 1423 Is Requiring A Technical Manual The Numbered Tmcr Will Be An Attachment To The Contract/purchase Order. block 5: Is The Section And Paragraph Area, Where The Requirement Statement For The Dd Form 1423 Will Be Found. block 6: Is The Activity That Will Inform The Contractor Of Approval, Conditional Approval Or Disapproval Of The Deliverable Item. block 7: Is A Code Which Designates Authority For Inspection And Acceptance Of The Deliverable Item. The Definition Of The Codes Is As Follows: Dd Form 250 Code Inspection Acceptance Ss (1) (2) Dd (3) (4) Sd (1) (4) Ds (3) (5) Lt (6) (7) No (8) (8) Xx (9) (9) (1) Inspection At Source. (2) Acceptance At Source. (3) No Inspection Performed At Source. Final Inspection Performance At Destination. (4) Acceptance At Destination. (5) Acceptance At Source. Acceptance Based On Written Approval From The Contract Officer. (6) Letter Of Transmittal Only. Lt Should Not Be Used When Inspection Is Required. The Data Is Sent By The Contractor Directly To The Personnel Listed In Block 14 Of The Dd Form 1423. Lt Is Used When The Contracting Agency Does Not Desire To Have A Dd Form 250 For Each And Every Piece Of Data Developed By The Contractor. The Only Other Authorized Use Of Lt Is The Special Case Where The Contracting Agency Does Not Desire To Have Separate Dd Forms 250 But Desires To Have A Government Quality Assurance Representative Perform Inspection. The Government Quality Assurance Representative Shall Be Listed On The Distribution In Block 14 And Requested To Provide Comments Via The Quality Assurance Letter Of Inspection. Use Of The Symbol Lt Is Not Authorized For Data Comprising Final Delivery Of Technical Data Package Of For Technical Manuals. (lt May, However, Be Used For Delivery Of Preliminary Tdp's Or Tm's). (7) As Specified In Block 8 Of The Dd Form 1423. (8) No Inspection Or Acceptance Required. No Dd Form 250 Or Letter Of Transmittal Required. Use Of The Symbol No Is Not Authorized For Data Comprising Technical Data Packages Or For Technical Manuals. (9) Inspection And Acceptance Requirements Specified Elsewhere In The Contract. block 8: Is The Approval Code - Items Of Critical Data Requiring Specific Advanced Written Approval Prior To Distribution Of The Final Data Item Will Be Identified By Placing An "a" In This Field. This Data Item Requires Submission Of A Preliminary Draft Prior To Publication Of A Final Document. When A Preliminary Draft Is Required, Block 16 Of The Dd Form 1423 Will Show Length Of Time Required For Government Approval/disapproval And Subsequent Turn-around Time For The Contractor To Resubmit The Data After Government Approval/disapproval Has Been Issued. Block 16 Will Also Indicate The Extent Of The Approval Requirements, E.g., Approval Of Technical Content And/or Format. block 9: Is The Distribution Statement Code Which Explains How The Government Can Circulate The Deliverable Item. The Definition Of Codes A, B, C, D, E, Or F Is As Follows: A. Distribution Of The Item Is Unrestricted. B. Distribution Of The Item Is Limited To Agencies Only. C. Distribution Of The Item Is Limited To Contractors With A Cage Code And Have A Dd Form 2345 On File With The Dla Logistics Information Services (dlis) Battle Creek, Mich. Or Government Activities. D. Distribution Of The Item Is Limited To Dod Activities And Dod Contractors Only. E. Distribution Of The Item Is Limited To Dod Components Only. F. Distribution Of The Item Is Restricted From Foreign Nations And Foreign Nationals. block 10: Is The Frequency Which The Deliverable Item Is Expected To Be Delivered To The Government. The Abbreviations And Their Meaning. Annly Annually Asgen As Generated Asreq As Required Bi-mo Every Two Months Bi-we Every Two Weeks Daily Daily Dfdel Deferred Delivery Mthly Monthly One/r One Time With Revisions Qrtly Quarterly Semia Every Six Months Wekly Weekly Xtime Number Of Times To Be Submitted (1time, 2times...9times) Use Of These Codes Requires Further Explanation In Block 16 To Provide The Contractor With Guidance Necessary To Accurately Price The Deliverable Data Item. Other Abbreviations Not Appearing On The Above List May On Occasion Be Used In Block 10 Of The Dd Form 1423. When Other Abbreviations Are Used They Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 11: Is The Last Calendar Date, Expressed In Year/month/day Format, The Deliverable Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423 For An Item With A Block 10 Entry Indication A Single Delivery. If The Item Is To Be Submitted Multiple Times, The Number Stated Is The Number Of Calendar Days After The Frequency Cited In Block 10 The Item Is To Be Received By The Requiring Office Cited In Block 6 Of The Dd Form 1423. On Occasion The Deliverable Item Will Be Required To Be Submitted Prior To The End Of The Frequency Cited In Block 6. In That Event The Requirement Will Be Fully Explained In Block 16 Of The Dd Form 1423. block 12: Is The Date Of First Submission Of The Deliverable Item To The Requiring Office (block 4) Expressed In Year/month/day Format. The Abbreviations And Their Meaning Are As Follows: Asgen As Generated Asreq As Required Dac Days After Contract Date Dfdel Deferred Delivery Eoc End Of Contract Eom End Of Month Eoq End Of Quarter Specific Instructions For These Requirements Will Be Provided In Block 16. If The Deliverable Item Is Constrained By A Specific Event Or Milestone The Constraint Will Be Fully Explained In Block 16 Of The Dd Form 1423. "as Generated", "as Required", And "deferred Delivery" Will Always Be Fully Explained In Block 16. block 13: Is The Date Of Subsequent Submission Of The Deliverable Item, After The Initial Submission. Subsequent Submission Is Only Used To Indicate The Specific Time Period. The Data Is Required When Block 10 Of The Dd Form 1423 Indicates Multiple Delivery Is Required. This Does Not Apply To Resubmission Of A Deliverable Item That Has Been Reviewed By The Requiring Office And Determined To Be Only Conditionally Acceptable Or Unacceptable. block 14a: Will Contain The Activity Name(s) Where The Deliverable Item Is To Be Sent. If The Activity Is Other Than Dcma Or Navsup-wss The Full Name, Address (including Code) Will Be Specified. That Specific Information Will Be Located In Block 16 Of The Dd Form 1423. block 14b: Is The Number Of Copies Of Draft And Or Final Copies To Be Submitted. When Final "repro" Copies Are To Be Submitted Block 16 Will Clarify The Type Of Repro Copies Required. (e.g., Vellum, Negative, Etc.) block 15: Is The Total Of Each Type Of Copies To Be Submitted As Required By Block 14. block 16: Is The Block Used To Provide Additional Or Clarifying Information Blocks 1 Through 15. This Block Is Also The Only Area Used To Tailor The Document Listed In Block 4. Only Deletions To The Minimum Requirements Stated In The Document In Block 4 Are Allowed. Block 16 May Also Be Used To Specify The Medium For Delivery Of The Data. block 17: Is The Block Where The Bidder Or Offeror Is To Enter The Appropriate Price Group. The Price Groups Are Defined As Follows: A. Group I - Data Which The Contractor Prepares To Satisfy The Government's Requirements. The Contractor Does Not Need This Type Of Data To Perform The Rest Of The Contract. Price Would Be Based On Identifiable Direct Costs, Overhead, General And Administrative (g&a) And Profit. B. Group Ii - Data Essential To Contract Performance Which Must Be Reworked Or Amended To Conform To Government Requirements. The Price For Data In This Group Would Be Based On The Direct Cost To Convert The Original Data To Meet Government Needs And To Deliver It, Plus Allocable Overhead, G&a And Profit. C. Group Iii - Data Which The Contractor Must Develop For His Own Use And Which Requires No Substantial Change To Conform To Government Requirements Regarding Depth Of Content, Format, Frequency Of Submittal, Preparation, And Quality Of Data. Only The Costs Of Reproducing, Handling And Delivery, Plus Overhead, G&a And Profit, Are Considered In Pricing Data In This Group. D. Group Iv - Data Which The Contractor Has Developed As Part Of His Commercial Business. Not Much Of This Data Is Required And The Cost Is Insignificant. The Item Should Normally Be Coded "no Charge." An Example Is A Brochure Or Brief Manual Developed For Commercial Application Which Will Be Acquired In Small Quantities, And The Added Cost Is Too Small To Justify The Expense Of Computing The Charge That Otherwise Would Go With The Acquisition. block 18: Enter The Total Estimated Price Equal To That Portion Of The Total Price Which Is Estimated To Be Attributable To The Production Or Development For The Government Of That Item Of Data. The Entry "n/c" For "no Charge" Is Acceptable. 6.3 In Accordance With Dodi 5230.24 All Documents And Drawings Provided By The U.s. Navy To Prospective Contractors Must Include A "distribution Statement" To Inform The Contractor Of The Limits Of Distribution, And The Safeguarding Of The Information contained On Those Documents And Drawings. There Are 6 (six) Separate Distribution Statement Codes Used For Non-classified Documents And Drawings. The Definition For Each Is As Follows: a... Approved For Public Release; Distribution Is Unlimited. b... Distribution Authorized To Us Governments Agencies Only. c... Distribution Authorized To Us Government Agencies And Their Contractors. d... Distribution Authorized To Dod And Dod Contractors Only. e... Distribution Authorized To Dod Components Only. f... Further Distribution Only As Directed By Commander, Naval Sea Systems Command, Code 09t. mark The Packaging Label With The Nomenclature Cited On The Irpod.zz= Package And Packing Iaw Irpod; Mil-prf-23199 date Of First Submission=eoc submit To Navsup-wss, Code N9433 For Review, A Complete Package Of All Applicable Vendor Certified Reports Of Test And Inspection Per Di-qcic-8872(latest Rev) See (individual Repair Parts Ordering Data) Irpod For Individual Documentsrequired. the Package Will Be Submitted Per The Contract Delivery Schedule, And Authorization To Ship Material Must Be Obtained From The Pco. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8872s Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Roti Package To Be Iaw Did Di-qcic-8872(latest Rev). date Of First Submission=045 Dac submit For Approval One Package (iaw Di-qcic-8871) Of All Applicable Procedure, Drawing And Other Pre-manufacturing Submittals, Listed On The Individual Repair Part Ordering Data (irpod) Document(s) And Detailed In The Cited Specification, Within 45 Days After contract Award To The Contracting Officer (navsup-wss Code N9433). See Irpod For Individual Documents Required. a Separate Package Will Be Prepared And Submitted For Each Unique Combination Of Contract Number, National Stock Number, And Item Nomenclature Specified In The Schedule Of Supplies/services. di-qcic-a8871 Cited In Block 4 Is A Unique Navsup-wss Dd1423 Sequence Control Number - Procedure Package To Be Iaw Did Di-qcic-8871(latest Rev).