City Of Kitchener Tender

This request For Quotations (the “rfq”) Is An invitation By The Corporation Of The City Of Kitchener (“the City”) To Prospective Respondents To Submit Non-binding Quotations For Supply And Installation Of Play Equipment At Carlyle, Glendale, And Mausser Park, As Further Described In Section A Of The Rfq Particulars (appendix D) (the “deliverables”).  The City Of Kitchener Is Looking To Partner For The Design, Supply And Installation Of Play Equipment At Three (3) Parks:  Carlyle, Glendale, And Mausser Park In Kitchener, Ontario. The Overall Construction Of The Three Parks Will Be Completed By A General Contractor And The Successful Playground Respondent Will Contract Directly With The Constructor, Executing Their Subcontract Stipulated Price Agreement, With A Targeted Completion Date Of Glendale And Mausser Park Of December 2024 and June 2025 For Carlyle Park.