Architect Tenders

Details: This Is A Sources Sought Notice. No Proposals Are Being Requested Or Will Be Accepted In Response To This Posting. If You Are Interested In Proposing On The General Scope Of Work Stated Below For A Design-build Project, Please Respond By Email Only To Krista.miller@gsa.gov. Please Provide Your Bonding Capacity, A Capability Statement, And Your Small Business And Small Business Socioeconomic Status, If Any. Please Include In Your Capability Statement Projects Which Your Firm Has Completed That Are Particularly Relevant To This Scope Of Work, Especially Involving Exterior Structural And Glazing Improvements, And/or Performed In Hawaii. general Statement Of Work Summary: the Prince Jonah Kuhio Kalaniana’ole (pjkk) Federal Building And Courthouse Is Located At 300 ala Moana Blvd., Honolulu, Within The Hawaii Capital District And On The Outskirts Of The Downtown central Business District. This Reinforced, Cast In Place Concrete With Concrete Masonry And Glass curtain Walls Is A Two-building Mid-century Modern Complex Originally Constructed In 1977. The illuminated Entry Pavilion Was Originally Designed By Gensler Sf And Constructed By Swinerton construction In January 2015. The Illuminated Entry Pavilion Design Was An Elegant, Iconic Aia award Winning Design That Unified Two Separate Entries Into A Single, Sky Lighted And Transparent entrance For The Pjkk Complex. The Single Portal/pavilion Simplified The Circulation For The Public and Created A Strong Sense Of Entry For Pjkk. on April 6, 2021 A Fire Occurred At The Entry Pavilion That Created Significant Damage. On January 24, 2022, Clifford Planning Architecture Completed A Fire Investigation Report That Stated “it Is probable The Entry Pavilion Fire Initiated Was A Result Of An Electrical Fault Within The Led Light Panel installed Adjacent To The Bottom Panel Of The South Wall Of The Entry Pavilion. Low Level Arcing Over a Period Of Time Was The Likely Source Of Heat For Ignition Of The Acrylic Panel Material” (see volume 4 – Fire Investigation). As Further Defined In The Fire Investigation Report, There Was Fire damage To Architectural Finishes And Structural Members. The Scope Of Work For The Entry Pavilion includes, But Is Not Limited To, Installing (2) Temporary Covered Entry Tunnels To The Existing United states Marshal Service (usms) And Federal Protection Services (fps) Security Check-point locations, Providing Code Compliant Construction Documents And Full Design Services That Adhere to The Original Gensler Design And Architectural Appearance Of The Original Entry Pavilion, While also Making The Necessary Design Changes To Address The Issues That Contributed To The Fire And smoke Damage As Further Defined In Volume 4 - Fire Investigation. The Design Should Also include Solutions For The Following Known Building Maintenance Issues: 1. The Original Design Led Panels Were Located Behind Heavy Glass Panels That Created issues For Regular Maintenance And Care. 2. The Original Designed Entry Door Operated On A Small Pin That Would Fail And Was Difficult to Replace. in Addition To The Scope Above, The Design And Construction Of The Courthouse Hardening Upgrades To The entry Pavilion And Ground Level Windows And Doors Facing Halekauwila Street And Ala Moana Boulevard are A Requirement For This Project. The Judiciary Had Previously Sought From Congress Supplemental appropriations To Fund Enhanced Security Measures To Protect Judges And The Judicial Process In Response to The Civil Unrest Following The Murder Of George Floyd And The January 6th Attack On The U.s. Capitol. the Judicial Conference Approved Funding To Begin Enhanced Security Measure Projects To Harden courthouses. initial Stakeholders From The General Services Administration (gsa), The Administrative Office Of The U.s. courts (ao), U.s Marshals Service (usms), And The Federal Protective Service (fps) Worked Together To analyze Potential Security Measures To Be Used In This Program. This Scope Of Work Covers The countermeasures For The Pjkk Courthouse In Honolulu, Hi: 1. Windows: Impact Resistant Window Glazing System At The Entry Pavilion And ground Level Courthouse Windows And Doors Facing Halekauwila Street And Ala moana Boulevard, Excluding Ground Level Windows Along The United States marshal Service Offices And Within The Confines Of The Exterior Secured Courtyard: ● Windows / Doors / Frames – Shall Meet A Minimum 15-minute Forced entry Resistance Per Astm F3038 Or Dept Of State (dos) sd-std.01.01 Rev G (amended) – Forced Entry Resistance Is The standard That Shall Apply. ● The Contractor Shall Install A New Shatter Break Resistance Riot Glazing system ● Contractor Is Responsible To Field Verify And Measure Each Opening. 2. Exterior Doors And Hardware (see Volume 2b_existing Pavilion Design drawings For Specific Locations): ● All Exterior Pavilion Entry Doors And Interior Courthouse Pavilion Vestibule doors Shall Be Equipped With Hardware And Controls To Engage electro-magnetic And/or Electro-mechanical Remote Locks. ● Remote Locks Shall Give The Ability For The Court Security Officers And The usms To Lock All Doors Immediately In Case Of An Emergency. ● Remote Lock Override Control Shall Run To The Main Usms / Cso Control room the Courthouse Hardening Upgrades Will Upgrade The Ground Level Courthouse Windows And doors And Replace All Window, Exterior Doors, And Hardware Included In The Original Gensler designed Pjkk Entry Pavilion. the Forced Entry Resistance Doors And Windows Shall Meet A Minimum 15 Minute Forced Entry resistance In Accordance With Astm Standard F3038-21, With The Following Exception. Astm standard F3038-21 Requires A Full Scale Test For Each Unique System Size And Configuration, however, If The Actual Overall System Dimensions Are Within 6” (both Height And Width Dimension) of Another Successfully Tested System Meeting The Requirements Of Astm Standard 3038-21, And the System Components Are Of Similar Size And Makeup, The Proposed System Shall Be Considered acceptable. Support Documentation Shall Be Provided Prior To Installation. the Construction Services Scope Of Work Includes Demolition Of The Remaining Pavilion Structure, build-out Of (2) Temporary Tunnels To Access The Existing Usms And Fps Security Check-points, the Build-out Of The New Entry Pavilion, Installation Of The Courthouse Hardening Window And Door upgrades, Including But Not Limited To Structural, Architectural Finishes, Lighting, Mechanical, electrical, Plumbing, Fire And Life Safety, And Data/cabling Infrastructure. the Federal Building And Courthouse Must Remain Fully Operational Throughout Design And construction. All Construction Work Related To This Project Shall Be Scheduled From 5:00 Pm To 7:00 am, After Normal Building Operation Hours To Minimize Disruptions To Building Occupants And To maintain Public Safety. Normal Building Operation Hours Are From 7:00 A.m. To 5:00 P.m. weekdays. the Project Delivery Method Is Design-build (db). the Db Contractor Shall Provide All Supervision, Labor, Materials, Equipment, And Testing Required to Accomplish The Design And Construction For The Pjkk Entry Pavilion And Courthouse Hardening project. design Services Shall Include, But Are Not Limited To, Design And Certification By A State Of Hawaii licensed Architect-engineer (a/e), Design Reviews, Weekly Progress Meetings, Design development, Construction Documents, Basis Of Design Documents, Site Investigation, Site measurements And Verification, Code Compliance, Reproduction Services, Consultant Coordination, contract Administration, Contract Close-out, Record Drawings And As-builts. construction Services Shall Include, But Are Not Limited To, Complete And Timely Submission Of security Clearance Applications For Workers (hspd-12 And Tenant Agency Review), Project schedule, Cost Estimating, 3-week Look Ahead Schedules, Demolition, Site Supervision, Drywall, mechanical, Electrical, Automatic Sprinkler System, Architectural Finishes, Submittal Samples, submittal Schedule, Hvac, System Balancing, Structural, Fire And Life Safety, Security Infrastructure, protocols For Utility Outages, Separation Of Utilities To Avoid Impacts To Occupied Areas, Temporary barricade Plan, Noise Mitigation, Clean Up After Work, Lead Weekly Meetings And Provide Minutes, file And Record Management, And All Other Work To Meet The Contract Requirements.

Details: Synopsis: introduction: in Accordance With Federal Acquisition Regulation (far) 10.002(b)(2), This Sources Sought Notice Is For Market Research And Information Purposes Only At This Time And Shall Not Be Construed As A Solicitation Or As An Obligation On The Part Of The Department Of Veterans Affairs (va). the Department Of Veterans Affairs, Veterans Health Administration (vha), Program Contracting Activity Central (pcac) Is Conducting A Market Survey And Is Seeking Potential Sources For Project 562-22-700, Construct Ehrm Infrastructure Upgrades At The Erie Va Medical Center (vamc) Located In Erie, Pennsylvania. project Description: the Erie Vamc Is Seeking A General Contractor To Provide All Necessary Tools, Labor, Materials, Equipment, Permits, License, Supervision, And Quality Control For Ehrm Infrastructure Upgrades Erie, Pa At The Erie Va Medical Center, In Accordance With The Drawings And Specifications. Work Includes General Construction, Alterations, Grading, And The Following Infrastructure Improvements: Electrical Power (normal And Emergency); Bonding; Ups; Building Management System (bms) Interfaces; New And Upgrades Of Existing Hvac; Reconfiguration, Expansion, And Renovation Of Existing Spaces; Communication Infrastructure; Physical Security Upgrades; Upgrade Of Fiber Infrastructure Backbone Campus-wide, Within Buildings And Between Buildings; Construct New Data Center; Hazardous Material Abatement And All Necessary Removal Of Existing Structures And Construction Of Certain Other Items. the Upgrade To The Infrastructure Will Include Campus Wide New Campus Wide Fiber Backbone Underground Routing And Will Require Excavation, Trenching, Reinforced Concrete Duct Bank With Associated Access Points. Campus Buildings Impacted By The Upgrades Include Buildings 1, 6, 7, 8, 11, 14, And 18. Upgrades In These Buildings Will Include Existing Rooms And Telecommunications Closets And Include Relocation, Reconfiguration, Expansion, And Renovation Involving New Walls, Doors And Finishes, Etc. Throughout Each Space. construction Shall Comply With Va Infrastructure Standard For Telecommunications Spaces (ists) V4.0, June 1, 2023. New Data Center To Include Electrical Distribution, Cable Management, Data Cabinets, Finishes And Hvac. The Data Center Is Designed For And Meeting The Requirements Of A Small/medium Campus Support Center. The Data Center Shall Be Constructed To Withstand Blast Protection Requirements Per The Va Psrdm. procurement Information: the Proposed Project Will Be A Competitive, Firm-fixed-price Contract Utilizing The Design-bid-build Approach (final Specifications And Drawings Will Be Provided). The Anticipated Solicitation Will Be Issued Either As A Request For Proposal (rfp) In Accordance With Far Part 15, Considering Technical And Price Factors Or As An Invitation For Bid (ifb) In Accordance With Far Part 14, Considering Price Only. The Results And Analysis Of The Market Research Will Finalize The Determination Of The Procurement Method. The Type Of Socio-economic Set-aside, If Any, Will Depend Upon The Responses To This Notice And Any Other Information Gathered During The Market Research Process. this Project Is Planned For Advertising In March, 2025. In Accordance With Vaar 836.204, The Magnitude Of Construction Is Between $20,000,000.00 And $50,000,000.00. The North American Industry Classification System (naics) Code 236220 (size Standard $45.0 Million) Applies To This Procurement. The Duration Of The Project Is Currently Estimated At 540 Calendar Days From The Issuance Of A Notice To Proceed. The Services For This Project Will Include Providing All Construction Related Services Such As: Providing Tools, Labor, Materials, Equipment, Permits, Licenses, Supervision, And Quality Control Required To Complete The Project As Per Contract Documents Prepared By An Independent Architect-engineer Firm. capability Statement: respondents Shall Provide A General Capabilities Statement To Include The Following Information: section 1: Provide Company Name, Duns Number And Unique Entity Identifier (uei), Company Address, Point-of-contact Name, Phone Number And Email. section 2: Provide Company Business Size Based On Naics Code 236220. Also, Provide Business Type (i.e., Large Business, Small Business, Service-disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-owned Small Business, Hub Zone Small Business, Etc.). section 3: Provide A Statement Of Interest In The Project. Please State Your Intent To Submit A Bid On This Project If The Only Evaluation Factor Is Price (far Part 14). Please Also State Your Intent To Submit A Proposal If The Solicitation Contains Both Price And Non-price Evaluation Factor (far 15). section 4: Provide The Prime Contractor S Available Bonding Capacity In The Form Of A Letter Of Intent From Your Bonding Company With This Submission. *please Ensure That The Individual Bonding Capacity Is In Line With The Vaar Magnitude Of Construction Listed Above. Letter Should Include Single Award Limit, Aggregate Limit And Available Bonding Capacity. section 5: Provide The Type Of Work Your Company Has Performed In The Past In Support Of The Same Or Similar Requirement. This Section Is Important As It Will Help To Determine The Type Of Socio-economic Set-aside, If Any. Please Provide The Following In Your Response: no More Than Three (3) Contracts That Your Company Has Performed Within The Last Six (6) Years That Are Of Comparable Size, Complexity, And Scope To This Requirement. Include The Project Name, Project Owner And Contact Information As This Person May Be Contacted For Further Information, Project Scope, Project Size (example: Square Footage), Building Use (example: Medical Facility, Office Building, Etc.), Project Dollar Value, Start And Completion Dates. provide Specific Examples That Relate Aspects Of Previous Projects To The Proposed Project. Describe Specific Technical Skills And Key Personnel Your Company Possess To Perform The Requirements Described Under Description Of Work. describe Your Self-performed** Effort (as Either A Prime Or Subcontractor). Describe Self-performed Work In Terms Of Dollar Value And Description. **self-performed Means Work Performed By The Offeror Themselves, Not Work Performed By Another Company For Them For Any Of The Project Examples Provided. it Is Requested That Interested Contractors Submit A Response (electronic Submission) Of No More Than Eight (8) Single Sided Pages, Single-spaced, 12-point Font Minimum That Addresses The Above Information. This Response Must Be Submitted As A Single Application-generated (not Scanned) Pdf Document That Is Less Than Or Equal To 4mb In Size. Please Note That Hard Copies Will Not Be Accepted. Please Also Include A Cover Page, Which Includes, At A Minimum: The Company S Name, Address, Unique Entity Identifier (if Available), Socio-economic Status, Point-of-contact Name, Phone Number, And E-mail Address. Responses Must Include The Sources Sought Number And Project Title In The Subject Line Of Their E-mail Response. Submissions (responses) Shall Be Submitted Via Email To The Primary And Secondary Points Of Contact Listed Below By January 15, 2025 At 1:00 Pm Et. No Phone Calls Will Be Accepted. the Capabilities Statement Submitted In Response To This Sources Sought Shall Not Be Considered To Be A Bid Or Proposal. This Notice Is For Information And Planning Purposes Only And Is Neither To Be Construed As A Commitment By The Government Nor Will The Government Pay For Information Solicited. No Evaluation Letters And/or Results Will Be Issued To The Respondents. After Completing Its Analyses, The Government Will Determine Whether To Limit Competition Among The Small Business Categories Listed Above Or Proceed With Full And Open Competition As Other Than Small Business. at This Time No Solicitation Exists; Therefore, Please Do Not Request A Copy Of The Solicitation. If A Solicitation Is Released It Will Be Synopsized In Contract Opportunities At Https://sam.gov/. It Is The Potential Offeror's Responsibility To Monitor This Site For The Release Of Any Solicitation Or Synopsis. contracting Office Address: vha Program Contracting Activity Central (vha-pcac) 6100 Oak Tree Blvd. Suite 490 independence, Oh 44131 primary Point Of Contact: leslie Prather contract Specialist leslie.prather@va.gov secondary Point Of Contact: samantha Mihaila contracting Officer samantha.mihaila@va.gov

Details: The Subject Of The Design Competition Will Be The Comprehensive Architectural Design Of The New Building Of The Alšova South Bohemian Gallery Museum On Senovážné Square In České Budějovice. The Selected Architect/general Designer Team Will Subsequently Process All Project Phases Of The Investment Plan. The Purpose Of This Preliminary Notice Is To Survey The Market Regarding The Interest Of Potential Suppliers In The Proposal Competition. More Detailed Information On The Market Research Is Published On The Profile Of The Client. This Is Not A Preliminary Market Consultation. Publication Of The Preliminary Information Notice Does Not Initiate The Design Competition; The Contest Will Be Initiated With The Announcement Of The Contest Commencement..

Details: Synopsis: project Title: pre-solicitation Notice For Project 657-24-111jc Renovate Ambassador Suite & Main Lobby, Building 1, Saint Louis Va Medical Center John Cochran Division, Saint Louis, Mo. contract Information a. This A/e Services Requirement Is Being Procured In Accordance With The Brooks Act (public Law (pl0582) And Implemented In Accordance With The Federal Acquisition Regulation (far) Subpart 36. Firms Will Be Selected Based On Demonstrated Competence And Qualifications For The Required Work. b. This Procurement Is Restricted To Service-disabled Veteran Owned Small Business (sdvosb) Firms. This Requirement Is Being Procured In Accordance With The Vaar 836.606-73 As Implemented In Far Subpart 36.6. c. This Is Not A Request For Proposal, And An Award Will Not Be Made With This Announcement. This Announcement Is A Request For Sf 330 S From Qualified Contractors That Meet The Professional Requirements. d. The Selection Criteria For This Acquisition Will Be In Accordance With Far 36.602-1 And Vaar 836.602-1 And Are Listed Below In Descending Order Of Importance. The Completed Sf 330 Will Be Evaluated By The St. Louis Va Medical Center Evaluation Board In Accordance With Far 36.602-5(a) And The Selection Report Shall Serve As The Final Selection List, Which Will Be Provided Directly To The Contracting Officer. The Government Will Not Pay Nor Reimburse Any Costs Associated With Responding To This Request. The Government Is Under No Obligation To Award A Contract As A Result Of This Announcement. e. Award Of Any Resultant Contract Is Contingent Upon The Availability Of Funds. f. No Solicitation Document Is Available And No Other Information Pertaining To Project Scope, Etc. Is Available At This Time. Any Request For Assistance With Submission Or Other Procedural Matters Shall Be Submitted Via Email Only To Abby.monroe2@va.gov And Arnold.payne@va.gov. Personal Visits To Discuss This Announcement Will Not Be Allowed. g. The Naics Codes For This Procurement Is 541310 Architectural Services And Small Business Size Standard Of $12.5m. Award Of A Firm Fixed Price Contract Is Anticipated. The Anticipated Time For Completion Of Design Is Approximately 199 Calendar Days Including Time For Va Reviews. The Estimated Magnitude Of The Resulting Construction Price Range Is Estimated To Be Between $1,000,000 And $5,000,000. h. Database Registration Information: verification Of Status Of Apparently Successful Offeror This Acquisition Is 100% Set-aside For Qualified Service-disabled Veteran Owned Small Business Ae Firms Incompliance With Vaar 852.219-10. Only Businesses Verified And Listed In The Small Business Administration (sba) Registry Https://veterans.certify.sba.gov, Shall Be Considered. system For Award Management (sam): federal Acquisition Registrations Require That Federal Contractors Register In The System For Award Management (sam) Database At Www.sam.gov And Enter All Mandatory Information Into The System. Award Cannot Be Made Until The Contractor Has Registered. Offerors Are Encouraged To Ensure That They Are Registered In Sam Prior To Submitting Their Qualifications Package. j. The Excluded Parties List System (epls): to Ensure That The Individuals Providing Services Under The Contract Have Not Engaged In Fraud Or Abuse Regarding Sections 1128 And1128a Of The Social Security Act Regarding Federal Health Care Programs, The Contractor Is Required To Check The Excluded Parties List System (epls) Located At Www.sam.gov For Each Person Providing Services Under This Contract. Further The Contractor Is Required To Certify That All Persons Listed In The Qualifications Package Have Been Compared Against The Epls List And Are Not Listed. During The Performance Of This Contract The Contractor Is Prohibited From Using Any Individual Or Business Listed On The List Of Excluded Individuals/entities. k. E-verify System: companies Awarded A Contract With The Federal Government Shall Be Required To Enroll In E-verify Within 30 Days Of The Contract Award Date. They Shall Also Need To Begin Using The E-verify System To Confirm That All Of Their New Hires And Their Employees Directly Working On Federal Contracts Are Authorized To Legally Work In The United States. E-verify Is An Internet-based System That Allows An Employer, Using Information Reported On An Employee's Form I-9, To Determine The Eligibility Of That Employee To Work In The United States. There Is No Charge To Employers To Use E-verify. (far 52.222-54) l. A/e Firms Are Required To Respond If Interested By Submitting One (1) Completed Standard Form 330 Qualification Package Parts I And Ii To Include All Consultants (form Available On-line At: Https://www.gsa.gov/system/files/sf330-21.pdf). Must Include In Part I Section H An Organizational Chart Of The Firm (excludes Consultants) And A Design Quality Management Plan. Submission Information Incorporated By Reference Is Not Allowed. All Submissions Shall Be Made Electronically. m. Completed Package Shall Be Delivered Electronically On Or Before 1/17/2025 At 3:00pm Central Standard Time To The Nco 15 Contracting Office, Attn: Arnold Payne, Contracting Officer @ Arnold.payne@va.gov And Abby Monroe, Contract Specialist @ Abby.monroe2@va.gov. project Information the Mission Of The Veterans Affairs Saint Louis Health Care System (vastlhcs) Is To Provide The Highest Quality Health Care To Our Nation S Veterans. In Order To Accomplish This Mission, Vastlhcs Facility Engineering Service (fes) Intends To Partner With An A/e Firm On A Project To 657-24-111jc Renovate Ambassador Suite & Main Lobby, Building 1, John Cochran Division, St. Louis, Mo 63106. Project Will Renovate An Ambassador Entrance, Entrance Corridor, And The Ambassador Suite To Improve Patient And Ada Access To The Building, Fix Moisture And Leaking Issues With The Existing Skylight, Update Finishes, Improve Patient Circulation, And Optimize Space For The Existing Functions Operating In The Area As Well As Correct Hvac And Electrical Deficiencies, And Other Facilities Conditions Assessment Deficiencies Located Within The Area. The Main Entrance Of Bldg. 1 Will Be Updated To Facilitate Visitor Traffic Flow And Experience. The Existing Revolving Door Will Be Replaced With An Airlock Of Sliding And Swinging Doors With Automatic Controls. supplement B scope Of Work: a/e Services Are Required For Schematics, Design Development, Construction Documents, Construction Cost Estimate And Construction Period Services For Project Number 657-24-111jc Renovate Ambassador Suite & Main Lobby, Building 1. This Delivery Order Shall Cover The Following Tasks. a/e Part Two Services Of This Design Project (also Known As Construction Period Services) Includes Responding To Construction Contractor Requests For Information (rfis) During The Solicitation And Construction Phases Of The Construction Project, Attendance At Pre-bid, Post-award And Commissioning Kick Off Construction Project Conferences, Review Of Construction Material Submittals And Shop Drawings, Approximately 5 Site Visits During Construction To Ensure Compliance With The Design Drawings And Specifications, Preparation Of Site Visit Reports, Coordination With Project Commissioning Requirements, Review Of Any Construction Project Modifications For Cost And Technical Acceptability, Attendance In The Final Acceptance Inspection, Preparation Of The Punch List And Preparation Of Record Drawings Of The Completed Construction Project Based On The Construction Contractor S As-built Drawings. The A/e Shall Prepare A Submittal Log To Be Utilized By The Va During Construction Period Services, Maintain Rfi Log And Provide Meeting Minutes For Weekly Construction Meetings Throughout The Duration Of Construction. The A/e Shall Hire A Third-party Commissioning Agent To Commission All Installed Equipment. the Above Paragraphs Constitute A Basic Outline Of The Work To Be Accomplished And In No Way Comprises All The Details For Design Of This Project. The A/e Shall Initiate Detailed Inspection Of The Project Site To Determine The Needs And Conditions For The Design Of This Project. the A/e Shall Be Solely Responsible For The Management, Including All Associated Labor, Equipment, Materials, Mailing Costs, And Inspection, To Meet The Requirements Of The Design Project. The A/e Shall Further Provide Meeting Minutes For All Meetings Held Under This Design Project. general Statement a/e Part One Services (also Known As Design Phase) For This Design Project Includes Site Visit, Field Investigation, Conduct Of Studies And User Interviews To Update Drawings, Specifications And Cost Estimates For All Facets Of Work And Disciplines/trades To Facilitate A Construction Project. This Project Will Renovate Ambassador Suite & Main Lobby, Building 1 2. Design Development: the A/e Firm Shall: a. Meet With Facilities, And Other Personnel Prior To Start Of Design To Determine Detailed Requirements Of Work Involved. b. Work From Existing Building And Site Drawings Furnished By The Va To Develop Project Design. (these Are To Be Used Only As Guidelines); c. Perform Any Necessary On-site Field Investigations To Accomplish Work And To Verify Drawings Provided By The Va; d. Prepare Rough Sketches, If Necessary, To Solve Possible Problems In Design Throughout The Contract; And e. Follow Va Program Guide Pg-08-15 Volume C, And Other Applicable Guidelines To Design The Project. 3. Evaluation Factors: selection Criteria Are In Accordance With Federal Acquisition Regulation (far) Part 36.602-5 And Va Acquisition Regulation (vaar) Part 836.602-1.â  Prospective Firms Are Required To Address All Selection Criteria Within Submitted Sf330 Packages Using Additional Pages As Necessary.â  Sf 330 Submissions Including Any Additional Pages Are Not To Exceed Fifty (50) Pages. Each Page Cannot Exceed 81/2 X 11 In Size. qualifications (sf330) Submitted By Each Firm For Project Number: 657-24-111jc Renovate Ambassador Suite & Main Lobby, Building 1 Va Medical Center Saint Louis John Cochran Division Will Be Reviewed And Evaluated Based On The Following Evaluation Criteria Listed Below In Descending Order Of Importance: 1. Professional Qualifications: The Qualifications Of The Individuals Which Will Be Used For These Services Will Be Examined For Experience And Education And Their Record Of Working Together As A Team. A/e Firms Shall Have Licensed Professional Architects And Engineers Currently Registered In The State Of Missouri Or In A State Of Which Missouri Has Recognized The Engineering License. The Specific Disciplines Which Will Be Evaluated Are Architects, Civil Engineer, Mechanical Engineers, Electrical Engineers, Structural Engineers, Industrial Hygienists, Estimators, Cad Operators, Project Managers, Leed Consultant, Fire Protection Engineer, And Interior Designer. 2. Specialized Experience And Technical Competence: Provide Detailed Project Information On Any Projects (that Are Complete - Design And Construction) The Proposed Team Has Worked Together On In The Last Five (5) Years. Special Emphasis Will Be Given To Any Medical Facility Related Projects. If The Entire Team Has Not Worked Together Previously, Provide Detailed Project Information That Each Of The Team Members Have Worked On In The Last Three (3) Years With Special Emphasis On Medical Facility Projects. The Project Information Should Include Project Titles, A Short Scope Of Work, Date Of Design Completion, Date Of Construction Completion, Firms Involved, Etc. The A/e Shall Also Describe If They Have Any Experience Completing A Design That Was Started By Another A/e Firm. Provide The Project Title, Scope Of Work, Date Of Design Start For This Team, Percentage Of Design When Accepted By Team And Completion Of Design. 3. Capacity To Accomplish The Work. The General Workload And Staffing Capacity Of The Design Offices Which Will Be Responsible For The Majority Of The Design And The Ability To Accomplish The Work In The Required Time Will Be Evaluated. 4. Past Performance: Nco 15 Will Evaluate Past Performance On Recent And Relevant Contracts With Government Agencies (emphasis On Va Work) And Private Industry In Terms Of Construction Cost Estimating, Cost Control, Quality Of Work, Compliance With Performance Schedules And A Record Of Significant Claims Against The Firm Due To Improper Or Incomplete Engineering Services (references Required). Project Past Performances That Are Older Than 3 Years Will Receive A Lesser Score Than Those References For Projects Accomplished Within The Past 3 Years. 5. Location Of Design Firm: The Geographic Proximity Of Each Firm To The Location Of The Va Medical Center Will Be Evaluated. The Firm Must Be Capable Of Issuing Stamp Drawings In The State Where The Work Is Performed.â  The Medical Center Is Located At Saint Louis, Va Medical Center, Saint Louis Missouri 63106. 6. Claims And Terminations: Provide Documentation Of Significant Claims Against The Firm Or Terminated Contracts Because Of Improper Or Incomplete Architectural And Engineering Services. Provide A Detailed Narrative Of Relevant Projects Within The Last 5 Years That Have Claims Against The Organization Or Have Been Terminated By The Owner. Include The Circumstances, Cost, And Schedule Impacts To Involved Parties, And Outcomes Of The Claims And/or Terminations. They Will Be Examined.

Purchaser Name: Issyk Kul Region Upr On Urban Planning And Architect State Agency Arch, Build And Residential com hoz | Purchasing a Passenger Car

Details: Description the Airborne Strategic Command, Control, And Communications (asc3) Program Office (pma-271) Is Conducting Market Research For A Competitive Indefinite Delivery Indefinite Quantity (idiq) Multiple Award Contract (mac) In Support Of The E-6b Mercury Aircraft. the Anticipated Request For Proposal Release Is First Quarter Fy2026. the Anticipated Idiq Mac Award Is First Quarter Fy2027. the Anticipated Ordering Period Is 10 Years. the Results Of This Sources Sought Will Be Utilized To Determine The Interest, Availability And Technical Capability Of Both Large And Small Businesses (including The Following Subsets: Small Disadvantaged Businesses, Hubzone Firms, Certified 8(a), Service-disabled Veteran-owned Small Businesses, And Woman Owned Small Business) To Provide The Required Products And/or Services. As Such, All Eligible Small Businesses, To Include Those With Any Socio-economic Status, Are Encouraged To Respond. the Execution Of Efforts Under This Mac Will Be Competitively Awarded Delivery And Task Orders. The Efforts Herein May Include Contractor Owned, Government Owned, Or A Combination Of Two And Will Be Specified At The Delivery Or Task Order Level. specific Requirements the Idiq Mac Scope Will Include Products And Services Such As, But Not Limited To, Engineering, Test, Facilities, Integrated Product Support (ips), Product Design, Development, Maintenance, Integration, And Logistics Support Services, To Support The Acquisition And Sustainment For The Life Cycle Of The E-6b, And Its Systems, System Of Systems (sos), Sub-systems, And Support Equipment (se). The Idiq Mac Scope Will Support The Take Charge And Move Out (tacamo), Airborne Command Post (abncp), Presidential National Voice Conferencing (pnvc), And Airborne Launch Control System (alcs) Missions, Plus Their Replacements, On The E-6b. the Scope Of Work For Delivery And Task Orders Issued Under The Idiq Mac Are Anticipated To Include, But Are Not Limited To, The Following Functional Areas: 1. Mission Communications Systems And Integration mission Communications Systems Are Integrated Into The E-6b And Provide Its Users With Data And Voice Connectivity To Other Aircraft, Ground-based Installations, And Surface Vessels. Capabilities Include Line Of Sight Radio In Multiple Bands/frequencies, Beyond Line Of Sight (blos) Communications, Satellite Communications (satcom), And Their Integration Into E-6b And Its Systems. Systems In This Functional Area Will Need To Interface With And Provide Data And/or Voice Communications To Support The Systems That Provide The Tacamo, Abncp, Pnvc, And Alcs Missions, And Their Replacements. Delivery Orders And Task Orders (dos/tos) Within This Functional Area Are Expected To Include Mission Communications Systems Research, Development, Technical Studies, Cybersecurity, Design And Prototyping, Delivery Of Build-to-print Technical Data Packages (tdps) Suitable For Follow-on Competition, Production, Modification, Integration, Maintenance, And Test. 2. Mission Systems Architecture Design, Development, And Integration mission Systems Architecture Provides The Airborne Information Technology (it) Infrastructure And The Integration Of The Various Aircraft Avionics, Broadband Capabilities, And Mission Communications Systems To Support The E-6b Operational Mission. In Addition, The Very Low Frequency (vlf) Transmit And Receive System Provides A Vital Component Of The E-6b Operational Mission To Communicate With Critical Components Of The Nuclear Enterprise. Components And Systems Within This Functional Area With Need To Interface With And Support The Systems That Provide The Tacamo, Abncp, Pnvc, And Alcs Missions, And Their Replacements. Do/tos Within This Functional Area Are Expected To Include Mission Systems Architecture Research, Development, Technical Studies, Cybersecurity, Design And Prototyping, Delivery Of Build-to-print Technical Data Packages (tdps) Suitable For Follow-on Competition, Production, Modification, Integration, Maintenance, And Test. 3. Air Vehicle Maintenance, Modification, And Support this Functional Area Supports The Sustainment And Modifications To The E-6b Air Vehicle. The Maintenance, Modification, And Improvement Of The E-6b Avionics, Flight Deck, And Aircraft Power, And Any Related Systems, Subsystems, And Components Is Required To Ensure The Viability Of The Aging E-6b Airframe. Do/tos Within This Functional Area Are Expected To Include Air Vehicle Systems And Subsystems Research, Development, Technical Studies, Cybersecurity, Design And Prototyping, Delivery Of Build-to-print Technical Data Packages (tdps) Suitable For Follow-on Competition, Production, Modification, Integration, Maintenance, And Test. 4. Systems Engineering this Functional Area Supports Systems Engineering Analysis, Reviews, White-paper Creation, And Studies To Support All Aspects Of The Operation And Upkeep Of The E-6b And All Its Systems And Subsystems, As Well As Potential New Capabilities And Directed System Integration. This Support Includes Mass Properties, Weight And Balance, System Safety Engineering, Position, Navigation, And Timing (pnt), System Integration Design, System Specification Creation And Modification, And System Operation Analysis. Dos/tos Within This Functional Area Are Expected To Include Analyses, Studies, White Papers, And Support Of Systems Engineering Technical Review (setr) Events, 5. Software Design, Development, And Integration this Functional Area Supports Software Development Activities In Support Of Aircraft Infrastructure, Mission Systems And Mission Communications Systems, Ground Infrastructure And Lab Setup And Integration, And The Sustainment And Support System (sass). Dos/tos Within This Functional Area Are Expected To Include Software Requirements Definition And Derivation, Design, Development, Test, Integration, Documentation, Delivery, Deployment, And Maintenance Of Software Components And Systems. 6. Systems Security Engineering this Functional Area Supports Cybersecurity, Anti-tamper (at) And Cryptographic Encryption Analysis, Studies, And Products To Support The Secure And Reliable Operation Of The E-6b And Its Connectivity To Other Systems. Dos/tos Within This Functional Area Are Expected To Include Cybersecurity Analysis, Studies, Cross-domain Solutions (cds), Data, And Support Of The Risk Management Framework (rmf) Submissions By The Government, And Any Follow-on Or Similar Systems, To Support Interim Authority To Test (iatt) And Authority To Operate (ato) For The E-6b And Any Of It Systems, Subsystems, Ground Components, And Labs. Dos/tos Within This Functional Area Are Also Expected To Include Analyses, Studies, Data, And Other Needs Defined By The Government In Support Of Systems Security Engineering, At, And Cryptographic Encryption. 7. Sustainment And Product Support logistics And Sustainment Activities Consist Of Providing Services That Are Required For Optimal Performance Of The E-6b And Related Components Throughout The Program Lifecycle. Logistics And Sustainment Activities May Include Contractor Logistics Support (cls), Life Cycle Sustainment, Supply Support, Depot-level Support, Organization-level Maintenance, Intermediate Field-level Maintenance, Repair And Refurbishment, Alteration Installation, Logistics And Sustainment Analyses, Maintenance Planning, Management, And Services, Packaging, Handling, Storage, And Transportation (phs&t), Training And Training Support, Operation And Operator Training Curriculum Development, Obsolescence Management, Diminishing Manufacturing Sources And Material Shortages (dmsms) Support, Inventory And Sparing Management, Documenting Technical Data/red-lines For Data/ Documents/drawings Updates, Part And System Identification, Labeling, And Marking, Developing Test Plans, Performance Testing, System Operational Testing, Test Instrument Installation And Removal, User Familiarization, Configuration Audits, Material Delivery/validation, Support Equipment, Providing Support To Operational Fleet Assets, Facilities And Infrastructure Support, Sparing, And Disposition Of Materials. Logistics And Sustainment Activities May Include Cross-domain Solutions Also Applicable To Unmanned Air Vehicles Or Unmanned Underwater Vehicles. Do/tos Within This Functional Area Are Expected To Include Logistics And Sustainment Research, Technical Studies, And Support Services. eligibility the Product Service Codes (psc) For These Requirements Are Anticipated To Include, But Are Not Limited To: 7a20 -it And Telecom - Application Development Software (perpetual License Software) 7j20 - It And Telecom - Security And Compliance Products (hardware And Perpetual License Software) 5831 - Intercommunication And Public Address Systems, Airborne 5826 - Radio Navigation Equipment, Airborne 5841 - Radar Equipment, Airborne r425 - Support- Professional: Engineering/technical r499 - Support- Professional: Other r706 – Logistics Support Services r699 – Support – Administrative: Other r799 - Support- Management: Other ac11 - National Defense R&d Services; Department Of Defense - Military; Basic Research ac12 - National Defense R&d Services; Department Of Defense - Military; Applied Research ac13 - National Defense R&d Services; Department Of Defense - Military; Experimental Development 6910 - Training Aids 1560 - Airframe Structural Components 1620 - Aircraft Landing Gear Components 1630 - Aircraft Wheel And Brake Systems 1730 - Aircraft Ground Servicing Equipment 1710 - Aircraft Landing Equipment 5342 - Hardware, Weapon System c219 – Architect And Engineering – General: Other 5963 – Electronic Modules ac31 - National Defense R&d Services; Defense-related Activities; Basic Research ac32 - National Defense R&d Services; Defense-related Activities; Applied Research ac33 - National Defense R&d Services; Defense-related Activities; Experimental Development j015 - Maint/repair/rebuild Of Equipment- Aircraft And Airframe Structural Components j016 - Maint/repair/rebuild Of Equipment- Aircraft Components And Accessories the North American Industry Classification System (naics) Codes Are Anticipated To Include, But Are Not Limited To: 336411 - Aircraft Manufacturing 336413 - Other Aircraft Parts And Auxiliary Equipment Manufacturing 488190 - Other Support Activities For Air Transportation 541330 (exception 1) Military And Aerospace Equipment And Military Weapons 334111 - Electronic Computer Manufacturing 513210 - Software Publishers 541611 - Administrative Management And General Management Consulting Services 541715 - Research And Development In The Physical, Engineering, And Life Sciences (except Nanotechnology And Biotechnology) 334112 - Computer Storage Device Manufacturing 541618 - Other Management Consulting Services 541715 – Research And Development In The Physical, Engineering, And Life Sciences (except Nanotechnology And Biotechnology) 334511 - Search, Detection, Navigation, Guidance, Aeronautical, And Nautical System And Instrument Manufacturing 334220 - Radio And Television Broadcasting And Wireless Communications Equipment Manufacturing please Note That Under A Small Business Set-aside, The Small Business Prime Must Perform At Least 50% Of The Work To Be Performed In Accordance With Far 19.505. disclaimer this Sources Sought Is For Informational Purposes Only. This Is Not A Request For Proposal. It Does Not Constitute A Solicitation And Shall Not Be Construed As A Commitment By The Government. Responses In Any Form Are Not Offers And The Government Is Under No Obligation To Award A Contract As A Result Of This Announcement. No Funds Are Available To Pay For Preparation Of Responses To This Announcement. Any Information Submitted By Respondents To This Technical Description Is Strictly Voluntary. submission Details it Is Requested That All Interested Businesses Complete The Sources Sought Response Defined In Attachment 1, In Ms Word Format (ms 365 Compatible). All Responses Must Be Unclassified. If The Response Provided Contains Proprietary Information, It Must Be Marked Accordingly. Submitted Data Will Not Be Returned To The Responders. interested Vendors Are Solely Responsible For All Expenses Associated With Responding To This Sources Sought Notice. Pma-271 Will Not Pay For Information Received In Response To This Sources Sought Notice. do Not Submit Pricing Information In Response To This Sources Sought Notice. the Sources Sought Response Shall Be Electronically Submitted To Randy Putnam At Randolph.a.putnam.civ@us.navy.mil And Lisa Troccoli At Lisa.j.troccoli.civ@us.navy.mil In Accordance With The Response Date Identified Within This Posting. Questions Or Comments Regarding This Notice May Be Addressed To Randy Putnam At Randolph.a.putnam.civ@us.navy.mil.

Details: In 2024, a Contemporary Architecture Photography Campaign in Morbihan Was Led by Photographer Kourtney Roy at the Request of the Ddtm of Morbihan. It Is Planned to Publish This Work; To Do This, It Is Necessary to Supplement the Photographs with Graphic Documents and Explanatory Texts in Order to Present These Remarkable Architectures More Precisely. If Photography Indeed Makes It Easy to Present Buildings and Reach a Wide Audience, Technical and Analytical Information Are Essential to Understand and Respect the Qualities of Constructions, Whether for Visitors, Amateurs, Owners or Project Leaders. The Approach to Raising Awareness of Contemporary and Modern Architecture Does Not Aim to Protect But to Highlight and Stimulate the Desire for Architecture. The architect's approach is to respond as best as possible to today's uses and construction practices. Knowledge of architecture is a prerequisite for any proper consideration of the context, potentials and constraints, in the same way as geography or climate.

Details: 1. Contract Information: This Contract Is Being Procured In Accordance With The Brooks A-e Act As Implemented In Far Subpart 36.6. Firms Will Be Selected For Negotiation Based On Demonstrated Competence And Qualifications For The Required Work. See Numbered Note 24 For General Information On The A-e Selection Process. A-e Services Are Required For Site Investigation, Concept Design, Final Design (option), And Construction Phase Services (option) For The Subject Project. North American Industrial Classification System Code Is 541330, Which Has A Size Standard Of $25,500,000 In Average Annual Receipts. This Announcement Is Open To All Businesses Regardless Of Size. Far Clause “52.219-4 Notice Of Price Evaluation Preference For Hubzone Small Business Concerns” Will Be Included In The Solicitation. A Firm-fixed-price Contract Will Be Negotiated. The Contract Is Anticipated To Be Awarded In Sep 2025 And Design Completed By Oct 2028. A-e Contract Price Is Estimated To Be More Than $10,000,000. If A Large Business Is Selected For This Contract, It Must Comply With Far 52.219 -9 “small Business Subcontracting Plan” Regarding The Requirement For A Subcontracting Plan On That Part Of The Work It Intends To Subcontract. This Action Will Be Subject To Far Clause 52.219-14 “limitations Of Subcontracting.” For The Purposes Of This Solicitation, This Acquisition Is To Be Considered A Service And As Such, The Government Will Not Pay More Than 50% Of The Amount Paid By The Government For Contract Performance To Subcontractors That Are Not Similarly Situated Entities. Any Work That A Similarly Situated Entity Further Subcontracts Will Count Towards The Prime Contractor's 50% Subcontract Amount That Cannot Be Exceeded. When A Contract Includes Both Services And Supplies, The 50% Limitation Shall Apply Only To The Service Portion Of The Contract; The Subcontracting Goals For The New York District Which Will Be Considered In The Negotiation Of This Contract Are: (1) At Least 25%, But No More Than 49% Of A Contractor's Intended Subcontract Amount Be Placed With Small Businesses (sb); (2) At Least 5 % Of A Contractor's Intended Subcontract Amount Be Placed With Small Disadvantaged Businesses (sdb); (3) At Least 3% Of A Contractor's Intended Subcontract Amount Be Placed With Women-owned Sb (wosb); (4) At Least 3% Of A Contractor's Intended Subcontract Amount Be Placed With Service-disabled Veteran-owned Sb; (5) At Least 3% Of A Contractor's Intended Subcontract Amount Be Placed With Veteran-owned Sb; And (6) At Least 3% Of A Contractor's Intended Subcontract Amount Be Placed With Hubzone Sb. The Plan Is Not Required With This Submittal, But Will Be Required With The Fee Proposal Of The Firm Selected For Negotiations. To Be Eligible For Contract Award, A Firm Must Register For An Unique Entity Id, A 12-character Alphanumeric Id Assigned To An Entity By Sam.gov. New Entities Can Get Their Unique Entity Id At Sam.gov And Complete An Entity Registration. 2. Project Information: Replace, By Deconstruction And Reconstruction, A Multi-story General Instruction Building. Rehabilitate The Original Features Of The Building Constructed In 1911 Which Have Survived. The Primary Facility Will Provide Spaces For General Instruction Classrooms, Lecture Halls And Collaboration Space, Administrative Space With Private And Open Offices, An Auditorium, Lab Space, Conference Rooms, Reception Areas, A Library And Mock Courtroom, An Arms Vault, Showers And Bathrooms, Lactation Rooms, Copy Rooms, Staff Break Rooms, Departmental Storage, Vending Areas And A Cafe, As Well As Freight And Passenger Elevators. Cybersecurity Measures, Electronic Security Systems (pacs & Ids) Installation, Energy Measurement And Control System (emcs) Connection, Building Information Systems, And Fire Alarm And Protection Systems Will Be Included. Supporting Facilities Include Utility Connections (water, Sanitary Sewer, Electrical), Storm Drainage, Walks, Curbs And Gutters, Landscaping, And Site Improvements. Heating Will Be Provided By District Heat, And Air Conditioning Will Be Provided By A Steam Powered Absorptive Chiller System. Comprehensive Building And Furnishings Related Interior Design Services Are Required. This Project Will Be Designed For Accessibility And Usability By Individuals With Disabilities. Utility Connections Are Required To Privatized Electric Distribution, Water, And Wastewater Systems. The Army Intends To Have The Respective Utilities Privatization System Owners, American Water And City Light & Power Make And Own The Necessary Connections Up To The Facility Service Disconnect Or Other Defined Point Of Demarcation. Facilities Will Be Designed To A Minimum Life Of 40 Years In Accordance With Dod's Unified Facilities Criteria (ufc 1-200-02) Including Energy Efficiencies, Building Envelope And Integrated Building Systems Performance. Demolish The Portion Of The Building Constructed In 1955 (321,012 Total Sf). U.s. Military Academy (usma) Has A Substantial Deficit Of -412,799 Square Feet In General Instructional Space, And This Project Will Address A Portion Of That Deficit By Constructing A New Addition. The New Addition, Exterior Alterations, And Related New Construction Will Not Destroy Historic 1911 Materials, Features, And Spatial Relationships That Characterize The Property. The New Work Will Be Differentiated From The Old And Will Be Compatible With The Historic Materials, Features, Size, Scale And Proportion, And Massing To Protect The Integrity Of The Property And Its Environment. The New Addition And Adjacent Or Related New Construction Will Be Undertaken In Such A Manner That, If Removed In The Future, The Essential Form And Integrity Of The Historic 1911 Property And Its Environment Would Be Unimpaired. Moreover, This Project Will Consolidate Key Programs In One Facility. By Upgrading And Consolidating Key Programs Into A Central Location Within The Main Campus, The Academy Aims To Foster A More Cohesive Academic Environment While Addressing Its Instructional Space Deficit. The Centralization Of Programs Will Reduce The Physical Fragmentation Of Departments And Encourage More Cross-disciplinary Collaboration. This Approach Aligns With Modern Educational Trends, Where Academic Institutions Are Moving Towards Flexible, Multi-purpose Spaces That Encourage Interaction And Innovation. Bringing Key Programs Together In Adequately Sized Spaces Will Not Only Optimize The Use Of Space But Also Create An Atmosphere Where Students And Faculty From Different Disciplines Can Engage In Meaningful Collaboration, Enhancing The Learning Experience. This Project Is Required To Update The Flagship Schoolhouse, Thayer Hall, As Part Of The Academic Building Upgrade Program (abup), Which Was Conceived To Address Critical Gaps In Instructional Space And Ensure That Academic Buildings Meet Both The Current And Future Needs Of The Usma's Academic Departments. Thayer Hall Will Support A Student Load Of 2,880 Students. The Project's Primary Goal Is To Reduce The Instructional Space Deficit. By Upgrading The Instructional Facilities, The Academy Seeks To Align Itself With Contemporary Educational Standards, Which Prioritize Collaborative Learning, Cross-disciplinary Interaction, And Active Engagement Between Students And Faculty. The Contract Will Require Accomplishment Of Site Investigation Work. The Contract Will Require Preparation Of Parametric Design Considered To Be 5 – 15 Percent Of The Total Design Effort. The Contract Will Require Preparation Of Concept Design Considered To Be 35 Percent Of The Total Design Effort. As An Option, The Contract Will Require Preparation Of 60%, 90%, And Final 100% Designs. As An Option, The Contract Will Require Delivery Of Construction Phase Ae Services. The Estimated Construction Cost Of This Project Is Over $500,000,000. Cost Estimates Must Be Prepared Using The Corps Of Engineers Micro Computer Aided Cost Estimating System (mcaces) – Second Generation (mii). The Contractor Shall Be Responsible For Accomplishing Designs And Preparing Drawings Using Advanced Modeling And Delivering The Three-dimensional Drawings In Autodesk Revit And Autodesk Civil 3d Software. The Government Will Only Accept The Final Product For Full Operation, Without Conversion Or Reformatting, In The Target Advanced Modeling Software Format, And On The Target Platform Specified Herein. Drawings Shall Be Compliant With The Current A/e/c Cad Standard Available From The Cad/bim Technology Center, Engineer Research And Development Center. 3. Selection Criteria: The Selection Criteria For This Particular Project Are Listed Below In Descending Order Of Importance (first By Major Criterion And Then By Each Sub- Criterion). Criteria A-e Are Primary. Criteria F-g Are Secondary And Will Only Be Used As "tie-breakers" Among Firms That Are Essentially Technically Equal. a. Submit No More Than Ten Projects Which Demonstrate Specialized Experience And Technical Competence In Design Of Facilities Similar To The Project Described Herein. Submitted Projects Should Have A Construction Cost Of At Least $100,000,000. Submitted Projects Should Have A Construction Completion Date No Earlier Than January 2015. On All Example Projects, The Government May Consider The Following Strengths For Evaluation Purposes: (1) Design Of Facility Renovations For Older/historic Institutions Of Higher Learning. (2) Application Of The Secretary Of The Interior’s Standards For The Treatment Of Historic Properties And Compliance With Section 106 Of The National Historic Preservation Act. (3) Sustainable Design Using An Integrated Design Approach And Emphasizing Environmental Stewardship, With Experience In Energy And Water Conservation And Efficiency; Use Of Recovered And Recycled Materials; Waste Reduction; Reduction Or Elimination Of Toxic And Harmful Substances In Facilities Construction And Operation; Efficiency In Resource And Materials Utilization; Development Of Healthy, Safe, And Productive Work Environments; And Employing The Leed Evaluation And Certification Methods. (4) Conducting Whole Building Life Cycle Cost Analysis (wb Lcca) Considering The Cradle-to-grave Costs Associated With Upfront Construction, Lifetime Building Sustainment, Maintenance, Operations (including Energy And Water Use), And Building Disposal, To Target The Most Cost-effective Design To Achieve Modeled Building Energy Consumption Reduction By A Minimum Of 30% Below The Ashrae 90.1 Baseline Specified In 10 Cfr 433 Without The Use Of Fossil Fuel Combustion Systems, With The Goal Being To Select The Optimal Combination Of Interdependent Building Systems (e.g. Envelope, Hvac, Hot Water, Lighting, Wall And Floor Thermal Mass Capacity, Etc). (5) Design Of Resilient Buildings, I.e. A Building That (i) Maximizes The Ability Of The Owner/operator To Withstand And Recover From A Potentially Disruptive Event That May Adversely Affect Mission Assurance And Mission-essential Functions, Including Extreme Weather (as Defined By 10 U.s.c. 101(a)(20)) Or A Disruption To Energy Or Water Supplies; (ii) Has Minimal Energy And Water Demand; (iii) Has An Indoor Environment Optimized To Promote Human Safety, Physical And Psychological Health, And Productivity; And (iv) Integrates Carbon-free Energy Generation And Storage. (6) Design Of Building Stabilization And Structural Shoring And Bracing Systems. (7) Experience Of The Prime Firm And Significant Subconsultants, Particularly The Cost Engineering Firm, The Geotechnical Drilling Firm, And The Asbestos/lead/pcb/hazmat Consulting Firm, In Working Together. b. Qualified Professional Personnel In The Following Key Disciplines: Aabc Certified Commissioning Authority (cxa), Accredited Learning Environment Planner (alep), Architecture, Asbestos/lead/pcb/hazmat Consulting, Certified Value Specialist, Civil Engineering, Clc Or Cld Certified Lighting Consulting, Comptia Certified Cybersecurity Consulting, Construction Project Scheduler Experienced With Primavera P6, Cost Engineering, Cts Certified Audio/visual Consulting, Electrical Engineering, Electronic Security Engineering, Fire Protection Engineering, Geotechnical Engineering, Historic Preservation Architecture, Ince Certified Acoustical Consulting, Land Surveying, Landscape Architecture, Leed Accredited Professional, Mechanical Engineering, Ncidq Or State Licensed Interior Design, Project Management, Structural Engineering, Telecommunications Engineering, And Vertical Transportation Engineering. The Lead Architect Or Engineer In Each Discipline Must Be Registered To Practice In The Appropriate Professional Field. The Civil Engineer, Asbestos/lead/pcb/hazmat Consultant And Land Surveyor Must Be Registered To Practice In New York. The Evaluation Will Consider Education, Certifications, Training, Registration, Overall And Relevant Experience, And Longevity With The Firm. c. Past Performance On Dod And Institution Of Higher Learning Contracts With Respect To Cost Control, Quality Of Work, And Compliance With Performance Schedules, As Determined From Cpars And Other Sources. d. Capacity To Submit The Draft Parametric Design Report (pdr) (10% Complete) By January Or February 2026, To Submit The Corrected Pdr (15% Complete) By April 2026, To Submit The Draft Concept Design (30% Complete) By June Or July 2026, To Submit The Corrected Concept Design (35% Complete) By September 2026, To Submit The 35% Certification Package (consisting Of Final Eng 3086, Designated Construction Agent Assessment Eng 6196, And Cost Schedule Risk Analysis Documentation) By November 2026 And Complete The Final Design (option) By October 2028. Schedule Is Critical For The Project. The Evaluation Will Consider The Experience Of The Firm And Any Consultants In Similar Size Projects, And The Availability Of An Adequate Number Of Personnel In Key Disciplines. e. Knowledge Of Design Of Foundations Bearing On Granite Or Gneiss Bedrock, Design Of Building Systems For Marine, Mixed-humid, And Cold Climate Zones, Rehabilitation Of Historic Stone Masonry, Design Complying With The Department Of Defense (dod) Unified Facilities Criteria, Design Complying With The Department Of The Army Policy Guidance On Resilient Buildings, Or Design Subject To Review By The New York State Historic Preservation Officer Or The New York State Department Of Environmental Conservation. f. Extent Of Participation Of Sb (including Wosb), Sdb, Historically Black Colleges And Universities, And Minority Institutions In The Proposed Contract Team, Measured As A Percentage Of The Total Estimated Effort. g. Volume Of Dod A-e Contract Awards In The Last 12 Months, With The Objective Of Effecting An Equitable Distribution Of Dod A-e Contracts Among Qualified Firms, Including Sb And Sdb. 4. Submission Requirements: Interested Firms Having The Capabilities To Perform This Work Must Submit Sf 330 Part I And Sf 330 Part Ii For The Prime Firm And All Consultants, To Jordan.k.moran@usace.army.mil Not Later Than 11:59 Pm Est On The Response Date Indicated Above. The Sf 330 Part I Shall Not Exceed 100 Pages (pdf Formatted To 8.5” X 11” Page Size), Including No More Than 50 Pages For Section E. Use No Smaller Than 12 Font Type. The Firm Is Encouraged, But Not Required, To Include Their Sam.gov-assigned Unique Entity Id Number In Sf 330, Part I, Section H. In Section H Describe The Firm's Overall Design Quality Management Plan (dqmp). A Project-specific Design Quality Control Plan Must Be Prepared And Approved By The Government As A Condition Of Contract Award But Is Not Required With This Submission. In Section H Also Indicate The Estimated Percentage Involvement Of Each Firm On The Proposed Team. The Most Highly Qualified Firms Will Be Interviewed. Neither Facsimile Nor Paper Hardcopy Transmissions Will Be Accepted. Solicitation Packages Are Not Provided, And No Additional Project Information Will Be Given To Firms During The Announcement Period. This Is Not A Request For Proposal. The Government Intends To Notify Interested Firms Of The Selection Or Non-selection Decision By March 2025. point Of Contact: Jordan Moran, (917) 908-8121 email Your Questions To Us Army Corps Of Engineers New York District At Jordan.k.moran@usace.army.mil

Details: Sources Sought Notice sources Sought Notice page 12 Of 12 sources Sought Notice *= Required Field sources Sought Notice page 1 Of 12 this Announcement Is Not A Request For Proposal. The Government Will Not Pay Nor Reimburse Any Costs Associated With Responding To This Request. The Government Is Under No Obligation To Award A Contract As A Result Of This Announcement. the Department Of Veterans Affairs Is Seeking A Qualified Architect-engineering (ae) Firm To Provide Schematics, Design Development, Construction Documents, Technical Specifications, Construction Period Services, Site Visits, Cost Estimates, As-built Documentation, And All Other Related Information For Project 528a5-24-504, Project Upgrade Buildings 7&8 Electric Room At The Canandaigua Vamc At 400 Fort Hill Ave, Canandaigua Ny 14424. This Project Will Expand The Existing Electrical Rooms On The Ground Floor Of Building 7 And 8, Into Adjacent Spaces And Replace Electrical Components. this Requirement Is Being Procured In Accordance With The Brooks Act As Implemented In Far Subpart 36.6. Applicable Naics Code Is 541330 And Small Business Size Standard Of $25.5 Million. Magnitude Of Construction Is Between $5,000,000.00 And $10,000,000.00. This Is A 100% Service-disabled Veteran Owned Small Business Set Aside. The Anticipated Award Date Of The Proposed A-e Contract Is On Or Before May 20th, 2025 . Potential Contractors Must Be Registered In Sam (www.sam.gov ) And Are Visible/verified/certified As Sdvosb (or Vosb) In Veterans Small Business Certification (https://veterans.certify.sba.gov/ ) At Time Of Submission Of Their Qualifications In Order To Be Considered For An Award. in Order To Assure Compliance With Vaar Clauses, 852.219-75 Va Notice Of Limitations On Subcontracting Certificate Of Compliance For Services And Construction (nov 2022) And 852.219-73 Va Notice To Total Set-aside For Verified Service-disabled Veteran-owned Small Businesses (nov 2022), All Firms Submitting A Sf 330 For This Notice Are Required To Indicate What Percentage Of The Cost Of Contract Performance Will Be Expended On The Concerns Employees And In Which Discipline(s) And Percentage Of Cost Of Contract Performance To Be Expended (and In What Disciplines) By Any Other Consultant/subcontractor Or Otherwise Used Small Or Large Business Entity(s). Any Consultant/subcontractor Or Otherwise Business Entity(s) Used Must Be Identified By Name, Office Location And Size/type Of Business (i.e., Sdvosb, Vosb, 8(a), Small, Large, Etc.). Failure To Provide This Information Will Deem The Firm S Sf 330 Submittal As Nonresponsive And Preclude Further Evaluation all A/e Firms Are Advised That In Accordance With Vaar 836.606-71 The Total Cost Of The Production And Delivery Of Designs, Plans, Drawings And Specifications Shall Not Exceed Six (6) Percent Of The Estimate Cost Of Construction. Other A-e Fees Are Not Included In The Six (6) Percent. Additionally, Far Clause 52.236-22 (c) - Design Within Funding Limitation, Will Be Applicable To This Procurement Action. exsisting Conditions: the Canandaigua Vamc Is Located At 400 Fort Hill Avenue, Canandaigua, Ny 14424. Building 7 And 8 Are Two Of The Main Campus Structures And Contains Sensitive Programming Including Clc S With In-patient Care. The Existing Electrical Rooms Are Insufficient In Size And Does Not Meet Current Codes/standards As Set By The Va. The Adjacent Spaces To These Electrical Rooms Consist Of Available Space For Expansion. All Electrical Equipment Shall Be Replaced Unless Otherwise Directed By The Va And All Building Services Shall Placed On Emergency Power. All Proposed Equipment Shall Meet Current Va Standards And Codes. scope Of Service Required 1. Provide Investigative, Schematic, And Design Development Services, Production Of Construction Documents, Working Drawings, Specifications, And Cost Estimates, And Perform Construction Administration Including Shop Drawing And Submittal Review As Required To Complete The Work And As Per The Architect/engineer (a/e) Required Deliverables. The A/e Firm Shall Analyze The Existing Conditions And Working With The Medical Center Staff Develop Various Proposals To Meet The Project Intent. Develop Accepted Proposal Into A Final Design And Cost Estimate To Best Suit The Needs And Constraints Of The Government, While Incorporating Vamc Canandaigua Engineering Services, Va Network 2, Or Any Other Government Comments. 2. Provide For Necessary Design For Utility Connections, Alternative Power, Phasing, And Support For Building Operations Through Construction With Minimal Interruptions. 3. Perform Load Test On Existing Generator And Emergency Power System To Confirm Existing Supply Will Support Additional Loads. 4. Provide An Independent Analysis To Locate Any Underground Or Hidden Utilities For Inclusion In The Design If Applicable, To Confirm Viability Of Planned Excavations Or Demolitions Of To Support Design Objectives. Such Analysis May Include Ground Penetrating Radar, Review Of Existing Va Documentation Or Other Viable Options To Verify These Utilities. 5. Attend All Design Review Meetings And Make All Necessary Site Visits During Design Phases To Gather Information Necessary From The Existing Site Conditions, Building Plans, Utility Plans, Etc. To Provide A Complete Assessment Of The Proposed Work. The Proposal Shall Include An Identified Number Of Visits. The Va Shall Provide Access To Hardcopy/electronic Files. The A/e Firm Shall Perform All Searches Of The Files For Any Required Reference Materials To Support Design Efforts. Limited Digital Drawings Are Available. 6. Attend Pre-bid Job Walk And Provide All Engineering Responses To Questions Asked By Potential Bidders And Issue Addendum When Necessary. 7. All Work Shall Be In Accordance With All Applicable Codes In The Department Of Veteran Affairs (va) Design Manuals And Va Publications (master Construction Specifications, Construction Standards, National Fire Protection Association (nfpa), Underwriters Laboratory, International Building Code Ibc, National Electric Code (nec), Building Codes And Standards, And Va Information Security Handbook 6500.6, Etc.) 8. All Work Containing Hazardous Materials Shall Be In Accordance With New York State Code Rule 56 Regarding Asbestos And Other Hazardous Materials, Ahera Regulations 40 Cfr Part 763.86, 763,87, And Osha 1926.1101(k)(1). 9. All Submissions Shall Include Physical And Digital Submissions Of Drawings And Specifications. 10. All Drawings Shall Be Submitted At Architectural E1 (30 X 42 ) For Full Sized Sets And Architectural C (18 X 24 ) For Half Sized Sets. All Sets Shall Be Bound. 11. All Cad Submissions Shall Be Provided In Autocad 2017 Unless Discussed Otherwise. Revit Models Shall Also Be Submitted In Addition To Cad Documents If Created. 12. The Autodesk Build Construction Management Platform (autodesk Construction Cloud Acc) Will Be Used For Information Sharing And Project Management Through The Design And Construction Phases. This Software Is Provided By The Va At No Additional Cost To The A/e. a. Platform Training Will Be Provided By The Va And Is Required By All Parties To Access. b. The A/e Shall, Upon Award, Provide A Comprehensive List Of Project Staff Who Will Need Access To Acc Including: i. Full Name ii. Company Name iii. Email Address iv. Role/position On The Project c. Completion Certificates Of Training By All Members Of The Team Shall Be Provided To The Cor Within 12 Calendar Days. d. Additional Members Can Be Added At Any Time Upon Written Request To The Cor. e. Acc Shall Be Used For All Digital Submissions, Official Project Correspondence, Submittals, Rfis, Schedules, Actionable Tasks, Photos, Surveys, Reports, Inspections, Etc. 13. Provide Design, Construction, And Post-construction Services As Listed Below. a Full Scope Of Services Including The Deliverables Will Be Included In The Formal Solicitation After A Review Of The Sf330s. Location canandaigua Vamc. 400 Fort Hill Avenue Canandaigua, Ny 14424 cost Range estimated Construction Cost Range: Between $5,000,000 And $10,000,000. type Of Contract Contemplated the Department Of Veterans Affairs Is Contemplating Awarding A Firm Fixed Price Contract. design Completion Period: The Department Of Veterans Affairs Requires Design And Contract Support Services. The A/e Shall Deliver 100% Bid Documents In 220 Calendar Days From The Notice To Proceed (ntp). selection Criteria Descriptions the Selection Criteria Descriptions Are Provided Below. professional Qualifications Necessary For Satisfactory Performance Of Required Services. offerors Will Be Evaluated In Terms Of The Qualifications, Competence And Experience Of The Key Personnel And Technical Team Proposed To Accomplish This Work. Key Personnel Are Individuals Who Will Have Major Contract Or Project Management Responsibilities And/or Will Provide Unusual Or Unique Expertise. Provide A Balanced Licensed And Or Certified Workforce In The Following Disciplines Architecture, Structural, Mechanical, Electrical, Interior Design, Environmental Services And Fire Protection Engineering As Needed. The Designers Of Record Shall Perform And Direct The Design Within Their Respective Discipline And Shall Sign And Seal The Drawings. The Lead Designer In Each Discipline Must Be Registered But Does Not Have To Be Registered In The Particular State Where The Project Is Located. submission Requirements: Provide Resumes For All Proposed Key Personnel. Resumes Are Limited To One Page Each And Should Cite Project Specific Experience And Indicate Proposed Role In This Contract. Provide Professional Registration, Certification, Licensure And/or Accreditation. Indicate Participation Of Key Personnel In Example Projects In The Sf-330 Part 1 Section G. (2) Specialized Experience And Technical Competence specialized Experience And Technical Competence Required For This Specific Project, Including, Where Appropriate, Experience In Energy Conservation, Pollution Prevention, Waste Reduction, And The Use Of Recovered Materials. offerors Will Be Evaluated On Specialized Experience And Technical Competence In The Performance Of Services Similar To Those Anticipated Under This Contract With Regard To: experience With Design Of Inpatient Medical Care Facilities. experience With Design Of Multifunctional Offices. experience With Specialized Hvac And Electrical Distribution Systems Design For Healthcare Facilities; experience In Providing Post Construction Award Services (shop Drawing Review, As-built Drawing And Quality Assurance Plan (qap) Preparation, Construction Inspection Services, And Operating And Maintenance Manuals). experience With Government Designs And Construction. experience With Extensive Site Survey Skills submission Requirements: Provide Up To Five (5) Projects Completed Or Substantially Completed Within The Past Five (5) Years That Best Illustrate Specialized Experience Of The Proposed Team In The Areas Outlined Above And The Scope Of Work Of The Project. Example Projects Shall Note Project S Square Footage. All Projects Provided In The Sf-330 Must Be Completed By The Office/branch/regional Office/individual Team Member Actually Proposed To Manage And/or Perform Work Under This Contract. To Enable Verification, Firms Should Include The Duns Number Along With Each Firm Name In The Sf-330 Part 1, Section F Item 25 Firms From Section C Involved In This Project, Block (1). Include A Contract Number Or Project Identification Number In Block 21. Include An E-mail Address, And Phone Number For The Point Of Contact In Block 23(c). Include In The Project Description The Contract Period Of Performance, Award Contract Value, Current Contract Value, A Summary Of The Work Performed That Demonstrates Relevance To Specialized Experience As Outlined Above. If The Contractor Served As A Subcontractor On A Project, Indicate The Value Of The Work They Provided Towards The Performance Of The Overall Project. If A Project Was Performed By A Joint Venture, And Not All Joint Venture Partners Are On The Team Proposed For This Contract, The Offeror/team Should Specifically Address The Work Performed By The Joint Venture Partner Offering/teaming On This Contract. Likewise, If The Offeror/team Member Worked As A Subcontractor On A Project, The Description Should Clearly Describe The Work Actually Performed By The Offeror/team Member And The Roles And Responsibilities Of Each On The Project, Rather Than The Work Performed On The Project As A Whole. If The Project Description Does Not Clearly Delineate The Work Performed By The Entity/entities Offering/teaming On This Contract, The Project Could Be Eliminated From Consideration. note: If The Offeror Is A Joint Venture, Information Should Be Submitted As A Joint Venture; However, If There Is No Information For The Joint Venture, Information Should Be Submitted For Either Joint Venture Partner, Not To Exceed A Total Of Five (5) Projects For This Criterion. Projects Shall Be Submitted On The Sf-330. For Submittal Purposes, A Task Order On An Idiq Contract Is Considered A Project, As Is A Stand-alone Contract Award. Do Not List An Idiq Contract As An Example Of A Completed Project. Instead, List Relevant Completed Task Orders Or Stand-alone Contract Awards That Fit Within The Definition Above. Examples Of Project Work Submitted That Do Not Conform To This Requirement Will Not Be Evaluated. failure To Provide Requested Data, Accessible Points Of Contact, Or Valid Phone Numbers Could Result In A Firm Being Rated Lower. all Information For Criterion 1 Should Be Submitted In Part 1, Section F Of The Sf-330. The Government Will Not Consider Information Submitted In Addition To Part 1, Section F In Evaluating Criterion 1. (3) Capacity this Factor Evaluates The Ability Of The Firm, Given Their Current Projected Workload And The Availability Of Their Key Personnel, To Accomplish The Possible Myriad Of Design Projects In The Required Time. submission Requirements: Describe The Firm S Ability To Concurrently Perform And Manage Multiple Projects In Different Locations To Meet Aggressive Schedules, Multiple Disciplines, And Control Costs And The Firm S Capacity To Accomplish Multiple Projects Simultaneously. the General Workload And Staffing Capacity Of The Design Office Will Be Evaluated. list Current Projects With A Design Fee Of Greater Than $20,000 Being Designed In The Firms Office. ii. Indicate The Firms Present Workload And The Availability Of The Project Team (including Sub-consultants) For The Specified Contract Performance Period; iii. Describe Experience In Successfully Delivering Projects Per Performance Schedule, Providing Timely Construction Support, And Successfully Completing Multiple Projects With Similar Delivery Dates (4) Past Performance: Visn2 Will Evaluate Past Performance On Recent And Relevant Contracts With Government Agencies (emphasis On Va Work) And Private Industry In Terms Of Cost Control, Quality Of Work, Compliance With Performance Schedules And A Record Of Significant Claims Against The Firm. i. Recent Is Defined As Performance Occurring Within Five (5) Years Of The Date Of This Sources Sought, Except Those Ongoing Projects Must Have Begun No Less Than One (1) Year Prior To The Issuance Of This Sources Sought. ii. Relevancy Is Defined As Performance Of Work On Projects That Are Similar In Scope Within A Va Hospital Setting In Relation To The Type Of Projects Anticipated Under The Resultant Contracts. respondents With No Previous Past Performance Shall State This When Addressing The Selection Criteria. Where There Is No Record Of Past Performance, The Proposal Will Be Evaluated Neither Favorably Nor Unfavorably. Superior Performance Ratings On Relevant Projects May Be Considered More Favorably In The Evaluation. submission Requirements: Submit A Completed Cpars/acass Evaluation For Each Project Under Criterion 1. If There Is Not A Completed Cpars/acass Evaluation, The Past Performance Questionnaire (ppq) Included In This Notice Is Provided For The Offeror Or Its Team Members To Submit To The Client For Each Project The Offeror Includes Under Criterion 1. An Offeror Shall Not Submit A Ppq When A Completed Cpars/acass Is Available. If A Cpars/acass Evaluation Is Not Available, Ensure Correct Phone Numbers And Email Addresses Are Provided For The Client Point Of Contact. Completed Ppqs Should Be Submitted With Your Sf-330. If The Offeror Is Unable To Obtain A Completed Ppq From A Client For A Project(s) Before The Response Date Set Forth In This Notice, Offerors Should Complete And Submit With Their Responses The First Page Of The Ppq (attachment), Which Will Provide Contract And Client Information For The Respective Project(s). Offerors May Submit A Ppq Previously Submitted Under A Different Notice/rfp (legible Copies Are Acceptable) As Long As It Is On The Same Form As Posted With This Synopsis. Offerors Should Follow Up With Clients/references To Ensure Timely Submittal Of Questionnaires. If Requested By The Client, Questionnaires May Be Submitted Directly To The Government's Point Of Contact, Network Contracting Office 2 Attn: Amanda Baumler Via Email At Amanda.baumler@va.gov Prior To The Response Date. Offerors Shall Not Incorporate By Reference Into Their Response Ppqs Or Cpars Previously Submitted In Response To Other A/e Services Procurements. However, This Does Not Preclude The Government From Utilizing Previously Submitted Ppq Information In The Past Performance Evaluation. (5) Location: Location In The General Geographical Area Of The Project And Knowledge Of The Locality Of The Project; Provided, That Application Of This Criterion Leaves An Appropriate Number Of Qualified Firms, Given The Nature And Size Of The Project iv. To Be Rated Acceptable For This Evaluation Factor, The A/e Firm Must Be Within 450 Miles From The Prime Contractor S Main Office Or Official Satellite Office To The Canandaigua Vamc At 400 Fort Hills Avenue. Canandaigua, Ny 14424. v. This Distance Is Determined According To Http://maps.google.com/ vi. This Factor Evaluates The Distance The Ae Firm's Design Office Or Official Satellite Office(s) From The Location Of Work (va Medical Center). Please Provide The Address (es) And Distance Of Your Closest Office To The Address Listed In Iv. Above. submission Requirements: Indicate Firms/teams Location, Including Main Offices, Branch Offices And Any Subconsultants Offices And Demonstrate How This Will Be Advantageous To The Government. (6) Veteran Owned: The Extent To Which Potential Contractors Identify And Commit To The Use Of Service-disabled Veteran-owned Small Businesses, Veteran-owned Small Businesses, And Other Types Of Small Businesses As Subcontractors. (7) Construction Period Services: Experience In Construction Period Services To Include Professional Field Inspections During The Construction Period, Review Of Construction Submittals, Support In Answering Requests For Information During The Construction Period, And Support Of Construction Contract Changes To Include Drafting Statements Of Work, And Cost Estimates Shall Be Included As An Evaluation Criterion When Construction Period Services Is Included In The Statement Of Work For A-e Services. (8) Experience Specific Experience And Qualifications Of Personnel Proposed For Assignment To The Project And Their Record Of Working Together As A Team. submission Requirements: Offerors Shall Submit Evidence Of Individuals Experience And Qualifications In Their Respective Fields. Additionally, Documentation Must Be Provided To Show These Individuals Have Worked Together As A Team On Previous Projects And Their Role. (completing Sections E, F, And G, On The Sf-330 Meets The Documentation Requirement). Furthermore, Offerors Shall Describe The Ability Of The Firm To Manage, Coordinate And Work Effectively With Team Members, Both Internal Staff And Consultants. Discuss The History Of Working Relationships With Team Members, Including Joint Venture Partners Where Applicable. (9) Reputation Reputation And Standing Of The Firm And Its Principal Officials With Respect To Professional Performance, General Management, And Cooperativeness. submission Requirements: Offerors Shall Provide Documentation (awards, Certificates, Publications, Commendations From Within The Community) As Evidence Of Reputation And Standing Of Its Firm. (10) - Claims - Record Of Significant Claims Against The Firm Because Of Improper Or Incomplete Architectural And Engineering Services. Offerors With Substantiated Claims Against The Firm As A Result Of Improper Architectural And Engineering Services Provided In The Last Three (3) Years. submission Requirements: Records And Any Other Documentation Of Substantiated Claims Highlighting Improper Or Incomplete Architectural Engineering Services Against The Firm Within The Last Three (3) Years. The Sf-330 Shall Contain A Statement Affirming That There Are No Records Of Significant Claims Because Of Improper Or Incomplete Architectural And Engineering Services. please Note: The Ae Evaluation Board Must Be Provided With Complete And Accurate Information For All Ten (10) Evaluation Factors Above In Order To Rank As Qualified And Eligible Firms. Therefore, The Ae Firm Must Expand Upon, As It Deems Necessary, On Any Evaluation Factor Not Well Demonstrated Or Addressed With Part 1a To Part Ig And Part Ii Of The Sf330. The Ae Firm Shall Use Part Ih And/or Use Additional Sheets To Supplement/address All Evaluation Factors To Clearly Demonstrate Its Qualifications. evaluation Scoring evaluation Factors 1, 2, 3, 5, 8, 9 And 10 Will Be Evaluated Using The Following Adjectival Ratings As Follows: outstanding: Proposal Meets Requirements And Indicates An Exceptional Approach And Understanding Of The Requirements. Strengths Far Outweigh Any Weaknesses. Risk Of Unsuccessful Performance Is Very Low. good: Proposal Meets Requirements And Indicates A Thorough Approach And Understanding Of The Requirements. Proposal Contains Strengths Which Outweigh Any Weaknesses. Risk Of Unsuccessful Performance Is Low. acceptable: Proposal Meets Requirements And Indicates An Adequate Approach And Understanding Of The Requirements. Strengths And Weaknesses Are Offsetting Or Will Have Little Or No Impact On Contract Performance. Risk Of Unsuccessful Performance Is Moderate. marginal: Proposal Does Not Clearly Meet Requirements And Has Not Demonstrated An Adequate Approach And Understanding Of The Requirements. The Proposal Has One Or More Weaknesses Which Are Not Offset By Strengths. Risk Of Unsuccessful Performance Is High. unacceptable: Proposal Does Not Meet Requirements And Contains One Or More Deficiencies. Proposal Is Not Awardable. The Firm S Proposal Demonstrates A Misunderstanding Of The Requirement And The Approach Fails To Meet Performance Standards. The Firm S Proposal Has Major Omissions And Inadequate Details To Assure Evaluators That The Offeror Has An Understanding Of Requirement. the Ratings Identified Below Were Used In The Evaluation Of Past Performance (criterion 4): substantial Confidence: Based On The Offeror S Recent/relevant Performance Record, The Government Has A High Expectation That The Offeror Will Successfully Perform The Required Effort. No Doubt Exists Based On The Offeror S Past Performance That They Can Satisfy The Requirements Of The Contract. satisfactory Confidence: Based On The Offeror S Recent/relevant Performance Record, The Government Has A Reasonable Expectation That The Offeror Will Successfully Perform The Required Effort. Little Doubt Exists Based On The Offeror S Past Performance That They Could Satisfy The Requirements Of The Contract. unknown Confidence (neutral): No Recent/relevant Performance Record Is Available Or The Offeror S Performance Record Is So Sparse That No Meaningful Confidence Assessment Rating Can Be Reasonably Assigned. limited Confidence: Based On The Offeror S Recent/relevant Performance Record, The Government Has Little Expectation That The Offeror Will Be Able To Successfully Perform The Required Effort. Some Doubt Exists Based On Past Performance That They Could Satisfy The Terms And Conditions Of The Contract. no Confidence: Based On The Offeror S Recent/relevant Performance Record, The Government Has Little Expectations That The Offeror Will Be Able To Successfully Perform The Required Effort. Significant Doubt Exists Based On The Offeror S Past Performance That They Can Satisfy The Requirements Of The Contract. limitations 852.219-73 Va Notice To Total Set-aside For Verified Service-disabled Veteran-owned Small Businesses (nov 2022) (a) Definition. For The Department Of Veterans Affairs, Service-disabled Veteran-owned Small Business Concern Or Sdvosb : (1) Means A Small Business Concern - (i) Not Less Than 51 Percent Of Which Is Owned By One Or More Service-disabled Veterans Or, In The Case Of Any Publicly Owned Business, Not Less Than 51 Percent Of The Stock Of Which Is Owned By One Or More Service-disabled Veterans Or Eligible Surviving Spouses (see Vaar802.101, Surviving Spouse Definition); (ii) The Management And Daily Business Operations Of Which Are Controlled By One Or More Service-disabled Veterans (or Eligible Surviving Spouses) Or, In The Case Of A Service-disabled Veteran With Permanent And Severe Disability, The Spouse Or Permanent Caregiver Of Such Veteran; (iii) The Business Meets Federal Small Business Size Standards For The Applicable North American Industry Classification System (naics) Code Identified In The Solicitation Document; (iv) The Business Has Been Verified For Ownership And Control Pursuant To 38 Cfr Part 74 And Is Listed In Va's Vendor Information Pages (vip) Database At Https://www.vetbiz.va.gov/vip/; And (v) The Business Will Comply With Vaar Subpart 819.70 And Small Business Administration (sba) Regulations Regarding Small Business Size And Government Contracting Programs At 13 Cfr Parts 121 And 125, Provided That Any Reference Therein To A Service-disabled Veteran-owned Small Business Concern Or Sdvo Sbc, Is To Be Construed To Apply To A Va Verified And Vip-listed Sdvosb, Unless Otherwise Stated In This Clause. (2) The Term Service-disabled Veteran Means A Veteran, As Defined In 38 U.s.c. 101(2), With A Disability That Is Service-connected, As Defined In 38 U.s.c. 101(16). (3) The Term Small Business Concern Has The Meaning Given That Term Under Section 3 Of The Small Business Act (15 U.s.c. 632). (4) The Term Small Business Concern Owned And Controlled By Veterans With Service-connected Disabilities Has The Meaning Given The Term Small Business Concern Owned And Controlled By Service-disabled Veterans Under Section 3(q)(2) Of The Small Business Act (15 U.s.c. 632(q)(2)), Except That For A Va Contract The Firm Must Be Listed In The Vip Database (see Paragraph (a)(1)(iv) Of This Clause). (b) General. (1) Offers Are Solicited Only From Vip-listed Sdvosbs. Offers Received From Entities That Are Not Vip-listed Sdvosbs At The Time Of Offer Shall Not Be Considered. (2) Any Award Resulting From This Solicitation Shall Be Made To A Vip-listed Sdvosb Who Is Eligible At The Time Of Submission Of Offer(s) And At The Time Of Award. (3) The Requirements In This Clause Apply To Any Contract, Order Or Subcontract Where The Firm Receives A Benefit Or Preference From Its Designation As An Sdvosb, Including Set-asides, Sole Source Awards, And Evaluation Preferences. (c) Representation. Pursuant To 38 U.s.c. 8127(e), Only Vip-listed Sdvosbs Are Considered Eligible To Receive Award Of A Resulting Contract. By Submitting An Offer, The Prospective Contractor Represents That It Is An Eligible Sdvosb As Defined In This Clause, 38 Cfr Part 74, And Vaar Subpart 819.70. (d) Agreement. When Awarded A Contract Action, Including Orders Under Multiple-award Contracts, An Sdvosb Agrees That In The Performance Of The Contract, The Sdvosb Shall Comply With Requirements In Vaar Subpart 819.70 And Sba Regulations On Small Business Size And Government Contracting Programs At 13 Cfr Part 121 And Part 125, Including The Non-manufacturer Rule And Limitations On Subcontracting Requirements In 13 Cfr 121.406(b) And 13 Cfr 125.6. Unless Otherwise Stated In This Clause, A Requirement In 13 Cfr Parts 121 And 125 That Applies To An Sdvo Sbc, Is To Be Construed To Also Apply To A Vip-listed Sdvosb. For The Purpose Of Limitations On Subcontracting, Only Vip-listed Sdvosbs (including Independent Contractors) Shall Be Considered Eligible And/or Similarly Situated (i.e., A Firm That Has The Same Small Business Program Status As The Prime Contractor). An Otherwise Eligible Firm Further Agrees To Comply With The Required Certification Requirements In This Solicitation (see 852.219-75 Or 852.219-76 As Applicable). These Requirements Are Summarized As Follows: (1) Services. In The Case Of A Contract For Services (except Construction), The Sdvosb Prime Contractor Will Not Pay More Than 50% Of The Amount Paid By The Government To The Prime For Contract Performance To Firms That Are Not Vip-listed Sdvosbs (excluding Direct Costs To The Extent They Are Not The Principal Purpose Of The Acquisition And The Sdvosb/vosb Does Not Provide The Service, Such As Airline Travel, Cloud Computing Services, Or Mass Media Purchases). When A Contract Includes Both Services And Supplies, The 50 Percent Limitation Shall Apply Only To The Service Portion Of The Contract (2) Supplies/products. (i) In The Case Of A Contract For Supplies Or Products (other Than From A Non-manufacturer Of Such Supplies), The Sdvosb Prime Contractor Will Not Pay More Than 50% Of The Amount Paid By The Government To The Prime For Contract Performance, Excluding The Cost Of Materials, To Firms That Are Not Vip-listed Sdvosbs. When A Contract Includes Both Supply And Services, The 50 Percent Limitation Shall Apply Only To The Supply Portion Of The Contract. (ii) In The Case Of A Contract For Supplies From A Non-manufacturer, The Sdvosb Prime Contractor Will Supply The Product Of A Domestic Small Business Manufacturer Or Processor, Unless A Waiver As Described In 13 Cfr 121.406(b)(5) Has Been Granted. Refer To 13 Crf 125.6(a)(2)(ii) For Guidance Pertaining To Multiple Item Procurements. (3) General Construction. In The Case Of A Contract For General Construction, The Sdvosb Prime Contractor Will Not Pay More Than 85% Of The Amount Paid By The Government To The Prime For Contract Performance, Excluding The Cost Of Materials, To Firms That Are Not Vip-listed Sdvosbs. (4) Special Trade Construction Contractors. In The Case Of A Contract For Special Trade Contractors, No More Than 75% Of The Amount Paid By The Government To The Prime For Contract Performance, Excluding The Cost Of Materials, May Be Paid To Firms That Are Not Vip-listed Sdvosbs. (5) Subcontracting. An Sdvosb Must Meet The Naics Size Standard Assigned By The Prime Contractor And Be Listed In Vip To Count As Similarly Situated. Any Work That A First Tier Vip-listed Sdvosb Subcontractor Further Subcontracts Will Count Towards The Percent Of Subcontract Amount That Cannot Be Exceeded. For Supply Or Construction Contracts, The Cost Of Materials Is Excluded And Not Considered To Be Subcontracted. When A Contract Includes Both Services And Supplies, The 50 Percent Limitation Shall Apply Only To The Portion Of The Contract With The Preponderance Of The Expenditure Upon Which The Assigned Naics Is Based. For Information And More Specific Requirements, Refer To 13 Cfr 125.6. (e) Required Limitations On Subcontracting Compliance Measurement Period. An Sdvosb Shall Comply With The Limitations On Subcontracting As Follows: _x_by The End Of The Base Term Of The Contract Or Order, And Then By The End Of Each Subsequent Option Period; Or __by The End Of The Performance Period For Each Order Issued Under The Contract. (f) Joint Ventures. A Joint Venture May Be Considered Eligible As An Sdvosb If The Joint Venture Is Listed In Vip And Complies With The Requirements In 13 Cfr 125.18(b), Provided That Any Requirement Therein That Applies To An Sdvo Sbc Is To Be Construed To Apply To A Vip-listed Sdvosb. A Joint Venture Agrees That, In The Performance Of The Contract, The Applicable Percentage Specified In Paragraph (d) Of This Clause Will Be Performed By The Aggregate Of The Joint Venture Participants. (g) Precedence. The Va Veterans First Contracting Program, As Defined In Vaar 802.101, Subpart 819.70, And This Clause, Takes Precedence Over Any Inconsistencies Between The Requirements Of The Sba Program For Sdvo Sbcs, And The Va Veterans First Contracting Program. (h) Misrepresentation. Pursuant To 38 U.s.c. 8127(g), Any Business Concern, Including All Its Principals, That Is Determined By Va To Have Willfully And Intentionally Misrepresented A Company's Sdvosb Status Is Subject To Debarment From Contracting With The Department For A Period Of Not Less Than Five Years (see Vaar 809.406-2 Causes For Debarment). submission Requirements: unless Paper Offers Are Specifically Authorized In An Individual Solicitation, All Responses To Solicitations Must Be Submitted Electronically As Described Below. Responses Submitted In A Paper Form Are Unacceptable. Failure To Comply With This Requirement May Jeopardize The Possibility Of Receiving An Award Due To Noncompliance With The Submission Requirements. email Submission Requirements Interested Firms Having The Capabilities To Perform This Work Must Submit: One (1) Electronic Sf 330, Including Parts I And Ii, And Attachments (if Any) To Amanda.baumler@va.gov No Later Than 10am, Eastern Standard Time (est) On Tuesday, January 21st 2025 Submittals Received After The Date And Time Identified Will Not Be Considered. The Submittal Will Be Date And Time Stamped By The Microsoft Email System And Will Be The Official Record Of Receipt For The Submission. All Sf 330 Submissions Shall Be Clearly Indicated In Subject Line, Displaying The Solicitation Number And Project Number And Title (abbreviated And Shortened Is Okay). Submission Is To Be No More Than A Total Of Fifty (50) Pages; Size Of Emails Is Not To Exceed 10 Megabytes (mb). If More Than One Email Is Sent, Please Number Emails In Subject Line As 1 Of 2, 2 Of 2 Etc. all Sf 330 Submissions Must Include The Following Information Either On The Sf 330 Or By Accompanying Document: 1. Cover Page With Solicitation Number, Project Number And Title 2. Table Of Contents 3. Copy Of Valid State Registration For Each Lead Designer 4. Copy Of Current Https://veterans.certify.sba.gov/ Sdvosb/vosb Certification 5. Duns Number 6. Cage Code 7. Tax Id Number 8. Email Address And Phone Number (including The Area Code) Of The Primary Point Of Contact.

Details: This Pre-solicitation Notice Is Not A Request For Proposal. All information Needed To Submit Sf330 Documents Are Contained herein. No Additional Solicitation Package Or Technical information Will Be Issued. project: 557-24-102 Correct Critical Fca Sanitary And Storm Water Deficiencies work Location: Carl Vinson Va Medical Center, Dublin, Ga 31021 estimated/target Completion Period: 240 Calendar Days After Award. construction Magnitude: Between $5,000,000 And $10,000,000. naics: 541330 - Engineering Services small Business Standard: $25.5 Million set-aside: 100% Service-disabled Veteran-owned Small Business (sdvosb) site Visits Will Not Be Arranged During This Phase. the Anticipated Award Date Of The Proposed A-e Contract Is On Or Before September 30, 2025. sf 330 Date Of Receipt/due Date: Interested Firms Having The Capabilities To Perform This Work Must Submit One (1) Electronic Sf 330 And Attachments (if Any) No Later Than (nlt) 12:00 Pm (est) January 13, 2025. ***attention*** Acknowledgement E-mails Will Be Sent From The Co Upon Receipt Of A Submission. If An Acknowledgement Is Not Returned, The Firm Should Contact The Co At Christopher.jenkins@va.gov And 478-595-2794. project Overview: the Purpose Of This Design Project Is To Provide For The Design To Repair The Campus Storm Sewage System From Roof Gutters, Downspouts, And Ground Connections Through Terracotta Pipe To Original Brick Manholes. Initial Smoke Study Shall Inform A Phased Construction Approach.storm System From Ground Connection To First Manhole Is Original Terracotta Pipe In Most Areas And Manholes Are Original Brick. This Original System Is In Need Of Replacement To Include Mainlines, Laterals, And Manholes. Newer Concrete Piping Through To Outfalls At Lake Leisure Should Be Tested/analyzed, But May Remain In System If Deemed Acceptable Condition. sanitary Lift Station On Site Consistently Reads A Higher Utilization Number Than Incoming Water Usage, Likely Indicating An Interconnection With The Storm System. An Inflow And Infiltration Study Shall Be Conducted To Determine Where The Storm System Is Interconnected With Sanitary System. Smoke Test Shall Include Camera Routing Through Mains Where Required To Identify Leaks, Defects, And Improper Connections. Utilize Nassco Specifications For Testing Procedures. An Analysis To Determine Anticipated Load And Outflow Sizing Shall Be Completed Prior To Design To Review Pipe Sizes. Updated Storm Water System Shall Rely Upon Main Pond, Lake Leisure, To The Greatest Extent Possible, Minimizing The Need For Additional Retention/detention Ponds, Swales, Etc. After Smoke Study Is Completed, The Results Shall Be Used To Inform And Recommend System Repairs And Replacements. A Phased Construction Will Be Designed, With The First Phase Correcting Any Infiltration Of Storm Water Into The Sanitary System, As Described In Below Fca Deficiencies. Additional Critical Repairs And Replacements Shall Be Designed To Fit Within Approved Construction Budget. Work Not Completed In This Project Will Be Moderately Scoped Out Into Phases For Further Future Design And Construction Efforts. sdvosb Set-aside: this Requirement Is A 100% Set-aside For Service-disabled Veteran-owned Small Businesses Under The Authority Of 38 U.s.c. 8127(d). To Be Eligible For Award The Sdvosb You Must Be Considered Small Under The Relevant Naics Code. Sdvosb Contractors Must Be Verified And Viewable In Sba Vetcert: Https://veterans.certify.sba.gov/ Prior To Submission Of Proposal And Prior To Award Of Contract With Vaar 804.1103-70. Status As A Qualified Sdvosb Concern Is Under The Authority Of 38 Cfr Part 74 In Accordance With The Va Acquisition Regulation (vaar) Part 819. Any Person, Persons, Or Business Entity Suspected Of Misrepresenting Itself For The Purpose Of Securing A Government Contract May Be Criminally Investigated And Prosecuted For Fraud Against The United States Of America. Parties Found Misrepresenting Their Status Also Risk Debarment From Further Government Contracts. Eligibility Determination Is Performed By The Center For Veterans Enterprise (cve). Eligible Sdvosb Concerns Must Also Be Registered At The Following Websites: system For Award Management (sam): Https://www.sam.gov vets-4212 Federal Contractor Reporting Https://www.dol.gov/agencies/vets/programs/vets4212 important Notice: Prior To Submitting A Proposal Under This Sdvosb Set- Aside Solicitation; Offerors Must Apply For And Receive Verification From The Department Of Veteran Affairs Center For Veterans Enterprise (cve) In Accordance With 38 Cfr Part 74 And Vaar 819.70 By Submission Of Documentation Of Veteran Status, Ownership And Control Sufficient To Establish Appropriate Status. All Offerors Are Urged To Contact The Cve And Submit The Aforementioned Required Documents To Obtain Cve Verification Of Their Sdvosb Status If They Have Not Already Done So. for A Service-disabled Veteran Owned Small Business (sdvosb) To Be Considered As A Prospective Contractor, The Firm, Including Joint Ventures, Must Be Verified And Registered In The Department Of Veteran Affairs (va) Office Of Small & Disadvantaged Business Utilization (osdbu) Sba Vetcert: Https://veterans.certify.sba.gov/ And Registered In The System For Award Management (sam) Database (www.sam.gov) At Time Of Submission Of Their Qualifications. Failure Of A Prospective Sdvosb To Be Verified By The Center For Veterans Enterprise (cve) At The Time The Sf 330 Is Submitted Shall Result In Elimination From Consideration. All Joint Ventures Must Be Cve Verified At Time Of Submission And Submit Agreements That Comply With 13cfr 125.15 Prior To contract Award. in Order To Assure Compliance With Far Clauses, 52.219-14 Limitations On subcontracting (deviation 2019-01) And Vaar 852.219-10, Va Notice Of Total service-disabled Veteran-owned Small Business Set-aside (jul 2019) (deviation), All Firms Submitting A Sf 330 For This Pre-solicitation Notice Are required To Indicate What Percentage Of The Cost Of Contract Performance Will Be Expended On The Concerns Employees And In Which Discipline(s) And Percentage Of Cost Of Contract Performance To Be Expended (and In What Disciplines) By Any Other Consultant/subcontractor Or Otherwise Used Small Or Large Business Entity(s). Any Consultant/subcontractor Or Otherwise Business Entity(s) Used Must Be Identified By Name, Office Location And Size/type Of Business (i.e. Sdvosb, Vosb, 8(a), Small, Large, Etc.). Failure To Provide This Information Will Deem The Firm S Sf 330 Submittal As Nonresponsive And Preclude Further Evaluation. far Part 36.6 (brooks Act) Selection Procedures Apply. The A-e Services Listed Herein Is Being Procured In Accordance With The Brooks Act (public Law 92-582) As Implemented In Far 36.6 And Vaar 836.6. Pursuant To Far, The Firm Responding To This Requirement Must Be Permitted, By Law, To Practice The Professions Of Architecture Or Engineering And Meet All Required Qualifications For The State Of Georgia. sf 330 Selection Criteria: The Va Will Utilize The Following Selection Criteria In relative Order Of Importance. specialized Experience And Technical Competence In The Type Of Work Required. submission Requirements: sf 330 Information Shall Be Provided Per The Latest Format From The Gsa Library Located At Https://www.gsa.gov/forms-library/architect-engineer-qualifications. complete Using Blocks F. And H. Of The Sf330 Form. Complete Block F. For Each Relevant Project. Complete Block H. Summary Sheet For The Offeror And Each Key Consultant; Each Summary Sheet Shall Be Not More Than One (1) Page In Length, And No More Than Ten (10) Pages Total. submit A Minimum Of Three (3) But No More Than Four (4) Projects Similar To Work In The Solicitation. projects Submitted Must Be Recent. Recent Is Defined As Services Provided Within The Last Five (5) Years. at Minimum, Two (2) Projects Must Have Construction Completed Or Construction Substantially (75%+) Complete. projects/data Submitted Shall Be Projects With Total Construction Costs Of $2,500,000 Dollars And Greater. projects May Include Federal, State, Or Local Government, As Well As Private Industry Projects. Offerors Are Responsible For Providing Project Description And Applicable Information In Sufficient Detail To Permit Evaluation Of Project Relevancy Versus These Minimum Requirements. basis Of Evaluation: specialized Experience Pertains To The Types, Size, Volume, Budget, And Complexity Of Work Previously Or Currently Being Performed By The Offeror That Is Comparable To The Work Covered By This Solicitation. Specialized Experience May Also Include Unique Conditions, Considerations, Or Circumstances Encountered That Are Relevant To This Solicitation, Such As Large Campus Sanitary And Storm Water Repairs And Replacement. specialized Experience Does Not Include Overseas Offices For Projects Outside The United States, Its Territories, Or Possessions; Nor Does It Include Subsidiaries That Are Not Normally Subject To Management Decisions, Accounting, And Policies, Or A Holding Or Parent Company Or An Incorporated Subsidiary That Operates Under A Firm Name Different From The Parent Company. technical Competence Includes Construction And Design Projects Similar In Project Scope, Size, Construction Features, Dollar Value, And Complexity Of That Listed In The Solicitation. Technical Competence Also Includes Experience In Energy Conservation, Pollution Prevention, Waste Reduction, And The Use Of Recovered Materials. similar Complexity Is Considered Projects Of An Operational, Construction, Or Design Likeness To The Work Covered In This Solicitation. offerors Unable To Demonstrate Proven Specialized Experience And Technical Competence May Be Considered Non-responsive Or Scored Negatively. higher Ratings May Be Given For Projects Completed On Va Campuses. failure To Provide Requested Data May Negatively Impact An Offeror's Rating. past Performance On Contracts With Government Agencies And Private Industry In Terms Of Cost Control, Quality Work, And Compliance With Performance Schedules. submission Requirements: complete Using Block H. Of The Sf 330 Describing The Offeror S Past Performance. The Summary Sheet Shall Be Not More Than Two (2) Pages In Length. provide A Contractor Performance Assessment Reporting System (cpars) Report For Each Submitted Project Under Specialized Experience Criteria, Above. Cpars Must Be Incorporated Into The Submission; Cpars Will Not Count Towards Page Limitations. If The Project Does Not Have Cpars, Then A Past Performance Questionnaire (ppq) May Be Used. basis Of Evaluation: past Performance Is A Measure Of The Degree To Which An Offeror Satisfied Its Customers Needs And Requirements And Compliance With Applicable Codes, Standards, Laws, And Regulations. The Evaluation Of Past Performance Will Include But Is Not Limited To: the Customer S Assessment Of The Offeror's Commitment To Customer Satisfaction; timely Delivery Of Quality Work; the Offeror's Record Of Conforming To Contract Requirements And Applicable Codes, Standards, Laws And Regulations; successful Implementation Of A Quality Control Plan And Quality Control Procedures; addressing Design Errors/omissions Timely; adherence To Approved Schedules; And, history Of Timely And Professional Communication And Cooperative Behavior. include Information On Problems (errors/omissions) Found, How The Problems Were Corrected, And The Impacts To The Successful Completion Of The Project (time Delays, Cost Impacts, Design Modifications, Etc.). provide Information Supporting Favorable Cost Control, Quality Of Design Submissions, And Schedule Compliance. offeror Risks Receiving A Lower Rating If Fewer Than Three (3) Ppqs Are Provided Or If The Ppqs Were Not Completed By Project Point Of Contact. include A Discussion On The Offeror S Record Of Significant Claims For Improper Or Incomplete Design Services. higher Ratings May Be Given For Work Performed On Va Medical Center Campuses. failure To Provide Requested Data Or To Provide An Accessible Point Of Contact (poc) May Negatively Impact An Offeror's Rating. failure To Demonstrate Proven Competence To Perform Projects Like The Requirements Of The Solicitation May Be Considered Ineligible For Award. professional Qualifications Necessary For Satisfactory Performance Of Required Services. submission Requirements: complete Using Block E. Of The Sf 330. Submit Personal Resumes And Relevant Information For Key And Responsible Personnel. Block E. Shall Be Not More Than One (1) Page In Length Per Individual, And Not More Than Fifteen (15) Total Pages. basis Of Evaluation: evaluation Of Professional Qualifications Will Include But Is Not Limited To The Subjective Assessment Of The Offeror's Individual Resumes. the Offeror Shall Have A Professional Engineer, Currently Registered In Any State Or Territory Of The United States, Knowledgeable In Their Registered Design Discipline, To Be The Lead Designer Responsible For Reviewing And Approving Design Submissions. the Offeror Shall Have A Professional Engineer, Qualified And Knowledgeable Of State And Local Regulations, Be The Lead Designer Responsible For Reviewing And Approving Design Submissions And Facilitating Permit Documentation (depending On The Nature Of The Design I.e. Environmental, Stormwater, Etc.). key Personnel To Provide Qualifications To Meet This Criterion Include Principal(s), Project Manager(s), Key Consultants, Individuals Responsible For Implementation Of The Design Qa/qc Plan, And Other Individuals That Are Responsible Or Accountable For Design Submissions. the Offeror Shall Describe And/or Depict Which Projects And How Well Key Personnel Of The Design Team Have Worked Together. higher Ratings For This Criterion May Be Given When The Offeror's Specific Personnel Demonstrate Relevant Credentials, Such As Involvement And Degree Of Involvement In Professional Organizations, Research/publications, Code/standard Body Involvement, Etc. offerors Unable To Demonstrate Professional Qualifications Necessary To Perform Designs May Be Considered Non-responsive . failure To Provide Sufficient Data Supporting Professional Qualifications May Negatively Impact An Offeror's Rating. location In The General Geographical Area Of Dublin, Ga And Knowledge Of The Locality Of The Carl Vinson Va Medical Center Facility: submission Requirements: complete Using Block H. Of The Sf 330. Provide A Narrative That Describes The Offeror S Experience In The Dublin, Ga Geographical Area. Narrative Shall Be Not More Than One (1) Page In Length. basis Of Evaluation: offerors Will Be Subjectively Evaluated Based On Their Knowledge (and The Knowledge Of Subcontractors) Of Unique Conditions Or Variables, Such As Familiarity Of Applicable Codes, Regulations, Construction Market & Labor Conditions, Geotechnical, Seismic, Weather, Environmental, Or Other Unique Considerations Found In Dublin, Ga And The Middle Georgia Area. if Prior Experience In Dublin, Ga Is Minimal, Describe How The Design Team Plans To Obtain Specific Knowledge Of Local Conditions Or Project Features Required For A Compliant Design. data From Other Projects And Locations Are Acceptable To Highlight Knowledge Of The Dublin, Ga Geographical Area Or Areas Of Similar Nature. offerors That Submit Relevant Projects Outside Of The Dublin, Ga Geographical Area May Be Given A Lower Rating Than Projects Within The Dublin, Ga Geographical Area. capacity To Accomplish The Work In The Required Time. submission Requirements: complete Using Block H. Of The Sf 330. Provide A Narrative That Describes The Offeror S Work Capacity. basis Of Evaluation: identify The Offeror S Past, Present And Projected Future Workload, Including Va Contracts Over The Previous 12 Months. describe The Offeror S Capacity To Incorporate This Solicitation S Work While Meeting Prescribed Dates For Current Workload. Each Key Team Member To Include % Of Available Capacity To Take On New Projects. evaluation Of This Factor Will Be An Assessment Of The Offeror S Ability To Complete Design Documents Within The Period Of Performance And Meet Solicitation Requirements. data Is Acceptable In Tables Or Charts. higher Ratings May Be Given For This Criterion When Information Provided Exceeds The Minimum Requirements. the Extent To Which Potential Contractors Identify And Commit To The Use Of Service-disabled Veteran-owned Small Businesses, Veteran-owned Small Businesses, And Other Types Of Small Businesses As Subcontractors: submission Requirements: complete Using Block H. Of The Sf 330. Provide A Narrative That Discusses The Offeror S Approach. Narrative Shall Be Not More Than One (1) Page In Length. offeror S Shall Complete And Submit The Following Statement In Block H. : I [signatory Authority], Of [offeror Company Or Joint Venture] Certify That The Team Proposed To Perform Under This Requirement Demonstrates The Capability Of 50% Sdvosb Performance In Compliance Of 48 Cfr 852.219-10 . basis Of Evaluation: offerors Shall Be Evaluated Based On Their Utilization Plans For Service-disabled Veteran-owned Small Businesses (sdvosbs), Veteran-owned Small Businesses (vosbs), Or Other Types Of Small Businesses. .