Electrical Tenders

Details: Description Request For Quotation Date: January 30, 2025 Rfq No. 2025-mc-62 _____________________________ _____________________________ _____________________________ _____________________________ (company Name & Address) Sir/madam: The Philippine International Convention Center, Inc. (picci), Through Its Bids And Awards Committee, Intends To Procure Supply Of Labor And Materials For The Cleaning Of Cistern Tanks At The Delegation Parking, Powerhouse And Forum, With An Approved Budget For Contract (abc) Of Four Hundred Thousand Pesos (₱400,000.00), Vat Inclusive, Which Will Be Undertaken In Accordance With Section 53.9 Of The 2016 Revised Implementing Rules And Regulations Of Republic Act No. 9184. Please Quote Your Best Offer For The Service/s Described Herein, Subject To The Terms Of Reference Provided For This Rfq. Submit Your Quotation/offer Duly Signed By You Or Your Duly Authorized Representative Not Later Than 3:00 P.m. Of _february 7, 2025_. A Copy Of The Following Shall Be Submitted Along With Your Quotation/offer: A. 2025 Mayor’s/business Permit; In Case The Mayor’s Permit Is Pending Renewal, Attach Proof Of Renewal I.e. Or/sales Invoice; B. Bir Registration Certificate; C. Philgeps Registration Number; D. Omnibus Sworn Statement; And E. Copy Of The Terms Of Reference Duly Signed On All Pages. Open Quotations May Be Submitted Manually Or Through Email At The Address And Contact Numbers Indicated Below. For Any Clarifications, You May Contact Ms. Carreen M. Mangaya At Telephone No. (02) 8789-4761 Or Email Address At Cmmangaya@picc.gov.ph Kristine Angelica E. Agujo Head, Bac Secretariat/ Procurement Unit Rfq No. 2025-mc-62 Terms Of Reference I. Project Title: Supply Of Labor And Materials For The Cleaning Of Cistern Tanks At The Delegation Parking, Powerhouse And Forum Ii. Approved Budget For Contract (abc): Four Hundred Thousand Pesos (₱ 400,000.00), Vat Inclusive. Iii. General Scope Of Works: The Works Include The Supply Of All Materials, Tools, Labor, Equipment And Other Services Necessary For The Cleaning And Maintenance Of The Delegation, Powerhouse And Forum Cistern Tank. The Following Features Of The Work Shall Be Performed, But Not Limited To The Following: 1.0 General Requirements: 1.1 Mobilization Manpower, Tools, Materials And Equipment. 1.2 Securing Of Surety, Performance And Guarantee Bonds 1.3 Health And Safety Requirements - Personal Protective Equipment (ppe). All Workers Shall Wear Their Company Uniform. - The Contractor Shall Install Two (2) – Safety Signage, Same As The Picc Standard Signage, 22” X 32”, Printed In Sintra Board. Text To Be Provided By Picc. - The Contractor Shall Provide Necessary Safety Equipment Needed Like Exhaust System During Actual Cleaning. 1.4 Demobilization Manpower, Tools, Equipment, Including Hauling-out Of Debris. 2.0 Cleaning Of Cistern Tanks (delegation, Powerhouse And Forum) 2.1 Draining/pumping Of The Tank’s Water Residual Content To A Considerable Level To Facilitate Efficient, Effective And Economical Cleaning System. Draining Should Be Properly Coordinated So That All Water To Be Re-use Or For Watering The Plants. 2.2 Provide Submersible Pumps With Hose, High Pressure Washer, Exhaust Ventilation Units, Ladders And Lights. 2.3 Brushing And Scraping Of Slime, Scales And Other Sedimentary Deposits At The Tanks Bed And Laterals (wall Chambers). 2.4 De-rusting Of Equalizing Pipe, Supply Lines, Domestic Pumps Suction Lines Inside The Tank. Manhole Steel Covers Should Be De-rusted/repainted With Primer And Final Coated With Qde. 2.5 Mixing/stirring Of Water With Loose Dirt/scales And Slime For Siphoning. 2.6 Manual Cleaning Of Left-over Dirt (cannot Be Pumped-out). 2.7 Rinsing The Tanks Inner Walls With Plain Water Using High Pressure Washer (first Stage). 2.8 Rinsing The Tank With Chlorinated Water Of Higher Concentration Than Maynilad To Effect Safe Sanitation On The Tanks Inner Wall Using Higher Pressure Washer. 2.9 Neutralizing The Tanks Chemical Toxity To Safest And Most Acceptable Level By Re-washing Or Further Rinsing With Plain Water. 2.10 Testing And Commissioning. Testing Shall Be Done By Taking Samples Of Water For Testing On Approved Water Testing Laboratories For Bacteriological And Physicochemical Analysis Of Drinking Water. If The Result Of Water Testing Failed, Same Procedure Of Cleaning Shall Be Done Before Testing Is Again Administered. Result Of Water Testing Shall Be Submitted A Week After Refilling The Cistern Tank Or The Soonest Possible Time. 3.0 Repainting Of The Manhole Cover Of The Delegation, Powerhouse And Cistern Tanks With Top Coat Of Elastomeric Paint. 4.0 Repainting Of The Exterior Wall Of The Power House And Forum (including Generator Set And Pressure Tank Room) Cistern Tank. Use Semi-gloss Latex Paint. 5.0 Application Of Sealant For All Manhole Covers. Sealant To Be Used Shall Be Moisture-curing And Elastic Joint Sealant. 6.0 Restoration Of All Affected Areas (perimeter Of Cistern Tanks) 7.0 Cleaning And Hauling Out Of All Garbage. Iv. General Conditions: A. Interpretation 1. The Contract Documents, Specifications And Drawings Are Mutually Complimentary. What Is Noted In One Although Not Shown In Other Shall Be Considered Contained In All, In Case Of Conflict. The Specifications Shall Prevail Over The Drawings. The Documents Forming The Contract Shall Be Interpreted In The Following Order Of Priority: A. Contract/construction Agreement B. Contractor’s Bid C. Special Conditions Of The Contract D. Specifications E. Drawings F. Bill Of Quantities G. Any Other Document Listed In The Special Conditions Of The Contract As Forming Part Of The Contract. 2. The Contractor Shall Examine All The Issued Documents Relating To The Work And Must Have Verified All The Existing Conditions At The Site. No Considerations Will Be Given For Any Alleged Misunderstanding Of Misinterpretations Of The Specifications And Materials To Be Used Or Work To Be Done. 3. All Works Should Be Properly Coordinated With Picc Representative/bsd Project-in-charge. 4. All Cleaning System (excluding Of Water Pumping) Should Be Done Manually And Avoid Too Much Vibration Causing Work Process That Can Be Detrimental Effect To The Concrete Walls And Bed. Furthermore, All Chemicals To Be Used For The Cleaning And Sanitizing Works Should Have Been Tested/proven Safe For Such Application In The Industry, And For Approval Of The Picc Project-in-charge. 5. The Tank Should Be Inspected By The Project-in-charge Or His Authorized Representative To Determine Its Condition And Readiness For The Refilling. The Interior Wall Should Be Thoroughly Cleaned, Sanitized And Well Rinsed Prior To Re-watering Or Refilling. 6. Work Completion Time Should Be Religiously Followed By The Contractor. 7. Cost Of Re-work/restoration On Damage/s Due To Contractor’s Poor Workmanship Or Negligence Should Be Done By The Contractor. 8. The Contractor Should Free Picc From Any Problem, Legal Suit/s Or Whatsoever That May Arise Or Claims Or All Of The Personnel Employed By The Contractor Of The Project. 9. For Suppliers And Contractors With On-going Deliveries Of Projects At The Picc Who Had Incurred Late Deliveries Or Negative Slippage In Their Activities Or Were Rated “unsatisfactory” In Their Previous Performance Are Not Qualified To Join In This Bidding. B. Possession Of Site 1. The Contractor Admits That He Has Inspected The Site Where The Work Will Be Performed; That He Has Informed Himself Fully As To The Conditions Which Might Affect The Nature, Extent And Cost Of The Work Required; That Picc Shall In No Way Be Responsible For Any Additional Costs Or Expenses Which May Develop On Account Of Failure Of The Contractor To Make Accurate Examination Of Present Or Future Factors Attendant To The Execution. 2. Tapping Of Equipment And Other Related Works Shall Be Properly Coordinated With Picc’s Representative For Provision Of Electrical Power. 3. The Picc Shall Designate A Specific Area To Be Used By The Contractor As Temporary Facilities/storage Area/administration Area In Connection With The Project. The Contractor Must Submit Layout Of The Mentioned Temporary Facilities And Must Be Approved By The Picc Management. 4. The Picc Shall Allow The Contractor To Tap From The Existing Electrical Connections To Be Used In The Latter’s Temporary Facilities, For This Purpose, The Picc Shall Install A Sub-meter Which Was Provided By The Contractor For Power Consumptions And Shall Be Billed Accordingly. C. Contractor’s Obligation 1. The Contractor Shall Perform All Works Necessary To Fully Accomplish The Project. 2. A Joint Inspection Must Be Conducted By The Contractor And Picc Representative, On The Specific Works To Be Done For This Project. 3. The Conractor Is Required To Inspect And Examine The Site And The Surroundings Of The Project To Arrive At An Estimate Of The Labor, Materials, Equipment, Facilities And Services Necessary To Carry Out The Works. 4. The Contractor Shall Commence Execution Of The Works On The Start Date And Shall Carry Out The Works In Accordance With The Program Of Work Submitted By The Contractor, As Updated With The Approval Of Picc Representative And Complete Them By The Intended Completion Date. 5. The Contractor Shall Provide All Supervision, Labor, Materials, Plant And Contractor’s Equipment, Which May Be Required. 6. The Contractor Shall Be Liable To All Fire And Accident Claims And Other Related Claims Arising From The Injuries And Damage, Which Occurred In The Vicinity. 7. The Contractor Shall Free The Picc And Its Personnel From And Against All Liability For Damages Arising From Injuries Or Liabilities To Persons Or Damages To Property Occasioned By Any Act Of Omissions Of The Contractor Including Any And All Expenses Which May Be Incurred By Picc And Its Personnel In The Defense Of Any Claim, Action Or Suit. 8. Any Work That May Affect The Operation, Security And Image Of The Center Shall Be Coordinated Properly With Picc Representative And Shall Be Done In Accordance With The Center’s Approved Schedule. 9. Cost Of Rework And Restoration Of Damaged Properties Due To Contractor’s Poor Workmanship Or Negligence Shall Be Borne By The Contractor. 10. The Contractor Must Submit List Of Personnel Assigned To The Project Including Their Nbi Clearances/barangay Clearance Before Commencing The Above Scope Of Works. D. Warranty The Warranty Shall Be One (1) Year Reckoned From The Date Of Final Turn-over And Acceptance. E. Terms Of Payment 1. Full Payment Shall Be Made Upon Completion Of The Project And Will Be Process Upon Submission Of The Following Documents: A. Letter Request Of The Contractor For The Release Of Payment. B. Work Accomplished As Validated And Certified By Picc’s Representative. C. Photographs Of Work Accomplished. D. Invoice E. Bacteriological Analysis And Physicochemical Test. 2. Full Payment Shall Be Subject To Five Percent (5%) Of The Contract Amount As Retention Money. The Total “retention Money” Shall Be Due For Release Upon Final Acceptance Of The Works. 3. The Picc Representative Shall Check The Contractor’s Request For Payment And Certify The Amount To Be Paid To The Contractor As Progress Payments. Materials And Equipment Delivered On The Site But Not Completely Put In Place Shall Not Be Included For Payment. 4. Picc Shall Pay The Contractor The Amounts Certified By Picc’s Representative Within Twenty-eight (28) Calendar Days From The Date The Request For Payment Is Evaluated And Approved. No Payment Interest Shall Be Made For The Delayed Payments And Adjustments. F. Contractor Qualification 1. The Contractor Shall Be Pcab Licensed With A Classification Of General Building, “d” Category With At Least Three (3) Years’ Work Experience In Cleaning Of Cistern Tanks. 2. The Minimum Work Experience Required For Key Personnel: Key Personnel Relevant Experience 1 – Project Engineer License Civil Engineer/ Architect Must Have At Least Three (3) Years’ Experience As Supervisor Of Civil Works. 1 – Full Time Safety Officer Minimum Of Three (3) Years’ Work Experience As Safety Officer/practitioner. Must Have Certificate Of Employment As Safety Officer And Certificate Of Training In Occupational Safety And Health From Dole Or Any Dole Accredited Training Institution. 3. The Minimum Major Equipment Required For The Project Are The Following: Item No. Number Of Units Description Of Equipment 1 2-units 5hp Sump Pump G. Workmanship The Work Throughout Shall Be Executed In The Best And Most Thorough Manner To The Satisfaction Of Picc And Its Engineers And Supervisors Who Will Jointly Interpret The Meaning Of The Scope Of Work And Its Conditions And Shall Have The Power To Reject The Work, Method Of Accomplishing Every Part Of Work And Material Used Which In Their Judgement Are Not In Full Accordance Therewith And Are Disadvantageous To Picc. H. Schedule Of Work Schedule Of Cleaning Shall Be During Holy Week For The Delegation And Powerhouse Cistern Tanks. The Forum Cistern Tank Shall Be Scheduled Just After The Holy Week. Note: Delays Due To Work Stoppage Ordered By Picc Shall Not Be Counted Against The Set Completion Date. I. Liquidated Damages In Case Of Delay In The Completion Period Inclusive Of Duly Granted Time Extensions, If Any, The Contractor Shall Be Liable For Damages And Shall Pay The Picc For Liquidated Damages In An Amount Equivalent To At Least One (1/10) Of One Percent (1%) Of The Cost Of The Unperformed Services For Everyday Of Delay. The Maximum Deduction Shall Be Ten Percent (10%) Of The Amount Of The Contract, The Procuring Entity Shall Rescind The Award Without Prejudice To Other Courses Of Action And Remedies Open To It. V. General Conditions Of The Contract: 1. All Prices Quoted Herein Are Valid, Binding And Effective For One Hundred Twenty (120) Calendar Days From Date Of Quotation. 2. The Contractor Shall Be Responsible For The Source(s) Of His Services/equipment Shall Make Deliveries In Accordance With Schedule, Quality And Specifications. Failure By The Awardee To Comply With The Same Shall Be Ground For Cancellation Of The Award. 3. The Contractor Shall Pick Up Rs And Ntp Issued In His Favor Within Three (3) Days After Receipt Of Notice To That Effect. A Telephone Call, Fax Transmission Or Email Shall Constitute An Official Notice To The Awardee. Thereafter, If The Rs Remain Unclaimed, The Said Rs Shall Be Sent By Messengerial Service To The Awardee At The Latter’s Expense. To Avoid Delay In The Service Of The Requesting Agency’s Requirement, All Defaulting Awardees Shall Be Precluded From Proposing Or Submitting A Substitute Sample. 4. Subject To The Provisions Of The Preceding Paragraph, Where Awardee Has Accepted A Ntp But Fails To Deliver The Services Within The Time Called For In The Same Order, He Shall Be Extended A Maximum Of Fifteen (15) Calendar Days Under Liquidated Damages To Make Good His Services. Thereafter If Awardee Has Not Completed Delivery Of Services Within The Extended Period, The Subject Rs & Ntp Shall Be Cancelled And The Award For The Undelivered Balance Withdrawn From That Awardee. The Picc-bac Shall Then Purchase The Required Services From Such Other Source(s) As It May Determine, With The Difference In Price To Be Charged Against The Defaulting Awardee. Refusal By The Defaulting Awardee To Shoulder The Price Difference Shall Be Ground For His Disqualification From Future Bids Of The Same Or All Items, Without Prejudice To The Imposition Of Other Sanctions As Prescribed Under Ra 9184 And Its Irr-a. 5. All Services By The Contractor Shall Be Subject To Inspection And Acceptance By The Picc. 6. A Penalty Of One Tenth (1/10) Of One Percent (1%) Of The Total Value Of Services/works Shall Be Deducted For Each Day Of Delay Including Sundays And Holidays In The Delivery Of The Services. 7. All Transactions Are Subject To Withholding Of Creditable Value Added Tax (vat) Per Revenue Regulation No. 10-93.

Description: Supply And Delivery Of Construction And Electrical Materials For The Citywide Repair Of Streetlights , Construction Materials And Supplies ,city Of Santiago, Isabela

Description: Ct0148 - Provision Of Mechanical + Electrical Services In Relation To Major Adaptations To Nihe Dwellings For People With Disabilities (mapds) North And South Region

Description: Renovation of multi-family house - Potsdamer Allee 45-51,53-59,61-69, 16227 Eberswalde, Germany, electrical engineering

Description: Supply And Installation Of Closed-circuit Television (cctv) System , Electrical Systems And Lighting Components ,municipality Of Mamburao, Occidental Mindoro

Description: Romania – Electrical Installation Work – Mărirea Capacității De Distribuție Prin Modernizare Lea 110kv Târgu Mureș-livezeni-corunca-fântânele, Respectiv Stațiile De Transformare Tg. Mureș, Livezeni, Corunca Și Târnăveni

Description: Germany – Repair And Maintenance Services Of Electrical Building Installations – Unterhaltung Fachtechnik In Brücken Und Ingenieurbauwerken; Wartung Und Instandsetzung Von Elektroinstallationen, Los 1 Und Los 2

Description: 055-25-00009 - Tax Office Bünde, Wc facilities: Electrical work

Description: Germany – Electrical Wiring And Fitting Work – Elektroanlagen - Kg440 Starkstrom

Description: Purchase Of Materials For The Installation/construction Of Solar Street Lights, Tugbungan-malabong, Barangay Andulauan,ilog, Negros Occidental , Electrical Systems And Lighting Components ,municipality Of Ilog, Negros Occidental