Roads And Buildings Department Tender

The bidder is required to have prior work experience in civil engineering constructions. The required experience includes a minimum annual financial turnover, defined as billing for works in progress and completed in all classes of civil engineering construction works only, in any one year, over the last five years of the annual value of contract/contracts applied for. The bidder should have experience in successfully completing or substantially completing at least one contract of highway (road and/or bridge works) or airport runway of at least 40 percent of the value of the proposed contract within the last five years. Substantially completed works mean those works which are at least 90% completed. The bidder should have completed at least one contract of similar work with a value of at least 40% of the proposed contract value, and the work should be substantially completed, i.e., at least 90% completed. The bidder should provide information on the value of similar works completed, with details such as contract value, billing amount, and percentage of work completed. The bidder should also provide information on quantities of work executed as prime contractor, work performed, in the past as a nominated sub-contractor. The required experience includes total value of civil engineering constructions work performed in the last five years, with specific details of each project, including project name, name of the employer, description of work, contract number, value of contract, date of issue of work order, stipulated period of completion, actual date of completion, and remarks explaining reasons for delay and work completed. The bidder must have completed works of a similar nature over the last five years, but no specific percentage of similar works is mentioned other than 40% of the proposed contract value. The bidder must provide certificates from the engineer(s) in charge for the completed projects. The bidder should provide information on the amount involved in any litigation or arbitration resulting from contracts completed or under execution by him over the last five years. The bidder should provide audited balance sheets for the last five years, demonstrating the soundness of the applicant's financial position, showing long-term profitability, including an estimated financial projection for the next two years. The bidder should have access to, or have available, liquid assets (aggregate of working capital, cash in hand, and uncommitted bank guarantees) and/or credit facilities up to 25 percent of the value of the contract/contracts applied. The bidder should provide information on the qualifications and experience of key personnel required for administration and execution of the contract. The bidder should provide information on the availability of key items of contractors' equipment for carrying out the works. The bidder should provide information on the proposed sub-contract and firms involved. The bidder should provide information on the financial reports for the last five years. The bidder should provide information on the evidence of access to financial resources to meet the qualification requirements. The bidder should provide information on the name, address, and telephone, telex, and fax numbers of the bidder's bankers who may provide references if contacted by the employer. The bidder should provide information on the litigation history. The bidder should provide a statement of compliance under the requirements of the instruction to bidders. The bidder should provide information on the general experience. The enhancement factors for calculating the experience are as follows: - 2024-2025: 1.00 - 2023-2024: 1.10 - 2022-2023: 1.21 - 2021-2022: 1.33 - 2020-2021: 1.46 - 2019-2020: 1.61 The applicant should indicate actual figures of costs and amount for the works executed by them without accounting for the above-mentioned factors. If the financial figures and value of completed works are in foreign currency, the current market exchange rate will be applied for the purpose of conversion of the amount in foreign currency into India rupees. The bidder is required to have prior work experience in civil engineering constructions, with a minimum annual financial turnover, and experience in successfully completing or substantially completing at least one contract of highway or airport runway, with substantially completed works meaning those works which are at least 90% completed. The bidder should provide information on the value of similar works completed, with details such as contract value, billing amount, and percentage of work completed, and quantities of work executed as prime contractor, work performed, in the past as a nominated sub-contractor. The bidder should provide certificates from the engineer(s) in charge for the completed projects, and information on the amount involved in any litigation or arbitration resulting from contracts completed or under execution by him over the last five years. The bidder should provide audited balance sheets for the last five years, and information on the qualifications and experience of key personnel required for administration and execution of the contract. The bidder should provide information on the availability of key items of contractors' equipment for carrying out the works, and the proposed sub-contract and firms involved. The